Company Engineering Labor Contract Template General Edition 1 ContractNo.: _ _ _ _ _ _ _
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, Party A subcontracts part of the _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ ... In order to clarify the rights and obligations of both parties, on the basis of fairness and reasonableness, the following terms are reached through negotiation between both parties.
Article 1 Contract documents
As an annex to this agreement, the following documents together with this agreement constitute contract documents, which have the same effect as this agreement:
1. Technical specifications, technical disclosure, work instructions and drawings of this project;
2. Engineering quality inspection and acceptance criteria;
3. Project construction safety standards;
4. Project construction organization design;
5. Project construction schedule (including node plan);
7. Documents of the owner, supervisor and Party A;
8. Supplementary agreements, meeting minutes and commitments of both parties.
Article 2 Contract Unit Price
See (attachment) for details, and there is no price adjustment.
Article 3 Related Agreements
1. Party B shall be responsible for Party A, acknowledge and strictly abide by the quality, safety, technology, environmental protection and civilized construction standards signed by Party A and the owner, and complete the construction within the construction schedule (including node plan) issued by Party A. ..
2. Measurement and payment
2. 1 After Party B completes the contracted project, Party A shall measure and pay according to the quantity of qualified projects completed by Party B and the unit price in the bill of quantities (attachment 1).
2.2 Party B shall organize the construction according to Party A's construction plan. If the construction plan cannot be completed due to Party B's reasons, Party A has the right to ask Party B for delay compensation (compensation = _ _ _ _ ‰× target amount× delay days) ... The maximum reward is _ _% of the total task amount. Meanwhile, Party A has the right to terminate this contract.
2.3 This project does not pay the advance payment, and Party B has the ability to advance the funds before the settlement payment.
3. Supply of engineering materials
3. 1 All the main materials required shall be the responsibility of Party B, and can only be used after being inspected by Party A. ..
3.2 Party B shall not lodge a claim against Party A because the materials cannot arrive in time due to irresistible external forces such as road congestion and natural disasters.
4. Technical work such as measurement, test and inspection.
4. 1 Party A shall make technical disclosure and measurement in written form at any time as required.
4.2 Party A shall be responsible for the engineering test and inspection, and Party B shall cooperate with Party A's laboratory inspection under the supervision of Party A. ..
5. Party B shall not subcontract. Otherwise, Party A has the right to terminate the contract. The losses caused thereby shall be borne by Party B, and _ _ _% of the total contract price shall be paid to Party A as liquidated damages.
6. The next working procedure can only be carried out after the concealed works are accepted by Party A and the supervisor.
7. The unit price contracted by Party A to Party B includes all the costs of project construction. As an economic entity, Party B shall fulfill all social obligations stipulated by the state (labor, medical care, industrial injury insurance, taxes, etc.). ).
8. According to the Labor Law, Party B shall pay the employee's labor remuneration in full and on time (not lower than the minimum wage standard published by the local government). Party A has the right to supervise, and if necessary, Party A has the right to pay (directly pay the salary to Party B's employees).
9. The unit price contracted by Party A to Party B includes Party B's industrial injury insurance and third-party liability insurance. Therefore, Party B's work-related accident expenses and related expenses shall all be borne by Party B. ..
10. The change of the person in charge of on-site construction and the technical person in charge of Party B shall be approved by Party A, and the leave formalities shall be handled with Party A when leaving the site.
1 1. The workload (calculated by the number of entities) completed by Party B shall come into effect after being signed by the entrusted representative of Party A. The project payment shall be signed by the heads of Party A's technology, safety, materials, contracts and finance departments, and paid after being approved by Party A's team leader.
12. Party A has the right to evaluate Party B's performance ability. If Party B fails to perform the contract (especially in terms of quality, construction period and safety), Party A has the right to terminate the contract and claim losses from Party B according to% of the total amount of the contract subject matter.
13. After signing this contract, Party B's personnel and equipment must enter the construction site as promised. Otherwise, Party A has the right to terminate the contract or impose corresponding penalties on Party B's breach of contract (the penalty standard is determined by Party A according to the degree of Party B's breach of contract, and the penalty limit is _ _% of Party B's total task.
