Model Ship Maintenance Contract 1 Party A: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ Company
According to the Contract Law of People's Republic of China (PRC) and relevant laws, Party A and Party B, through friendly negotiation, unanimously agree to sign this contract according to the following terms:
Article 1: Project Overview
1. Project name: _ _ _ _ _ _ _ _ _ _ _
2. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. Contracting method: quantity contracting (Party A recognizes quality and price).
Article 2: Construction Period, Contract Amount and Payment Method
1, and the term of this contract is _ _ _ _ _ _ days.
2. Total project cost: _ _ _ _ _ _ Yuan only, in words: _ _ _ _ _ _ _ _ _ _ _. After this contract comes into effect, Party A shall, within _ _ _ _ days after Party B's production and installation is completed, pay the full amount by cheque after Party A has passed the acceptance without deduction, and Party B has issued a valid invoice supervised by the tax bureau.
Article 3: Responsibilities and obligations of both parties
1. Party B must carry out the construction with good quality and quantity according to the design drawings and Party A's requirements. If the project quality does not meet the relevant regulations, Party B shall be responsible for free repair or rework, otherwise it will compensate Party A for all losses.
2. Party B must complete the project according to the time agreed by both parties. In case of force majeure, the construction period will be postponed. Otherwise, it will be regarded as breach of contract, and _ _ _% of the total project cost of Party A will be compensated as liquidated damages.
3. In case of quality problems during use, Party B shall be responsible for maintenance in time after receiving the notice from Party A. ..
Article 4: Liability for breach of contract
1. The materials purchased by Party B must ensure the quality and are qualified products that meet the design requirements. Otherwise, it shall be replaced free of charge in time according to Party A's requirements and compensate Party A for its losses.
2. Settlement of contract disputes: court prosecution.
This contract is made in quadruplicate, three for Party A and one for Party B, all of which are equally authentic. This contract shall come into force as of the date of signing.
Party A: _ _ _ _ _ _ _ Company
Party B: _ _ _ _ _ _ _ Company
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Mode 2 Ship maintenance contract signing place: signing time: 20xx year x month x day.
The entrusting party entrusts the ship repairer to undertake the ship engineering, and both parties reach an agreement through consultation and sign this contract, each party holds one copy.
Article 1 Scope of work: The repairer shall, according to the list of ship repair work put forward by the entrusting party, take it as the basis of the scope of ship repair work after being checked and signed by both parties.
Article 2 Add and subtract account items
1. The additional project shall be put forward by the entrusting party's representative to the contractor in writing within one quarter of the construction period after commencement, and confirmed by both parties. If the additional project cost does not exceed 10 of the total ship repair cost, and its single project does not affect the project construction period, the contractor can carry out repairs according to the conventional repair project. If the additional project cost exceeds 10 of the total ship repair cost, or the additional project is put forward by the entrusting party after a quarter of the start of the project period, and its single project will affect the project period, both parties can negotiate separately to determine the repair price and project period according to the specific situation, and sign a supplementary agreement.
2. The account reduction project shall be put forward by the entrusting party's representative to the contractor in writing and confirmed by both parties. If the contractor has incurred expenses for the account reduction project of the entrusting party, the expenses shall still be borne by the entrusting party.
Article 3 Project price: The repair cost of this ship does not include the items of adding and subtracting accounts, and it is estimated to be xx xx xx xx xx xx XX, and its final total price shall be settled according to the actual repair items after the ship is completed and delivered from the factory.
Article 4 Construction period: The ship is scheduled to enter the factory on xx, xx, xx, and the construction period is * * * days, of which the time spent at the dock row and slipway is xx days.
Article 5 Project acceptance
1. The entrusting party shall apply for the items that need to be submitted to the ship inspection bureau for inspection during the repair of this ship. If the single project is repaired or accepted, it shall be signed and accepted by the representative designated by the entrusting party. After the completion of all repair work or dock test, the representatives of both parties shall sign the general acceptance of ship repair completion as the basis for delivery.
2. The technical requirements and acceptance criteria of ship repair works shall be implemented according to the technical agreement signed by both parties. During the inspection and trial voyage, the Ship Inspection Bureau and the entrusting party put forward the defects and omissions in the repair items of the repairer, and the repairer should repair and complete them in time. If it is not within the scope of the contractor's repair project and needs to be repaired by the contractor, it can be treated as an additional project.
3. After the ship's dock test, sea trial and other related tests pass, the repairer shall provide relevant supporting documents and materials to the entrusting party within xx days.
Article 6 Quality Assurance
1. After the ship is repaired and accepted, the warranty period of the fixed parts repaired by the repairer is six months, and the warranty period of the moving parts is three months. During the warranty period, if the fault or defect is caused by the contractor's repair quality problem, the contractor shall repair it free of charge in time.
2. If faults, defects and losses are caused by quality problems or improper operation of accessories, spare parts and equipment provided by the entrusting party, the entrusting party shall be responsible.
Article 7 Engineering maintenance
1. Waste equipment, materials and other articles removed during ship repair and construction, except the stern shaft and propeller, shall be disposed of by the contractor. If the entrusting party needs old parts and equipment, the entrusting party shall submit it to the repairer in writing and obtain the consent before disassembly. After disassembly, it should be transported away in time.
2. During the repair of the ship in the factory, the entrusting party shall not hire people to repair the ship for related projects without the consent of the repairing party. The contractor shall support the self-repair work of the entrusting party's crew without affecting the contractor's construction. However, the entrusting party must notify the repairer in writing of the repair items and schedule of the ship.
Article 8 Payment of project funds
1. After this contract comes into effect, the entrusting party shall pay the contractor an advance payment of RMB xxxx million, accounting for 40% of the total repair cost. When the repair progress reaches half of the construction period, the entrusting party shall pay the balance of the total repair cost of 300,000 yuan to the contractor in one lump sum within xx days after completion. If the entrusting party makes overdue payment, it shall be handled in accordance with the relevant provisions of the People's Bank of China on overdue payment.
2. The repairer shall collect money from the entrusting party's bank on the basis of the statement. Article 9 When a ship repair project is completed ahead of schedule or overdue, both parties shall pay the other party the quick repair fee or delayed repair fee. The calculation method is as follows: for each day that the repairer finishes ahead of schedule, the entrusting party shall pay the repairer the quick repair fee according to xx of the total repair fee of the ship, but the maximum amount shall not exceed xx of the total repair fee. If the completion is delayed due to the contractor's reasons, the contractor shall pay the delay fee to the employer according to xx of the total repair cost for each day overdue, but the maximum amount shall not exceed xx of the total repair cost. The contractor shall automatically deduct the overdue repair fee from the bill and notify the entrusting party.
Article 10: Fire Safety Work During ship repair, the fire safety work must strictly implement the Regulations on Fire Prevention and Explosion Prevention for Ship Repair jointly issued by People's Republic of China (PRC), Ministry of Communications, Ministry of Public Security and China State Shipbuilding Corporation on May 25th.
Article 11 Settlement of Disputes During the execution of the contract, both parties shall settle disputes through consultation. If negotiation fails, it shall be submitted to China Maritime Arbitration Commission for arbitration in accordance with its arbitration rules in effect at the time of applying for arbitration. The arbitral award is final and binding on both parties.
Article 12 Others
1. For matters not covered in this contract, both parties may supplement the agreement separately, and the agreement has the same effect as the original contract.
2. This contract shall come into effect as of the date of signing.
3. The original of this contract is in duplicate, each party holds one copy and xx copies, one of which is sent to the contract management authority where the contractor is located for the record. Where both parties require the contract to be authenticated, they shall go through the authentication procedures at the contract management authority where the contractor is located.
Address of entrusting party, repairing party, unit name stamp and unit name stamp:
Legal representative:
Legal representative:
Entrusted agent:
Entrusted agent:
Tel: Tel:
Telegraph registration: telegraph registration:
Bank of deposit: Bank of deposit:
Account number: Account number:
Postal code:
Model 3 Ship Maintenance ContractNo.: _ _ _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ _
Customer: _ _ _ _ _ _ _ _ _ _ _
Contractor: _ _ _ _ _ _ _ _
Signing time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The entrusting party entrusts the ship repairer to undertake the ship engineering, and both parties reach an agreement through consultation and sign this contract, each party holds one copy.
Article 1 Scope of Work The repairer shall, according to the list of ship repair work put forward by the entrusting party, take it as the basis of the scope of ship repair work after being checked and signed by both parties.
Article 2 Add and subtract account items
1. The additional project shall be put forward by the entrusting party's representative to the contractor in writing within one quarter of the construction period after commencement, and confirmed by both parties. If the additional project cost does not exceed _ _ _ _ _ of the total ship repair cost, and the single project does not affect the construction period, the contractor can carry out the repair according to the conventional repair project. If the additional project cost exceeds _ _ _ _ _ of the total ship repair cost, or the additional project is proposed by the entrusting party after the first quarter of the project period, and its single project will affect the project period, both parties can negotiate separately to determine the repair price and project period according to the specific situation, and sign a supplementary agreement.
2. The account reduction project shall be put forward by the entrusting party's representative to the contractor in writing and confirmed by both parties. If the contractor has incurred expenses for the account reduction project of the entrusting party, the expenses shall still be borne by the entrusting party.
Article 3 Project price: excluding the repair fee of this ship. The project plan is RMB _ _ _ _ _ _ _ ten thousand yuan.
Article 4 Construction period: This ship is scheduled to enter the factory on _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 5 Project acceptance
1. The entrusting party shall apply for the items that need to be submitted to the ship inspection bureau for inspection during the repair of this ship. If the single project is repaired or accepted, it shall be signed and accepted by the representative designated by the entrusting party. After the completion of all repair work or dock test, the representatives of both parties shall sign the general acceptance of ship repair completion as the basis for delivery.
2. The technical requirements and acceptance criteria of ship repair works shall be implemented according to the technical agreement signed by both parties. During the inspection and trial voyage, the Ship Inspection Bureau and the entrusting party put forward the defects and omissions in the repair items of the repairer, and the repairer should repair and complete them in time. If it is not within the scope of the contractor's repair project and needs to be repaired by the contractor, it can be treated as an additional project.
3. After the ship's dock test, sea test and other related tests have passed, the repairer shall provide relevant supporting documents and materials to the entrusting party within _ _ _ _ _.
Article 6 Quality Assurance
1. After the ship is repaired and accepted, the warranty period of the fixed parts repaired by the repairer is six months, and the warranty period of the moving parts is three months. During the warranty period, if the fault or defect is caused by the contractor's repair quality problem, the contractor shall repair it free of charge in time.
2. If faults, defects and losses are caused by quality problems or improper operation of accessories, spare parts and equipment provided by the entrusting party, the entrusting party shall be responsible.
Article 7 Engineering maintenance
1. Waste equipment, materials and other articles removed during ship repair and construction, except the stern shaft and propeller, shall be disposed of by the contractor. If the entrusting party needs old parts and equipment, the entrusting party shall submit it to the repairer in writing and obtain the consent before disassembly. After disassembly, it should be transported away in time.
2. During the repair of the ship in the factory, the entrusting party shall not hire people to repair the ship for related projects without the consent of the repairing party. The contractor shall support the self-repair work of the entrusting party's crew without affecting the contractor's construction. However, the entrusting party must notify the repairer in writing of the repair items and schedule of the ship.
Article 8 Payment of project funds
1. After this contract comes into effect, the entrusting party shall pay RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. The repairer shall collect money from the entrusting party's bank on the basis of the statement.
Article 9 When the ship repair project is completed ahead of schedule or beyond schedule, both parties shall pay the other party the quick repair fee or the delayed repair fee. The calculation method is as follows: The entrusting party shall pay the repairer the quick repair fee according to the total repair fee of the ship every day ahead of schedule, but the maximum amount shall not exceed _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. If the completion is overdue due to the contractor's reasons, the contractor shall pay the employer a late fee of _ _ _ _ of the total repair fee for each day overdue, but the maximum amount shall not exceed _ _ _ _ of the total repair fee. The contractor shall automatically deduct the overdue repair fee from the bill and notify the entrusting party.
Article 10 Fire Safety Work The fire safety work during ship repair must strictly implement the Provisions on Fire Prevention and Explosion Prevention for Ship Repair jointly issued by People's Republic of China (PRC), Ministry of Communications, Ministry of Public Security and China Shipbuilding Corporation on May 25th.
Article 11 Settlement of Disputes During the execution of the contract, if there is any dispute between the two parties, it shall be settled through consultation. If negotiation fails, it shall be submitted to China Maritime Arbitration Commission for arbitration in accordance with its arbitration rules in effect at the time of applying for arbitration. The arbitral award is final and binding on both parties.
Article 12 Others
1. For matters not covered in this contract, both parties may supplement the agreement separately, and the agreement has the same effect as the original contract.
2. This contract shall come into effect as of the date of signing.
3. This contract is in duplicate, each party holds one copy, and _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Entrusting party: _ _ _ _ _ _ _ _ Undertaking party: _ _ _ _ _ _ _
Company name (seal): _ _ _ _ _ Company name (seal): _ _ _ _ _ _
Address: _ _ _ _ _ _ Address: _ _ _ _ _ _
Legal representative: _ _ _ _ _ _ _ _ Legal representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Authorized Agent: _ _ _ _ _ _ _ _ Authorized Agent: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Tel: _ _ _ _ _ Tel: _ _ _ _ _ _
Telegraph registration: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Bank of deposit: _ _ _ _ _ _ _ Bank of deposit: _ _ _ _ _ _ _
Account number: _ _ _ _ _ _ _ Account number: _ _ _ _ _ _ _ _
Postal Code: _ _ _ _ _ _ _ _ Postal Code: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Mode 4 Name of manufacturer of ship maintenance contract: _ _ _ _ _ (hereinafter referred to as manufacturer)
Place of registration: _ _ _ _ _ _ _
Name of agent: _ _ _ _ _ _ (hereinafter referred to as agent)
Place of registration: _ _ _ _ _ _ _
1. Appointment:
We hereby appoint _ _ _ _ _ _ _ _ _ as the sole agent for repairing and selling ships in _ _ _ _ _ _ _.
2. The responsibility of the agent:
(1) Seek the inquiry form of the shipowner who wants to buy and repair the ship from this area and notify the manufacturer;
(two) report the general situation of the comprehensive market in the region;
(3) Assist in arranging the business activities of factory dealers;
(4) Conduct regular market surveys on behalf of the shipyard;
(5) Assist manufacturers to collect payment (legal means shall not be used without permission);
(6) Report the business situation in this area to the manufacturer in an agreed way.
3. Scope:
In order to facilitate the work, the manufacturer shall provide the agent with a list of owners in the agency area, and the agent shall comment on the list and put forward suggestions or amendments for the manufacturer's reference;
If there is a dispute between regions due to the commission charged by individual ships, the manufacturer will be the sole arbitrator, and it will give fair and reasonable remuneration according to all the circumstances.
4. Commission:
The manufacturer pays _ _ _ _ _ _ _ _ _ _ _ _ _ _
When the manufacturer needs to pay the commission to the owner's broker and the third party introducer, the agent must say hello in advance; At the same time, the manufacturer decides whether to pay.
5. Cost:
Except for the following cases, the remaining expenses shall be borne by the agent.
(1) Fees for visiting the manufacturer within the time specified by the manufacturer;
(2) Communication expenses under special circumstances (long telex, various instructions, etc.). );
(3) The expenses incurred by the manufacturer in the sales visit to this area.
6. Manufacturer's responsibilities:
The manufacturer shall:
(1) Provide sales promotional materials such as product samples to agents;
(2) Provide the agent with the delivery list of important customers, so that they can know fairly well;
(3) Inform the agent to directly contact the relevant shipowners in this area;
(4) Provide the agent with copies of all major documents exchanged with the owner, and ask the agent not to disclose business secrets.
7. Terms of reference:
The agent has no right to interfere with the manufacturer in terms of price, time, specifications or other contract conditions; The decision to undertake its business belongs to the manufacturer.
8. Conflicts of interest:
It is hereby declared that during the validity of this agreement, the agent shall not harm the interests of the manufacturer as a representative of other shipyards. The agent agrees to consult the manufacturer before signing other agency contracts; The agent guarantees that without the permission of the manufacturer, he shall not disclose information that is harmful to the commercial interests of the manufacturer to a third party.
Sales contract, office furniture sales contract, seedling sales contract, electronic product sales contract, real estate sales agency contract, building materials sales contract, mobile phone sales agency contract model text, furniture store joining contract agreement format example 9. Termination:
This agreement will be terminated three months after either party gives a written notice; During the performance of the agreement, the commission of the ships undertaken by the agent will still be paid, regardless of whether these ships are repaired in the factory during this period.
10, leakage:
During or after the execution of the agreement, the agent guarantees that it will not disclose any information classified as confidential by the manufacturer to any party without the prior consent of the manufacturer.
1 1. Arbitration:
Except as stated in Article 3, any dispute arising from this Agreement and its interpretation or any dispute that cannot be satisfactorily resolved through the efforts of both parties shall be submitted to arbitrators confirmed by both parties for arbitration. If no agreement can be reached on the arbitrator, the arbitrator shall be temporarily appointed by the president of _ _ _ _ _ _ _.
Agent (signature): _ _ _ _ _ _
Manufacturer (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _
Signing place: _ _ _ _ _ _
Model ship maintenance contract 5 Party A (customer): Party B (customer):
Mailing address (postal code): Mailing address (postal code):
Contact: E-mail: Contact:
Telephone: fax: telephone: fax:
Please fill in the contact information in detail so that we can convey the latest service information and preferential activities to you in time!
Xx Equipment Center is a large-scale formal service provider integrating wholesale and retail of office equipment, maintenance and consumables supply. In order to make your work progress more smoothly and conveniently, we provide you with effective logistics support. Our commitment: to serve you wholeheartedly and bring you the best quality, fastest and most satisfactory service.
I. Determination before signing the contract by both parties
Before signing the contract, both parties shall confirm the status of the equipment to be repaired/maintained and register it. Party B shall check the integrity of the main components and accessories of the warranty equipment, register the machine model, overall condition and other relevant information, and establish customer files.
Two. Rights and obligations of Party A
1. Party A shall promptly notify Party B of the failure of the office equipment included in this agreement, and truthfully inform Party B of the failure, so as to assist Party B's maintenance personnel to make a correct judgment.
2. When Party A decides to repair the faulty machine, Party A shall bear the cost of replacing the parts. The quotation provided by Party B is for Party A's reference and confirmation, and the price of parts in the quotation shall not be higher than the price of parts provided by the equipment manufacturer in the authorized maintenance center in this city.
3. Party B shall not be responsible for the damage of machines and accessories caused by Party A's unauthorized maintenance or purchase of non-original consumables and accessories from other units. Party B shall not be responsible for the damage to the machine and accessories caused by Party A's insistence on using the worn parts that should be replaced.
4. Without the consent of Party B, Party A shall not replace or hire a third party to replace or disassemble machine parts. Once Party B is found, Party A has the right to terminate the contract unconditionally.
5. During the warranty period of the original factory (including the extended warranty service purchased from the original factory), Party A can carry out maintenance according to the provisions in the original factory warranty card.
6. If Party A needs Party B to provide other technical support (such as equipment installation, use and simple maintenance, basic knowledge training, assisting the relocation, installation and debugging of equipment in this city, etc.). ), Party A shall notify Party B 2 days in advance.
Three. Rights and obligations of Party B
1. During the execution of the contract, Party B shall be responsible for providing free maintenance for the machines used under normal conditions.
2. During the execution of the contract, except for national statutory holidays, Party B guarantees that the service will be in place within hours after receiving the maintenance notice from Party A (unlimited times).
3. When Party B receives Party A's maintenance notice and confirms that the machine needs to be replaced, it will take back the faulty machine for maintenance without affecting Party A's normal work. Under special circumstances, Party B will provide Party A with a spare machine.
4. Party B has the obligation to explain each maintenance to Party A and provide a list of replacement parts, and the price of parts shall not be higher than the price provided by the equipment manufacturer in the authorized maintenance center in this city.
5. During the execution of the contract, after Party B replaces the new parts for Party A's machine, the new parts appear again, which belongs to the quality problem of the parts themselves, and Party B is responsible for the free maintenance and replacement; If the accessories are damaged (non-accessory quality problems) due to improper use by Party A, Party A shall be responsible.
6. After the maintenance (replacement of parts) is completed, Party B's maintenance personnel shall provide a written report to Party A, and both parties shall sign to confirm that the fault has been repaired.
7. During the execution of the contract, Party B can provide Party A with technical support and necessary extension services (such as equipment installation, use and simple maintenance, basic knowledge training, assistance in long-distance relocation, installation and debugging of equipment in this city, etc.). ) In addition to the manufacturer's standard warranty service for newly purchased office equipment (photocopiers, printers, fax machines, all-in-one machines, etc.). ).
Four. Payment and payment methods
Annual maintenance payment category:
□ Class A: Party B shall comprehensively maintain Party A's office equipment once a month, and the annual service fee is RMB (in words: RMB only).
□ Class B: When Party A's office equipment breaks down or needs maintenance, Party B will provide unlimited on-site service, and the annual service fee is RMB Yuan only.
Payment method: one-time payment within one week from the date of signing the contract, and cash check is accepted.
Verb (abbreviation for verb) dispute settlement
This contract shall come into force after being signed and sealed by both parties and shall be binding on both parties. If one party fails to perform the contract, the other party may bring a lawsuit directly to the local court.
Termination and breach of contract with intransitive verbs
1. This contract will be automatically terminated upon expiration. If Party A needs Party B to continue the service, it shall renew the contract within one month after the expiration of this contract.
2. breach of contract. Party A informs Party B to go for maintenance. If Party B fails to perform maintenance on schedule for more than three times without reason, Party A has the right to terminate the contract and may require Party B to return the remaining contract money. (Refund of contract money = x months of non-service).
7. This contract shall come into force as of the date of signature and seal by both parties.
This contract is made in duplicate, each party holds one copy, which has the same effect. Matters not covered in this contract shall be settled by both parties through consultation based on the principle of reasonableness and fairness.
Eight. Supplementary terms:
IX. Schedule:
Machine model
Number of copies
Reserve bill
Contract execution period: to
Party A: (Seal) Party B:
Signature of person in charge: signature of person in charge:
Date: Date: