Entrusting party:
I. Total (in words): The specific amount shall be subject to the actual shipment.
Second, quality requirements and technical standards: subject to the confirmation of the manuscript provided by the customer! According to national standards.
Third, the responsibility and quantity of the page fee:
All packages are made by Yuncheng Plate Making Company, and the printing fee is 65,438+049,000 yuan in advance by the entrusting party. If the cumulative value of each set reaches150,000 yuan, the organizer will refund the publishing fee in full. The modification fee shall be borne by the entrusting party. See the attachment for the minimum order quantity.
Four. Payment settlement method and time:
The contractor shall provide 17% VAT invoice at the end of each month, and the entrusting party shall pay it before 20th of the following month. Unless otherwise stipulated by the contractor in writing, payment shall be made by remittance to the bank where the contractor opens an account listed in this contract.
Verb (abbreviation of verb) acceptance criteria and methods: according to the relevant national standards or the acceptance criteria and methods agreed by both parties in writing.
6. Mode of transportation and delivery time: The contractor is responsible for delivery to the entrusting party, and the freight contractor is responsible. Delivery time of the new version: 20 days after the customer confirms the manuscript, and 15 days after the contract is signed.
7. Processing place: the location of the contractor.
Eight, after the contract comes into effect, the contractor shall pay the developer a quality deposit of 20000 yuan, which will be deducted at the time of settlement.
Nine. After the contract comes into effect, the entrusting party proposes to change the subject matter of the contract halfway. If no losses are caused to the contractor, the entrusting party may request to change the order, and the contractor shall deliver the goods according to the changed order. If the contractor has carried out the construction, all the manuscript fees, edition fees, material fees and working hours shall be borne by the entrusting party, and the entrusting party shall not refuse to pay the relevant fees.
X agreement on delivery date: the delivery date shall be determined by both parties through consultation according to the technical requirements of the product, and the time shall be counted from the time when the entrusting party finally determines and places the order. The delivery date will be delayed due to the finalization or delay of the order.
XI。 Acceptance time: From the date when the contractor delivers the products, the entrusting party shall inspect the quantity and quality of the products as agreed in the contract. If the quantity or quality of the product is not in conformity with the contract, the entrusting party shall raise a written objection to the contractor within 15 days from the date of receiving the product, and shall not use the product, otherwise it shall be deemed that the quantity and quality of the product are in conformity with the contract. For quality defects that are difficult to find in short-term inspection, the contractor shall be responsible for returning the goods except those caused by improper use or storage by the entrusting party. If there are other problems, both parties should solve them through consultation.
12. Intellectual property rights: If the products ordered by the entrusting party involve intellectual property rights such as registered trademarks, design patents and copyrights. , the entrusting party shall provide the ownership or use license to the contractor. The entrusting party shall also provide the contractor with the power of attorney, a copy of business license (with official seal), barcode certificate, QS certificate, etc. The entrusting party shall be responsible for the authenticity and legality of all the information provided. If the client fails to provide or the information provided is untrue, the client shall bear all economic and legal responsibilities.
Thirteen. The contractor shall provide the client with a copy of business license (with official seal), QS certificate, a copy of printing license (with official seal) and a third-party inspection report.
14. exclusions: the delay or non-delivery of products caused by accidents such as force majeure, power failure and major equipment failure shall not be regarded as the contractor's breach of contract, but the contractor shall notify the entrusting party in writing within 12 hours after the above accidents, and the contractor is still obliged to take all necessary measures to deliver the products as soon as possible. If the force majeure lasts for more than one week, the entrusting party has the right to cancel this contract.
Fifteen. Liability for breach of contract:
1. If the contractor fails to deliver the crops according to the quality stipulated in the contract and the entrusting party agrees to use them, the price shall be determined according to the quality; If it does not agree to use it, it shall be responsible for replacing it and bear the responsibility for overdue delivery; If the replacement still does not meet the requirements of the contract, the entrusting party has the right to refuse, and the losses caused thereby shall be compensated by the contractor.
2. If the quantity of delivered crops or completed work is less than that stipulated in the contract, if the entrusting party still needs it, it shall make up according to the quantity, and the overdue delivery shall be handled according to the fourth paragraph of this article; If the underpaid part of the client is no longer needed, the client has the right to terminate the contract, and the losses caused thereby shall be compensated by the contractor.
3. If the crops are damaged or lost due to packaging problems, the contractor shall compensate for the losses.
4. If the delivery is overdue, the contractor shall bear 0.2% of the total contract price as liquidated damages for each day of delay (delivery of qualified products according to the agreed quantity shall be regarded as delivery); Without the consent of the entrusting party, the ordering party has the right to refuse to deliver the crops in advance.
5. If the crops cannot be delivered or the work cannot be completed, a penalty of 20% of the total contract price shall be paid.
If the client misses the best opportunity to sell products because the contractor's work schedule or product quality does not meet the contract requirements, causing losses to the client, the contractor shall not only refund all the money paid by the buyer in the early stage, but also bear the direct and indirect economic losses of the client according to the actual situation.
16. After the conclusion of this contract, both parties shall be bound by this contract for the order business increased by the entrusting party and confirmed by the undertaking party.
17. Matters not covered in this contract shall be handled in accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC).
18. Any dispute arising during the performance of the contract shall be settled by both parties through consultation. If negotiation fails, it shall be settled by the court with jurisdiction where the entrusting party is located.
19. This contract is made in duplicate, one for each party, and shall come into effect as of the date when both parties affix their seals. However, if the contract stipulates that there is an advance payment, it will take effect from the date of delivery of the advance payment.
The validity of this contract is from year to year.
contractor
client
Organization name
member as of right
Entrusted agent
Signing place: Signing time: