Letter of Commitment on Contract 1 Once our company is recommended as the candidate for winning the bid, our company will negotiate the construction contract with the tenderee according to the Model Text of Construction Contract for Construction Projects (GF- 1999-020 1) issued by the State Administration for Industry and Commerce and the Ministry of Construction. Our company promises the main terms of its contract.
If our company does not accept the main terms of the following contract, the tenderer has the right to choose the second and third candidates.
First, the project acceptance
The project completion acceptance shall be carried out according to the acceptance method stipulated by the state.
Second, the construction period
The bidding period is 120 days. If the construction period is delayed due to the reasons of the construction unit, the construction period will not be postponed, and Party A shall bear all the economic losses caused thereby. Due to the tight construction period of this project, except for force majeure and Party A's reasons, the construction period will not be postponed. Our company has fully considered various factors affecting the construction period, including rainy season construction and power outage measures. The cost of not taking measures to catch up with work. If the construction period is delayed due to our company's reasons, the construction period will not be postponed, and for each day of delay, it will bear the penalty of Wu Bai yuan; Party A shall also bear all economic losses caused by the delay of the construction period, and the maximum compensation amount of liquidated damages for the construction period shall not exceed 10% of the total contract price.
Third, the project quality
Ensure that the project quality meets the acceptance standards stipulated in the relevant documents of this project. If the quality of the project fails to meet the standards stipulated in the tender due to our company's reasons, our company should rework it in time, bear the rework fee, delay the construction period and bear the economic liquidated damages of 2% of the contract price; If the project is reworked due to the reasons of the construction unit, the construction unit shall bear the cost of rework, and the construction period shall be postponed accordingly.
Fourth, the project price and payment
1, the contract price is guaranteed at one time according to the bid quotation promised by the winning bidder, and the adjustment of the contract price is implemented according to the relevant provisions of this tender document.
2. Pay an advance payment of 20% of the total project price within 15 days after the contract is signed and started.
3. After deducting the down payment of 20%, the remaining project funds will be allocated according to 80% of the actual project progress of the month. The project payment for design change shall be adjusted and paid according to the proportion of progress payment in the same period, and payment shall be stopped after 80% of the total cost of the completed project is paid. After the project is completed and accepted to meet the specified quality requirements, the remaining balance except the quality guarantee fund shall be paid within 30 days.
4, after the completion of the project settlement, leave 5% as the project warranty.
5. The warranty money expires according to the regulations of the Ministry of Construction, and will be refunded after earnestly performing the warranty duties, without interest.
6. Adjustment of contract price: It shall be implemented according to Article 7 of Chapter II.
Verb (abbreviation for verb) project subcontracting
In order to ensure the quality of the project, our company shall not subcontract or link the project. The specific construction technology and materials must be approved by the construction unit when subcontracting, and meet the requirements of various building regulations. The builder must be a registered builder of the unit.
The construction department and all management personnel of the project construction must be consistent with the personnel in the tender and always be in the corresponding posts. Otherwise, Party A may terminate the contract, and Party B has no right to return the bid bond and bear all the losses caused to Party A ... When the construction personnel in charge of this project go out due to special circumstances during the project implementation, they need to obtain the consent of the owner.
Six, safety in production
In the process of construction, our company should ensure safe production and civilized construction. In case of major construction accidents or casualties, all responsibilities and expenses shall be borne by Party B. ..
Seven. Breach of contract and compensation
Breach of contract and claim for compensation according to Articles 35 and 36 of General Terms and Conditions of Model Construction Contract for Construction Projects (GD- 1999-020 1).
1. No matter whether Party A or Party B is uneasy about performing the obligations under this contract, they shall be liable for breach of contract.
2. Party B's failure to fulfill the bidding promise, changing the construction engineer and technical director without authorization, subcontracting the project or subcontracting the project without Party A's consent are regarded as breach of contract, and Party A has the right to terminate the contract and all the economic consequences caused thereby.
All losses shall be borne by Party B. ..
Eight. Mediation and arbitration of contract disputes
If there are any problems in the execution of this contract, both parties shall refer to the Contract Law of People's Republic of China (PRC) and solve them in a spirit of mutual understanding and mutual accommodation. When necessary, it may be submitted to the higher authorities of both parties for mediation. In case of dispute, it shall be arbitrated by the relevant departments or submitted to the people's court with jurisdiction for adjudication.
Nine. Supplementary, Effective and Invalid Contract
For matters not covered in this contract, both parties can supplement and modify it through consultation, and the supplementary contract has the same effect as this contract.
This contract shall come into effect after being signed, sealed and notarized by both parties, and shall naturally become invalid from the effective date to the completion of project acceptance and delivery, and after the bond debt is settled.
Bidder: legal representative or entrusted agent of Yunnan Yongyao Construction Engineering Co., Ltd. (company seal): (signature)
Letter of Commitment on the Contract 2:
ID number:
Address:
Telephone:
Commitment party:
Address:
Telephone:
Guarantor:
Address:
Telephone:
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ refers to any one of _ _ _ _ _ _ _ _ _ _
1. The promisor shall unconditionally perform the responsibilities, rights and interests of Party B in the labor subcontracting contract.
2, engineering quality, safety, wages of migrant workers, the progress of the project and other issues by _ _ _ _ _ _ _ _ labor subcontracting company to bear the responsibilities and losses (including indirect losses) are unconditionally borne by the promisor.
3. Abide by relevant national laws, regulations, standards, new policies and relevant systems of labor service companies.
4. Accept the management and supervision of relevant departments, general contracting enterprises and labor service companies.
5. Shall not damage the image and reputation of the labor service company and other things that are detrimental to the labor service company.
6. Labor workers (including special workers) to whom Party B belongs shall apply for accident insurance and hold relevant certificates when entering the site, and other social insurance shall be handled in accordance with relevant regulations.
7. If losses and accidents are caused by Party B's responsibility in the construction process, they must be solved as soon as possible in accordance with relevant regulations, otherwise, the labor service company has the right to detain all creditor's rights and other private property in the general contracting enterprise through various means (including judicial means) to solve them.
8. This commitment contract was signed on _ _ _ _ _ _ _ _ _.
9. All taxes, fees and management fees caused by the above-mentioned contract to the _ _ _ _ _ labor subcontracting company and other problems caused by the above-mentioned contract (above terms) shall be unconditionally borne by the promisor.
Commitment (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Commitment party (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Guarantor (signature):
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
About Contract Commitment Letter 3: Tenderer:
If our company is lucky enough to win the bid, we hereby solemnly promise:
1. The bidding documents (including contract terms) have the final interpretation right.
2. During the project implementation, our company fully responded to all terms of the bidding documents and fulfilled its contractual obligations. The quality standard is by no means lower than the requirements of the tender documents or the national and local mandatory standards of Guangdong Province.
3. Our company fully responds to and abides by the project acceptance, measurement and payment methods specified in the bidding documents.
4. During the implementation of the project, your company has the right to add (add or add new work contents) or reduce some work contents according to the design change and on-site visa of the project. Our company is willing to fully cooperate with and support all your decisions, and settle accounts in the way stipulated in the bidding documents and contract terms.
5. Our company agrees and cooperates with your company to supervise the project funds. If our company violates the above commitments during the project implementation, you have the right to cancel our bid-winning qualification or terminate the construction contract, and confiscate our bid guarantee or performance guarantee.
Note: The bidder must correspond to the text of the construction contract in this tender document.
Bidder: (Seal)
Legal representative or its authorized client (signature or seal):
Date: Year Month Day
Regarding the Contract Commitment Letter 4 1, we agree that Party A will negotiate to adjust the unbalanced part of our bidding unit price under the condition that the total price remains unchanged;
2. We agree to settle accounts according to the actual quantities approved by Party A according to the increase or decrease of quantities in the construction process, while keeping the unit price of the subcontract unchanged. We unconditionally accept the excavation and fill position adjusted by Party A during the construction. If the transportation distance is changed, the settlement shall be adjusted according to the unit price of the subcontract;
2, we guarantee that after receiving the notice of entry, according to the requirements of the contract documents and notice of entry, equipped with all management personnel, technical personnel and mechanical equipment, materials, comprehensive management of this project, to meet the performance inspection of relevant departments, to ensure that all projects are not subcontracted or subcontracted; At the same time, we will accept your inspection and acceptance. If we can't meet your requirements and our own commitments, we will accept your cancellation of the contract and bear all the responsibilities ourselves.
3. We promise to ensure that the model of the equipment entering the site meets the mandatory requirements of bidding, and the ownership rate of main construction equipment is not less than 60%. If the project progress is delayed because the quantity of equipment does not meet the bidding requirements, Party A has the right to ask our company to leave, and all losses caused thereby shall be borne by our company;
We promise that under any circumstances, we will not buy the materials provided by Party A as stipulated in the price list of materials provided by Party A without your written consent.
5. We guarantee to meet the construction plan issued by Party A. If the progress plan required by your company cannot be met for three consecutive weeks or five weeks in total, your company has the right to ask our company to leave and terminate the subcontract, and promise not to charge you any fees and bear other expenses increased by your company. After all the construction personnel and mechanical equipment of our unit are evacuated from the site, the settlement shall be made according to the actual completed quantity approved by your unit and the unit price agreed in the subcontract.
6. We promise to accept the supervision, inspection and guidance of the local government, you and the supervision engineer on the construction safety management of our unit at any time, and accept rewards and punishments. In case of casualties, I will report to you immediately, take emergency measures, rescue in time, and bear all responsibilities and all expenses incurred by myself.
7. We promise to ensure that the environmental objectives agreed by you in the terms of the contract are achieved. Economic losses caused by non-compliance with environmental protection requirements shall be borne by us.
8. We promise that after signing the contract, we will sign insurance claims with the insurance company for all our personnel, property, machinery and equipment in time, and guarantee that you will not be required to bear the economic loss compensation.
9. We promise to guarantee this project in strict accordance with the contract and the laws, regulations and provisions of the project location.
Commitment letter of contract commitment 5 in response to the contract agreement in the bidding documents.
To: zhangwan district Housing and Construction Bureau, Shiyan City.
If our company can win the bid for the construction of zhangwan district sewage branch pipe network project in 20xx, according to the requirements of "People's Republic of China (PRC) Bidding Law" and "Construction Law", our company promises to accept the terms of the contract agreement in the bidding documents.
1. Time limit: According to the bidding time limit, the effective working day is 90 days. The commencement time shall be subject to the notice of Party A. If it is not completed within the specified time limit, a fine of 1 000 yuan will be imposed for each day of delay, which will be deducted from the performance bond of our company.
2. Quality: the first acceptance reaches the qualified standard; If the first acceptance fails to meet the qualified standard, 2% of the contract amount will be deducted as liquidated damages, and rework will be carried out until the specified quality standard is reached.
3. Payment of project funds: payment according to the project schedule agreed in the contract.
Four. Warranty: It shall be implemented in accordance with the National Construction Project Warranty Measures and relevant national laws and regulations.
Verb (abbreviation of verb) liability for breach of contract: in accordance with the bidding documents, contract terms and relevant national laws and regulations.
Six, other terms of the contract agreement in the tender documents are confirmed and responded by our unit. Hereby promise!
Bidder: Zhao Yi Huatang Construction and Installation Engineering Co., Ltd.
Date: Year Month Day
Commitment letter of Contract 6:
In order to strictly control the wrong behavior of overestimating and making false reports, and ensure the authenticity and accuracy of the project budget. According to the relevant regulations, we promise to implement the measures to link the quality of the project budget compiled by our unit with the audit fee. The specific commitments are as follows:
1, we promise that our unit will bear the audit fee for the increased project cost caused by the omission, under-calculation and over-calculation of the budget submitted by the * * * * project.
2, the audit fee calculation standard:
(1) We promise that when the settlement reduction amount submitted for review is between 10% and 15%, the audit fee exceeding 10% will be borne by us;
(2) If the settlement reduction amount submitted by us exceeds 15%, all audit expenses shall be borne by us;
(3) If the settlement submitted by us is excessively reduced, the audit cost of the whole project general contracting cost shall be borne by the construction unit, then the audit cost shall be borne by our unit.
3. The above reduction rate is determined according to the requirements of the construction unit. If the construction unit has new regulations, the new regulations shall prevail.
Subcontractor (signature and seal):
Date: Year Month Day
Contract Commitment Letter 7 If our company is lucky enough to win the bid, Nantong Huayuan Science and Technology Development Co., Ltd. has no objection to the contract terms in the bidding documents of the intelligent system project for the overall relocation of Hai 'an Fire Building, and responds in full accordance with these terms.
Authorized representative of the bidder as a legal person: (signature)
Bidder (seal):
Date:
Party A: (If Party A is not a company, adjust)
Party B: (If it is a legal person, it must have the same name as the business license; If it is a natural person, it is the same as the ID card).
ID number: (If it is a natural person, keep this item)
Party A and Party B signed the _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
1. The original _ _ _ _ _ _ was dissolved on _ _ _ _, and the rights and obligations of both parties agreed in the original contract/agreement shall be terminated as of the date of dissolution;
2. Party A shall return the unpaid amount of _ _ _ _ _ _ _ _ _ to Party B.
3. When this termination agreement comes into effect, Party A shall return the RMB deposit paid by Party B to Party B; If there is a deposit, keep this clause, if there is no deposit, delete this clause.
4. Use this clause when both parties are not liable for breach of contract. This agreement shall come into force after being signed and sealed by both parties. On the effective date of this agreement, the original "_ _" shall be filled with the name of the contract/agreement previously signed by both parties, and both parties shall not be liable for breach of contract; This agreement shall come into force after being signed and sealed by both parties. On the effective date of this agreement, the original _ _ _ _ _ shall be dissolved, and Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. This agreement is made in duplicate, each party holds one copy, which has the same legal effect.
Party A: Party B:
Representative: representative:
Date: Date: