Now the public's legal consciousness is getting stronger and stronger, and the status of contract is becoming more and more important. Signing a contract is also very necessary. So what should we pay attention to when concluding a contract? The following are five production contracts I collected. Welcome to read the collection.
Concluding the Contract 1 Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
Based on the principles of honesty, credibility, equality and mutual benefit, Party A and Party B, through friendly negotiation, Party A entrusts Party B to be responsible for _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
1. Party A shall select the installation location of relevant billboards and provide relevant certificates and materials required for approving the setting of advertisements.
2. Party B is responsible for the normal production and installation of shop signs.
Three, advertising signs design, production and installation requirements:
1. It is made in strict accordance with the VI image of the company, and the design draft must be approved by Party A. ..
2, materials, production requirements shall be subject to the requirements of the site.
3. Installation and overall appearance requirements. Installation requirements must be made by pulling nails, welding, etc., and the drawings must be neat and smooth; The overall beauty is exquisite.
4. Party B shall complete the manufacturing and installation work within 7 days after receiving the order.
Four. Fees and payment methods:
1. Fee: calculated per square meter, and the price is calculated in RMB (subject to the price list of Zhuhai Henglin Advertising Company).
2. Payment method: Party A shall pay by bank transfer within one month after receiving the invoice and photos.
Payee: * * Advertising Co., Ltd.,
Bank of deposit: China Industrial and Commercial Bank * * * Sub-branch.
Bank account: 200202 * * * * * * * *
Verb (abbreviation for verb) is published and signed:
1. After each signboard is installed, Party B shall take a five-inch color photo and provide it to Party A for signature and confirmation.
2. Before the 28th of each month, submit the detailed list of store recruitment made this month (the format of the detailed list of store recruitment is provided by Party A, which needs to be signed and sealed by the heads of the Ministry of Commerce (office), agents and production units) to the handover personnel of Party A, and return it to the headquarters for Party A's signature and verification.
3. Headquarters inspection: Due to the long distance, Party A may sign for the billboard in the form of inspection photos. Therefore, Party A reserves the right to send personnel from the headquarters for inspection and acceptance within 1 year, and the inspection indicators of the headquarters only include: actual dimensions and materials. Party B understands this. If the inspection results of the size and materials of the headquarters are different from the acceptance results, the inspection results of the headquarters shall prevail. If Party B misstates the dimensions and materials at the time of receiving the goods for any reason, resulting in the actual dimensions being smaller than the acceptance dimensions or the materials being different from the materials approved by both parties in writing, and the actual expenses are different, Party B shall pay Party A a a quality penalty equivalent to 3 times of the corresponding difference.
Maintenance of intransitive verbs:
1. The shelf life of billboards is _ 1 _ _ _ years.
2. The warranty period is twelve months from the date of completion of the project, and Party B is responsible for the free maintenance of the installed billboards (the maintenance cost caused by force majeure factors such as man-made damage and strong winds of magnitude 8 or above shall be settled by both parties through consultation), and the quality (including installation) of the repaired billboards shall meet the production requirements at the time of installation.
3. During the installation, if there is any quality problem with the billboard, Party B will send someone to inspect and repair it free of charge within five days after receiving the notice from Party A. ..
Seven. Good faith clause: the staff of both parties shall not accept, ask for, borrow or accept gifts in any form.
Accept any money, goods and services from the other party. If either party gives material or non-material benefits to the staff of the other party in this way or in disguised form, it is regarded as a serious breach of contract, and the breaching party must unconditionally return or compensate the corresponding benefits to the other party and bear other legal responsibilities arising therefrom.
Eight. Other matters that both parties think need to be agreed upon: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
________________________________________________________________
________________________________________________________________
________________________________________________________________
________________________________________________________________
________________________________________________________________
Nine. Effective terms of the contract:
1. Based on the signing of this contract, Party B clearly knows and agrees to any letter of commitment issued in the name of Party A,
Documents that establish, modify or terminate rights and obligations, such as confirmation letter, purchase order, acceptance certificate and account reconciliation letter, shall have legal effect on Party A only after being signed and stamped with the official seal by the legal representative or authorized person of Party A; Other personnel of Party A who commit the above-mentioned acts shall be regarded as acts with undetermined effect, and only after being approved by Party A in writing shall they have legal effect on Party A.. ..
2. Party B has the obligation to examine the signatory of any document issued by Party A to establish, change or terminate rights and obligations and the qualification of his signing behavior. Party A shall not be liable for any losses caused to Party B or a third party due to Party B's delay or improper performance.
X. preferential commitment: in view of the long-term cooperative relationship between the two parties, Party B promises that the quotations of all products and services are not high.
The quotation provided by Party B to other customers is not higher than the normal market price.
XI。 Methods of resolving disputes.
1. In case of any dispute during the performance of this contract, Party A and Party B shall settle it through consultation and sign an agreement with this Association.
The supplementary agreement shall be negotiated through the same procedure, and the validity of the supplementary agreement shall be higher than this agreement.
2. Unwilling to negotiate or failing to negotiate, it shall be under the jurisdiction of the people's court where Party A is located.
12. This contract is valid for two years, from _ _ _ to _ _ _. Thirteen. This contract is made in quadruplicate, with Party A holding three copies and Party B holding one copy. This contract shall come into effect after being signed and sealed by the three parties, and
Party A shall take effect on behalf of both parties by the commercial representative and the advertising department.
Party A:
Representative of the Ministry of Commerce: Representative of Party B:
Date: _ _ _ _ _ _ _ _ _ _ _ _ _
Party B:
Representative of advertising department:
Date: _ _ _ _ _ _ _ _ _ _ _ _ _
date month year
Concluding the Contract Part II Party A:
Party B:
Through equal consultation between Party A and Party B, Party B agrees to manufacture and install for Party A..
The details of the Head Office are as follows:
1. The total cost of manufacture and installation is RMB (in words) five thousand Yuan only (in figures) 15000.00 Yuan.
2. The specification is 3. The start and end date of the construction site construction period is from to September 25th, 20xx, and the installation is completed.
4. Party A is responsible for providing:
5. Party B is responsible for providing:
6. Party A shall pay Party B the down payment of the project in RMB before the installation of the project is completed.
After completion, Party A will pay the remaining project funds to Party B in one lump sum.
7. The warranty period is months, except for force majeure (natural factors and human factors).
Party B shall maintain the plaque free of charge due to quality problems (such as aluminum-plastic board gluing, acrylic board fading and deformation, light source damage, etc.).
Repair. After the warranty period, if you still need maintenance, it is taste maintenance.
This agreement is made in duplicate, each party holds one copy, and the signatures of both parties have legal effect.
Signature of Party A: Signature of Party B:
Or (seal) or (seal)
20xx August 3 1
Concluding the Contract Part III Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC), Advertising Law of People's Republic of China (PRC), Regulations on Contracting of Construction and Installation Projects and other laws and regulations, in order to clarify the rights and obligations of both parties, the following agreement is reached on the production and installation of billboards contracted by Party B (hereinafter referred to as billboards) through friendly negotiation.
One: billboard production
1, billboard specifications:
2, material:
3. Requirements:
Two: billboard installation
Installation location:
3. Project cost and payment method
1. Billboard production fee (i.e. total contract price): * * * RMB only, in words.
2. Payment method:
A. When signing the contract, Party A shall pay 30% of the project cost in advance.
B. After the fabrication and installation are completed, Party A shall pay off all the project funds after passing the acceptance.
Four: the construction cycle
1, from the date when Party A prepays the project payment after the signing of this contract. In case of force majeure factors (such as rain, snow, gale above level 4), the construction period will be postponed.
2. If Party B's work can't be completed on time due to Party A's repeated revisions, the extension time can be determined by both parties through consultation.
Verb (abbreviation for verb) Rights and obligations of both parties.
Party A:
1, go through the necessary examination and approval procedures and related expenses for billboard installation.
2. Have the right to put forward suggestions and amendments to Party B's design, so that the works designed by Party B are more in line with the cultural connotation of Party A's unit.
3. Provide Party B with the location of the billboard, and ensure that there is no pipeline in this location, so it can be constructed.
4. Party B has the obligation to provide relevant company information or other relevant information for Party B's design reference.
5. The trees, flowers and plants responsible for the construction site can be moved.
6, according to the provisions of this contract settlement billboard production and installation costs.
Party B:
1. After Party A notifies that the site construction can be carried out, it shall complete the construction and installation within the specified time according to the installation location provided by Party A. ..
2, in strict accordance with the construction plan drawings confirmed by Party A for production and installation. If the site conditions are inconsistent with the construction drawing scheme, it shall be reported to Party A in time for negotiation, modification and confirmation.
3. Party B enjoys the copyright of the design works.
Six: About acceptance
1. Within one week after Party B completes all production and installation, Party A must organize formal acceptance; If Party A fails to organize the acceptance within one week after the completion, it shall be deemed that the quality of the project accepted by Party B is qualified.
2. The project quality acceptance is based on the national steel structure building standards, and the advertising structure is made and installed firmly, and the wind resistance level reaches 7.
Seven. Liability for breach of contract:
1. If Party A fails to make payment according to the time stipulated in Article 3 of this contract, Party A shall pay 0.5% of the total contract price as liquidated damages to Party B for each day overdue, and extend the contract period.
2. If Party B fails to complete the production and installation of billboards on time as stipulated in Article 4 of this contract without justifiable reasons, Party B shall pay 0.5% of the total contract price to Party A as liquidated damages for each overdue day.
3. Party B shall ensure that the project quality, structural firmness, wind resistance and other indicators meet the national standards. If it is unqualified, Party B shall bear the rework and corresponding losses.
4. If it is due to Party A's reasons, Party A shall be responsible for stopping work, construction and demolition. Party B has the right to require Party A to pay part or all of the production costs according to the actual construction conditions.
Eight. Responsibility arising from advertising:
1. During the production and setting of this advertisement, if the personal or property damage of a third party is caused by Party B, Party A has nothing to do with it.
2. Party A shall bear all responsibilities for disputes arising from trademarks, portraits, advertising words and other advertising contents provided by Party A. ..
Nine, warranty period:
1. From the date of acceptance, the quality of engineering steel produced by Party B shall be guaranteed for half a year. Party B is not responsible for the warranty for man-made damage.
2. After the warranty period expires, both parties shall re-sign a maintenance agreement for maintenance.
X any dispute arising from this contract shall be settled through friendly negotiation. If negotiation fails, it shall be arbitrated by Changting County Arbitration Commission. XI。 This contract is made in duplicate, one for each party, with the same legal effect.
Concluding a Contract Article 4 Cooperation Agreement
Party A: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Based on the principles of sincere cooperation, equality and democracy, Party A and Party B have reached the following agreement on relevant cooperation matters through friendly consultation for mutual compliance:
Article 1: Scope of cooperation
Article 2: Rights and obligations of both parties
(I) Rights and obligations of Party A
1、
2、
(II) Rights and obligations of Party B
1、
2、
Article 3: Conclusion of a treaty of understanding.
1、
2、
3、
4、
Article 4: Liability for breach of contract
1 party and _ _ _ _ party fail to abide by the provisions of this contract, which is a breach of contract and should be given to _ _ _ _
2. If Party A fails to comply with the provisions of this contract, it shall be deemed as a breach of contract and shall be given to Party A..
3. The determination of the entrustment content of this agreement and the alteration, suspension, dissolution and early termination of entrustment shall be confirmed by both parties in writing. If either party breaches the contract, the breaching party shall compensate the other party.
Article 5: Others
1. This agreement is made in duplicate, with each party holding one copy. All have the same legal effect.
2. Matters not covered in this agreement shall be settled by both parties through negotiation and a supplementary agreement shall be signed separately.
3. This agreement shall come into force as of the date of signing.
Party A (signature): _ _ Party B (signature): _ _
Consultant (signature): _ _ _ _
Notary Office (Seal): _ _ _
Signed at _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 5 Production Contract Party A (buyer): Yulin * * Clothing Co., Ltd. Party B (seller): Party A and Party B have reached the following fabric purchase contract on the basis of equality, voluntariness and consensus in accordance with relevant national laws and regulations for common compliance:
I. Product name, specification, color, quantity and price
Party A shall purchase the required goods from Party B according to the contents listed in the above purchase order, and Party B shall supply the goods according to the contents listed in the above purchase order. All prices include tax, and 17% VAT is calculated at 0.08%.
Second, the delivery date:
Party B shall transport all the goods purchased by Party A to the place designated by Party A within 25 days after the signing of the contract. Party B solemnly promises to deliver the goods in strict accordance with the delivery time agreed in the order. If Party B fails to deliver the goods on time, Party B shall notify Party A in writing five days in advance, and the delivery cannot be delayed until Party A agrees. If Party A accepts the ordered goods in case of overdue delivery,
Still have the right to investigate Party B's liability for breach of contract.
Third, the quality requirements:
According to the samples confirmed by Party A, the quality must be consistent with that of Shaanxi Fiber Inspection Institute, and the dyes are directly dyed according to national environmental protection standards. The color fastness is above 3.5, the gram weight is above 280 g, and the pilling resistance is above 3.
Party B must produce large goods in strict accordance with the samples of Party B held by Party A. The fabrics delivered shall conform to the national general safety technical specifications for textile products, and the quality shall be consistent with the samples held by Party A. There shall be no color difference. Gram weight, amplitude, elasticity, density, etc. Should be consistent with the sample, there should be no drawing, color fading, pilling and other phenomena, good gloss, clothes can not be worn and washed for 5 times without quality defects such as color fading and pilling. If the fabric produced by Party B does not meet the national testing standards and Party A's quality requirements, Party A has the right to refuse to receive the goods. All economic losses caused thereby shall be borne by Party B. ..
Four. Acceptance of goods
1. Due to the particularity of fabric products, Party B must attach relevant test reports when delivering, and the test reports must be consistent with those of Shaanxi Fiber Inspection Institute. However, if Party A finds that the purchased fabrics have quality problems after cutting, it has the right to raise quality objections.
Party A has the right to entrust another quality inspection department to inspect the fabrics delivered by Party B according to national standards. If the quality is found to be unqualified, Party A has the right to return this batch of fabrics, whether it is cut or not. Party B will unconditionally refund all the payment and bear all the losses caused to Party A from it.
2. When Party A discovers the quality and quantity problems of Party B's bulk fabrics, it shall promptly issue a notice of quality objection in written form (including but not limited to fax, email, telegram, letter, express delivery, etc.). ).
After receiving the written notice from Party A, Party B must put forward the remedial treatment plan within 1 working days and actively negotiate with Party A.. If Party B refuses to put forward a clear treatment plan within the time limit, or fails to reach an agreement with Party A on the treatment plan, Party A has the right to terminate the contract and hold Party B liable for breach of contract according to Article 8 of this contract; In this case, Party A also has the right to choose to continue to perform the contract as the case may be, and ask Party B to bear the liability for breach of contract and compensation.
Verb (abbreviation for verb) delivered quantity:
Party A needs bulk goods exceeding% of the agreed quantity, and Party B shall accept it. The actual delivered quantity shall not be less than the agreed quantity. If Party B fails to deliver the goods according to the agreed quantity or the quantity required by Party A for some reason, Party B shall notify Party A in writing five days in advance, and the delivery can be delayed only after Party A agrees, otherwise the delivery shall not be delayed for any reason.
Intransitive verb delivery method:
Party B shall deliver the bulk fabric to the delivery place designated by Party A according to Party A's delivery requirements (Party A shall designate the delivery place by fax, email, telegram, letter and other written documents), and the freight shall be borne by Party A. When Party B delivers the goods, it shall indicate the single number and the model, color number, cloth type, gram weight, color, quantity and other information of the goods on the invoice.
Seven. Payment terms:
After signing the contract, Party A shall pay% of the total payment in advance as the down payment, and pay% of the total payment after all the goods have arrived at the place designated by Party A and the preliminary acceptance meets the requirements of Party A's order, and the balance shall be paid within the day after inspection.
Eight. Liability for breach of contract:
If the overdue delivery reaches more than 5 days (including 5 days), Party B will bear the total contract price.
5% penalty; If the delivery is overdue for more than 10 days (including 10 days), Party B shall bear the penalty of 10% of the total contract price; If the delivery date exceeds 15 days, Party A has the right to choose to terminate this contract or continue to perform this contract, but at the same time, Party B is required to bear the liability for breach of contract.
Party A and Party B must strictly perform this contract. If this contract cannot be continued due to breach of contract, the breaching party will compensate 30% of the total contract price as liquidated damages. If the liquidated damages are insufficient to make up for the losses, the breaching party shall also make compensation.
9. Any dispute arising from this contract shall be settled by both parties through consultation. If negotiation fails, either party may bring a civil lawsuit to the people's court where Party A is located to resolve the dispute.
X this contract is made in duplicate, one for each party. It has legal effect from the date of signature by both parties.
Party A: (Seal) Party B: (Seal)
Signature Representative: Signature Representative:
Date: Year Month Day Date: Year Month Day