14. Party B shall be responsible for the safety of this project, equip with necessary safety protection facilities, abide by the national laws, administrative regulations and operating rules related to safety production, and obey the safety supervision and management of Party A. Party B shall bear all responsibilities for personal injuries and mechanical accidents caused by whatever reasons, and Party A shall not bear any responsibilities.
15. Party B must carry out on-site civilized construction and environmental protection, including all related operations such as dust prevention and noise reduction, and be equipped with various signs and signs that meet the requirements of engineering construction.
16. Party B shall take measures to actively cooperate with the owner or supervision engineer of Party A for regular or irregular inspection and assessment. If Party A is punished in the inspection and appraisal by the owner or supervision engineer or the appraisal result of Party A is affected due to Party B, Party A will impose a double fine or punish Party B according to the appraisal result. In case of any incident that seriously affects Party A's reputation due to Party B's reasons, Party A has the right to terminate Party B's contract.
Article 4 Dispute settlement
In case of any dispute during the performance of this contract, both parties agree to settle it in the following ways:
1. Reconciliation. On the basis of voluntariness and friendship, the two sides communicate with each other, understand each other and settle through consultation;
2. Mediation. Under the auspices of the third party, through the persuasion, guidance and mediation of the third party, the dispute is resolved and an agreement is reached;
3. arbitration. If negotiation or mediation fails, it shall be submitted to the Municipal Arbitration Commission for arbitration.
Article 5 Supplementary Provisions
1. Matters not covered in this contract need to be signed by both parties through negotiation, and the supplementary agreement has the same legal effect as this contract.
2. This contract shall come into effect after being signed and sealed by both parties, and shall naturally become invalid after the project is completed, the final payment of the project is settled and the warranty period expires.
3. This contract is made in two originals, one for each party1; 2 copies, 2 copies for Party A. ..
Party A: _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Representative: _ _ _ _ _ _ _ Representative: _ _ _ _ _ _ _ _
Tel: _ _ _ _ _ _ Tel: _ _ _ _ _ _ _ _
Time of contract conclusion: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _
Party B (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _
Risk notification: The contractor and the labor subcontractor should strictly sign the labor subcontracting contract, so as to avoid the construction enterprise's difficulty in safeguarding its own rights and interests because it has not signed the labor subcontracting contract or the contract is not clear. The legal operation of labor subcontractors must include two forms: one is to establish labor subcontracting contract relationship with construction enterprises with labor qualifications, that is, labor subcontractors (general contracting enterprises or professional contracting enterprises); The second is to sign a labor contract with each worker of a number of natural persons who have received pre-job training in a specific field.
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the use of engineering services in this project and signed this contract.
Article 1. General situation of the project
This project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 2. Signing method and requirements
This project is contracted by Party A to Party B in the form of tax, labor and accommodation by combining the division of labor and unit price into the total price. The contracting team is required to have the qualification of labor contract, and the main types of work should have the certificate of appointment, and the roster of personnel should be compiled and submitted to Party A for filing for future reference.
Article 3, the project contract unit price and content
Through negotiation between both parties, Party B will contract the _ _ _ _ _ _ _ _ _ _ _ _ _ _ project to Party A at the contract unit price of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Horizontal ground transportation within 200 meters; Maintenance of production equipment; Save materials; Cooperate with other teams and so on.
Article 4, the construction period
Employment start date is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 5, civilized construction, standardized management
Party B must meet the requirements of _ _ _ _ class civilized construction site at the construction site; Must meet the requirements of _ _ _ _ class standard of chemical industry.
Article 6. Project Quality and Safety
According to the requirements of the owner, the project quality is required to be excellent, so the single contract must be guaranteed to be excellent. If the project quality is assessed as excellent, Party A will give appropriate rewards. If a single contract is assessed as unqualified, Party B will rework and repair it until it is qualified. All economic losses caused by rework shall be borne by Party B and deducted from Party B's labor settlement.
Party B's construction personnel must obey the arrangement of Party A's management personnel and strictly abide by the safety operation rules. In order to enhance workers' safety awareness, the team leader and the team leader should arrange the workload every day, conduct safety disclosure education, emphasize safe operation, wear safety helmets, install safety nets, fasten safety belts, and do all kinds of safety protection work to prevent safety accidents. All safety accidents caused by Party B shall be borne by Party B, and Party A shall not bear any economic and legal responsibilities.
Article 7. terms of payment
After Party B's team enters the site, Party B shall be responsible for the upfront expenses. Party A will lend Party B a certain amount of living expenses according to the progress of the project, with _ _ _% of the service fee as the upper limit. After the completion of the project, pay _ _ _ _% of the service fee. After the project is settled, 10% is reserved for the expiration of the warranty period. Due to the tight construction period of this project and strict rewards and punishments of the owner, in order to ensure that the project is completed according to the construction period, Party B must pay a time limit deposit of RMB _ _ _ _ _ _ _. At the construction site, Party B must carefully organize the construction according to the time limit control points determined by Party A to ensure the realization of the time limit objectives. If the construction period is delayed due to Party B's reasons. In addition to deducting the time limit deposit, it will also be punished according to the contract signed between Party A and the owner.
Article 8. Responsibility of both parties
(I) Party A's responsibilities
1. Prepare the construction organization design and construction scheme, conduct on-site disclosure, construction disclosure and three-level safety education for Party B, and provide construction drawings.
2. Provide temporary construction facilities, water and electricity supply, and provide accommodation for Party B's personnel.
3. Handle temporary residence permits, badges and other relevant certificates for Party B's personnel.
(II) Party B's responsibilities
1. Party B must obtain the approval of Party A before entering the site. Party B must submit or handle relevant certificates (copy of ID card, temporary residence permit, work permit, employment permit, etc.) before entering the site. ) to ensure the authenticity and validity of the documents provided.
2. Before Party B enters the site, it shall determine its responsible person and sign a power of attorney to authorize its responsible person to settle accounts, receive wages and handle related affairs on its behalf.
3. Ensure the authenticity of all information provided to Party A, prohibit fraud and maintain the normal operation and management order of the company.
4. Organize the construction in strict accordance with Party A's construction organization design, disclosure and scheme, and obtain Party A's written consent when making changes, otherwise Party A has the right to refuse to accept and settle the salary.
5. Party B's personnel must wear badges when entering or leaving the site and living quarters, and shall not bring irrelevant personnel in or out of the site and living quarters, and shall not enter the construction site after working hours.
6. Party B shall organize the construction in strict accordance with the monthly node schedule approved by Party A to ensure the project progress. If Party B fails to complete the plan on schedule, Party A may take corresponding measures to ensure the progress, and the expenses incurred therefrom shall be borne by Party B. If Party B fails to complete the plan for two consecutive months, Party A may unilaterally terminate this contract, and the losses incurred therefrom shall be borne by Party B. ..
7. In the process of construction, Party B's personnel must obey the management and command of Party A, enhance self-management awareness, and achieve safe and civilized construction.
8. Before entering the site, Party B must truthfully inform Party A of its health status, including whether there are any diseases that affect the construction of this type of work and the health of others, such as disability and infectious diseases. If a safety accident is caused by Party B's disability, all consequences shall be borne by Party B; After entering the site, if Party A finds that the health condition of Party B's personnel is not suitable for site construction, it must leave the site unconditionally.
9. Party B must abide by Party A's labor and employment management system, and Party A has the right to dismiss if it does not meet Party A's requirements.
10, the construction shall be organized in strict accordance with the construction technology, and the next working procedure shall not be carried out without the acceptance of Party A. ..
1 1. If there is any objection to Party A's requirements, it can be settled through negotiation.
According to the relevant spirit of People's Republic of China (PRC) Contract Law and Regulations on Construction Project Contracting, Party A agrees to contract out the engineering services of this project to Party B through negotiation between Party A and Party B. In order to clarify the rights and obligations of both parties, the following terms of the agreement are hereby signed for both parties to abide by.
I. Name and location of the project
The project is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Second, the contracting methods and requirements
This project is contracted by Party A to Party B in the form of tax, labor and accommodation by combining the division of labor and unit price into the total price. The contracting team is required to have the qualification of labor contract, and the main types of work should have the certificate of appointment, and the roster of personnel should be compiled and submitted to Party A for filing for future reference.
Third, the project contract unit price and content
The model labor contract is determined by both parties through negotiation, and the unit price of this contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Before Party A makes payment, Party B shall provide Party A with the corresponding invoice in advance.
Fourth, the project quality and safety
According to Party A's requirements, the project quality is excellent, and the single contract must be guaranteed to be excellent. If a single contract is judged unqualified, Party B will rework it until it is qualified, and all economic losses caused by rework shall be borne by Party B and deducted from Party B's labor settlement.
Party B's construction personnel must obey the arrangement of Party A's management personnel and strictly abide by the safety operation rules. In order to enhance workers' safety awareness, the team leader and the team leader should arrange the workload every day, conduct safety disclosure education, emphasize safe operation, wear safety helmets, install safety nets, fasten safety belts, and do all kinds of safety protection work to prevent safety accidents. All safety accidents caused by Party B shall be borne by Party B, and Party A shall not bear any economic and legal responsibilities.
Five, civilized construction and rewards and punishment
Party B's personnel entering the construction site must abide by the civilized construction manual, clean up the site and materials within their contracted scope after work, and strictly save materials. Sawing, littering or wasting materials are not allowed. If found, a fine will be imposed after the responsibility is clarified. At the same time, Party B strictly abides by the regulations on public security management, and offenders will be fined. Party B's personnel must obey the command of the management personnel and abide by all the rules and regulations of the construction site.
The payment method and time limit of intransitive verbs
All the project prices of the labor cost of this project have been included, and no other projects will be set up. If yes, it shall be determined on the spot according to the actual situation. After Party B's team enters the site, Party B shall be responsible for the upfront expenses, and pay _ _ _ _ _ _% service fee before the project starts, _ _ _ _ _ _% service fee after the project ends and _ _ _ _ _ _% service fee after the project is settled.
The construction period of Party B is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Seven. Rights and obligations of both parties
(1) Party A
1. Party A has the right to examine Party B's qualifications and to punish, compensate financially and dismiss Party B who violates the terms of this contract.
2. Party A arranges Party B to implement the project contract according to the project requirements, and Party B shall unconditionally abide by it.
3. Party A shall provide Party B with convenient construction conditions as far as possible, and pay the labor fee according to the labor contract and the owner's payment.
4. Party A shall implement the real-name registration system for the construction personnel provided by Party B, establish health status files, repel all disabled and mentally retarded personnel, and shall not enter the construction site.
(II) Party B
1. Party B must submit the contract qualification to Party A, and has the right to put forward legal requirements to Party A, and take the initiative to undertake all the work of the contract content to ensure the project quality.
2. Party B must carry out safety production according to the requirements of Party A, and shall not violate the safety operation rules without authorization. In case of personal injury or death in violation of safety operation regulations, Party B must take full responsibility, and Party A will not take any responsibility.
3. Party B has the right to reject Party A's instructions that do not meet the requirements of safe production, and put forward its own opinions for Party A's reference.
4. Party B shall not use disabled and mentally retarded workers, and shall not conceal or use them privately. At the same time, Party B shall provide the personnel list and ID card.
5. Party B shall take good care of his team and shall not engage in illegal and criminal activities such as gambling, prostitution and whoring. , inside and outside the website. Party A is not responsible for the consequences of the crime.
6. In order to ensure the construction period, Party B must ensure that there is enough labor force in this project according to the requirements of Party A, and shall not go slow.
Eight. Liability for breach of contract and others
1. Both parties must strictly abide by the above terms. If either party breaches the contract or causes the project to stop working, the responsibility of the breaching party must be investigated.
2. If the company's reputation, on-site equipment and certain economic losses are caused to the project due to Party B's reasons, Party A has the right to require Party B to compensate all the losses and deduct them from the contracted labor fee.
3. Party B must take good care of the equipment, tools and utensils belonging to Party B, and shall not put forward other requirements to Party A, let alone make excuses to affect the quality and progress of the trip, and the losses caused thereby shall be borne by Party B. ..
4. This contract is made in triplicate, two for Party A and one for Party B, which shall come into effect after being signed by both parties and have the same legal effect.
Any dispute arising from this contract shall be settled by both parties through consultation. If no settlement can be reached, it shall be submitted to the people's court for jurisdiction.
Party A: _ _ _ _ _ _ _ _ _ _ _
Person in charge: _ _ _ _ _ _ _ _ _ _ _
Authorized representative: _ _ _ _ _ _ _ _ _ _
Date of signing this contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ \
Party B: _ _ _ _ _ _ _ _ _ _ _
Person in charge: _ _ _ _ _ _ _ _ _ _ _
Authorized representative: _ _ _ _ _ _ _ _ _ _
Date of Contract Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Company Engineering Labor Contract Model General Edition IV Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, mutual benefit, fairness, honesty and credit, the two parties reached an agreement on the construction labor contract of this project and concluded this contract.
I. Overview of the Project
1. Name: _ _ _ _ _ _ _
2. Project content: _ _ _ _ _ _ _ _
3. Engineering quantity: The engineering quantity shall be settled according to the actual engineering quantity.
Second, the contract period
1. Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
2. Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. During the construction process, in case of losses and delays caused by irresistible natural disasters, Party A shall implement them to Party B in accordance with the relevant regulations of the construction unit to Party A.. ..
4. In the course of construction, if Party B fails to arrange the construction according to the relevant construction schedule of Party A and the constructor, and the constructor fines Party A for the delay in the construction period, Party A has the right to divide the project contracted by Party B and impose a fine of twice.
Third, the quality of labor services.
1. Party B must carry out the construction according to the design documents, the current technical specifications of the state and relevant departments and the requirements of the construction unit.
2. Party B must obey the supervision and quality management of Party A's field personnel.
3. All engineering quality qualified rate _ _ _ _ _ _%
4. If the project quality is unqualified due to Party B's failure to meet the above standards, Party A will not accept it and has the right to order rework. All expenses will be borne by Party B until the quality requirements are met. All rework costs and liabilities for breach of contract shall be borne by Party B, and the construction period shall not be postponed.
Four, safety construction and inspection
1. Party B must formulate safety measures and carry out construction in strict accordance with relevant safety operation regulations and standards to ensure construction safety.
2. Party B shall abide by the regulations on safety production in engineering construction, obey the command and safety management of on-site safety management personnel, accept the supervision and inspection carried out by industry safety inspectors according to law at any time, and take necessary safety protection measures to eliminate hidden dangers of accidents.
3. In the process of construction, if Party B violates the safety operation regulations, or causes personal injury, other safety accidents and third-party liability accidents due to Party B, all responsibilities and expenses shall be borne by Party B. ..
Verb (abbreviation of verb) security protection
1. In the construction of power equipment, transmission lines, underground pipelines, inflammable and explosive areas, facing the street or crossing traffic arteries, Party B shall take practical safety protection measures according to regulations.
2. Party B shall put forward the use plan for the safety protection articles (such as safety helmet, safety belt and safety rope) used by Party B at the construction site, and Party A shall be responsible for the supply and the expenses shall be borne by Party B. ..
Material supply of intransitive verbs
1. Main materials (including steel, cement, cement concrete, etc. ) provided by Party A, other materials shall be purchased, transported and kept by Party B, and the damage and loss shall be borne by Party B. ..
2. If the labor contract requires other materials, Party B shall purchase them by itself, and all materials must meet the design standards and quality requirements, and submit the material certificate (original) to Party A, otherwise Party B shall bear all the responsibilities and expenses for the adverse consequences caused thereby.
Seven, design change, concealed engineering
In case of design change or concealed engineering construction, if the design drawings are inconsistent with the site geology, Party B shall report to Party A in time, and construction shall not be carried out without consent. The inspection of concealed works shall be notified to the quality inspection engineer of Party A 24 hours in advance. Without the signature of Party A's quality inspection engineer, concealed engineering construction shall not be carried out, otherwise the expenses for rework, inspection and rework shall be borne by Party B. ..
Eight, the payment of labor costs
1. There is no advance payment for this project, and the first month's project payment shall be paid by the labor party.
2. The project inspection pricing and project progress payment:
(1) Work inspection and valuation: the relevant responsible persons of both parties shall conduct on-site acceptance of the completed projects within the scope of design drawings, and the qualified ones shall be accepted and measured. At the end of each month, Party B shall submit the engineering quantity, which shall be reviewed by the Engineering Quality Inspection Department of Party A, and the contract department shall carry out the work inspection and valuation according to the review data and the agreed unit price, and the work inspection and valuation shall be established after being signed by the person in charge of Party A. ..
(2) Payment of progress payment: After the monthly work inspection valuation is established, Party A will deduct the material advance payment and other expenses agreed in other agreements from the work inspection valuation, and detain 20% of the total work inspection valuation as the project quality deposit, and the remaining amount is the progress payment payable.
(3) If the construction unit is in arrears and temporarily unable to pay the project funds due to various factors, Party A and Party B shall jointly bear the risks.
Nine. Party A's responsibilities (responsibilities undertaken through negotiation)
1. Responsible for construction drawing review, technical disclosure and site delivery.
2. Be responsible for all the command and coordination of the construction site, formulate the construction technology, construction technology, safety and quality standards and measures, and supervise the implementation of Party B..
3. Be responsible for the regular implementation of recheck survey, and the daily construction survey shall be determined by both parties through consultation.
4. Responsible for engineering quantity calculation and technical disclosure of design changes. All design changes shall be notified to Party B in written form as the basis for increasing or decreasing the quantities and the project price, and any oral changes shall be invalid.
5. Party A shall strengthen the site management, be responsible for the inspection, acceptance and visa agency of the project progress, quality and concealed works, and handle the construction matters that should be handled by Party A. ..
6. Assist Party B in accident rescue.
7. Pay the project business tax on time.
X. Party B's responsibilities (responsibilities undertaken through negotiation)
1. Party B must bear Party A's obligations and contracting risks to the construction unit.
2. Party B must pay the wages of migrant workers on time, and shall not delay or deduct the wages of migrant workers. Otherwise, Party A has the right to impose economic penalties until the Contract is terminated.
3. If Party B causes any reputational impact on Party A, it shall actively recover the impact, otherwise Party A will be fined _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
4. Party B shall manage its own employees well, and often carry out folk education, and shall not have disputes with the outside world to affect the normal construction; Otherwise, the consequences are at your own risk.
5. Party B shall do a good job in labor management, properly keep and reasonably use the machines and tools, turnover materials and other facilities provided or leased by Party A to Party B. ..
6. Party B shall not subcontract or subcontract the construction tasks. Any dispute between Party B and any third party has nothing to do with Party A, and Party B shall be responsible for solving it.
7. Accept the adjustment of Party A's work arrangement and workload unconditionally.
XI。 Contract dispute settlement agreement
Any dispute arising from this contract shall be settled by both parties through consultation. If negotiation fails, the dispute settlement institution shall be the people's court where Party A is located.
Twelve. others
1. This contract shall come into effect as of the date of signature and seal by both parties.
2. If there is any imperfection in the execution of this contract, both parties shall sign a supplementary contract through negotiation, which shall be a supplement to this contract and have the same effect as this contract.
3. The original of this contract is in duplicate, with each party holding one copy.
Party A (official seal): _ _ _ _ _ Supplier (official seal): _ _ _ _ _ _
Address: _ _ _ _ _ _ Address: _ _ _ _ _ _
Tel: _ _ _ _ _ Tel: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Signature time: _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _