When signing a construction contract, we must abide by national laws and conform to national policies. Try to write short sentences. Simplicity is beauty. Short sentences are easier to understand and less ambiguous than long sentences. Whether you are looking for or preparing to write an "advertising project construction contract agreement", I have collected relevant materials below for your reference!
Advertising project construction contract agreement 1
Party A:
Party B:
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law and the current relevant regulations, Party A and Party B, on the premise of equality, mutual benefit and voluntary cooperation, have agreed to contract out the road project of Wangjiawan residential area to Party B in the form of a single package. In order to ensure the interests of both parties, both parties have reached the following agreement:
I. Project management:
Party B is a professional worker to which Party A belongs, and the daily work of all workers is carried out under the unified management of the company. In order to speed up the progress of the project, ensure the quality of the project, and give full play to the management role of professional types of work, Party B accepts the inspection and supervision of Party A within the scope stipulated in the contract and agreement, and everything must be subject to the unified management of Party A (the project management system is attached).
Second, the basic situation of the project
Project Name: Road Project of Residential Quarter
Construction site: _ _ residential area
Third, the contract form:
In order to ensure the common interests of both parties, Party B contracts all the contents of this contract, and Party B shall meet the requirements of quality and progress as required by Party A..
Four, the specific content of project contracting:
1, road engineering leveling and rolling;
2. According to the design width of road engineering, macadam base 10㎝, c30 concrete surface 20 ㎝;
3. Earthwork excavation of roadside rainwater pipes, sewage pipes and inspection wells;
4, manhole every 12 meters masonry a rainwater manhole and a sewage manhole;
5. Install roadside rainwater pipes dn300, sewage pipes dn400 and precast reinforced concrete pipes;
6. Party B is responsible for the post-construction maintenance of the road, and Party A is responsible for the expansion and excavation of the road;
7. The sidewalk is flat (excluding cushion and brick);
8. If other matters not covered actually occur, Party A and Party B shall settle them through negotiation.
5. Project price: 406,000.00 yuan (four hundred and sixty-six thousand yuan only).
Sixth, the construction period
After signing the construction agreement with Party A, Party B shall organize the construction in strict accordance with the construction period of Party A, and organize capable construction personnel and management personnel to ensure that the project is completed on time. If Party B fails to complete the project as required by Party A, all economic losses and consequences caused thereby shall be borne by Party B. ..
The proposed commencement time is: according to the requirements of the project department.
The planned completion time is: stipulated by the project department.
Seven. Project quality
1, the quality grade of this project is qualified.
2. Party B shall carefully organize the construction, carefully manage and take strict quality control measures to ensure the engineering quality level stipulated in the contract. Party A has the right to check the quality of the project at any time, put forward rectification opinions on the parts that do not meet the quality standards, and impose economic penalties on Party B when necessary. Party B shall actively cooperate. If the quality of the project continues to fail to meet the standard and reaches the quality level after rectification, Party A has the right to withdraw the contracting right, and all economic losses and consequences caused thereby shall be borne by Party B..
Eight, construction safety
Party B shall carry out the construction in strict accordance with the safety operation regulations, and sign a special safety contract with Party A for implementation. Party B must carry out safety education and construction safety disclosure for all workers on duty to prevent all safety accidents. If Party B neglects safety management and does not listen to Party A's safety management, resulting in safety accidents, all economic and legal responsibilities shall be borne by Party B, and Party A shall not be held responsible. Party A is responsible for providing safety supplies for Party B's construction personnel (the safety contract is attached). Including safety helmet (expenses shall be borne by Party B)
Nine, civilized construction management
Civilized construction management is a symbol of a company's comprehensive management ability. The quality of civilized construction management directly affects the company's image. Party B shall conduct management in accordance with the relevant regulations on civilized construction, ensure that the construction site is clean and tidy, and ensure that the civilized model site is reached.
X. Family planning management
Party B must carry out family planning management for the construction personnel in accordance with the relevant regulations of the State on family planning management. All construction personnel must hold the family planning certificate of floating population from the local family planning department, and those who do not meet the family planning regulations shall not use it, and shall be inspected by the relevant departments. If Party B fails to use the personnel without family planning certificate as required, all economic losses caused thereby shall be borne by Party B. ..
XI。 Public safety management
Party B must educate the constructors about public security, check their ID cards and submit copies to Party A for future reference. Those suspected of crimes of unknown origin shall not be used, and shall be inspected by the local public security department. If Party B fails to manage personnel as required, or a fight occurs during the construction, Party B shall bear all economic and legal responsibilities.
Twelve, the project payment settlement method
1, sign the contract lump sum table according to the budgeted cost.
2. If the total budget price is not priced, it will be adjusted according to the on-site visa and included in the total settlement price.
XIII. Payment Method of the Project
Party B's project will be settled in one lump sum, and no fees will be paid halfway.
Fourteen Rights and obligations of Party A
1. Party A shall make technical disclosure and management disclosure to Party B. ..
2. Party A shall perform the terms of the contract.
3. Party A has the right to supervise and inspect Party B at any time according to the contract.
Fifteen. Rights and obligations of Party B
1. Party B shall abide by the terms of the contract.
2. Party B shall manage according to the contract.
3. Party B has the right to make suggestions to Party A. ..
4. If Party A fails to abide by the contract, Party B has the right to appeal.
Sixteen. other terms
If Party B leaves his post halfway or fails to perform the contract, Party A will not settle the project payment for Party B, and all expenses will be borne by Party B.. In the process of construction, in order to realize convenient, timely and effective management, the first responsible person of Party B must live in the construction site.
17. This agreement is made in duplicate, with each party holding one copy. It will take effect after signing, and will automatically become invalid after the project is completed and the final payment is paid.
18. Other matters not covered shall be settled by both parties through negotiation and a supplementary agreement shall be signed.
Nineteen. Any dispute arising from the performance of this contract shall be submitted to Lichuan Arbitration Commission for arbitration.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Advertising project construction contract agreement II
(name of owner, hereinafter referred to as "owner") implementation
(project name), accepted
(name of contractor, hereinafter referred to as "contractor") to carry out this project.
Bid section construction bidding. The Employer and the Contractor have reached the following agreement.
1. The first bid section is from K+ to K+, which is about kilometers long, the highway grade is, the design speed is, and the road surface is provided with an interchange; Bridge seat, m long, m; Large and medium bridge seat, length m; Structural engineering such as tunnel seat, meter length m, etc.
2. The following documents shall be regarded as an integral part of the contract documents:
(1) this agreement and various contract attachments (including clarification documents and supplementary materials during bid evaluation and contract negotiation);
(2) Letter of acceptance;
(3) Appendix;
(4) Letter of Tender and its attachments;
(5) Special contract terms for the project;
(6) Special contract terms for highway engineering;
(7) General contract terms;
(8) Technical specifications;
(9) Drawings;
(10) priced bill of quantities;
(1 1) The contractor's commitment to personnel and equipment investment and construction organization design in the bidding documents;
(12) Other contract documents.
3. The above documents complement each other and explain each other. If there is any ambiguity or inconsistency, the order agreed in the contract shall prevail.
4. The signed contract price calculated according to the estimated quantity and unit price or total price listed in the bill of quantities: RMB (in words).
5. The project manager of the contractor: Chief Project Engineer of the Contractor:.
6. The project quality meets the standards.
7. The contractor promises to undertake the implementation, completion and defect repair of the project in accordance with the contract.
8. The employer promises to pay the contract price to the contractor according to the conditions, time and method agreed in the contract.
9. The contractor shall start construction according to the supervisor's instructions, and the construction period shall be calendar days.
10. after the contractor provides the performance guarantee, this agreement shall come into effect after being signed by the legal representatives of both parties or their entrusted agents and stamped with the official seals of the company. After the completion of all projects, it will take effect after the completion acceptance, the expiration of the defect liability period and the issuance of the defect liability termination certificate.
1 1. This agreement is made in duplicate, with each party holding one copy. If the original and the copy are inconsistent, the original shall prevail.
12. For matters not covered in this contract, both parties shall sign a supplementary agreement separately. Supplementary agreement is an integral part of the contract.
Employer: (official seal of the company) Contractor: (official seal of the company)
Legal representative or its authorized agent: (signature) Legal representative or its authorized agent: (signature)
Year, month, sun, moon, sun.
Advertising project construction contract agreement 3
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
In accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC) and the Construction Law of People's Republic of China (PRC), and in combination with the specific conditions of this project, the two parties reached the following agreement through consultation on the principle of friendship, honesty and voluntariness:
Article 1 General situation of the project
1. Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;
2. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _;
Article 2 Scope of contracting: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 3 Project contracting method: _ _ _ _ _ _ _ _ _ _.
Article 4 Term of Contract
Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Completion date (the time when the project passes the fire control acceptance and the fire control acceptance certificate is issued): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 5 Project cost, payment method and price adjustment
Project cost: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Payment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Price adjustment: _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 6 Engineering Quality and Acceptance Criteria
1. This project has been accepted by Party A, Party B and the government fire department according to the construction drawing, design description, design changes and relevant national (industry) standards and specifications.
2. The project quality must conform to the Unified Standard for Acceptance of Construction Quality of Building Engineering (gb50300-200 1), Code for Construction and Acceptance of Automatic Fire Alarm System (gb50 166- 1992) and Code for Construction and Acceptance of Automatic Sprinkler Fire Extinguishing System (2003 edition) Gb5026 1- 1996。 Code for construction and acceptance of mechanical equipment installation engineering gb5023 1- 1998. Code for acceptance of construction quality of building electrical engineering (gb50303-2002). Technical standard for construction of indoor fire hydrant water supply and fire extinguishing system installation engineering J565433.
Article 7 Safe construction
1. Party B must comply with the current national and local relevant specifications and requirements, and at the same time, Party A must implement the safety and civilized management measures for construction projects. ..
2. In the process of construction, Party B shall bear all responsibilities and losses for quality accidents, safety accidents or fire accidents caused by Party B's violation of relevant safety operation regulations or fire regulations.
Article 8 Quality Assurance
1. The free quality warranty period of this project is _ _ _ _ _ _ _ _ years, and it will be maintained for life.
2. Party B shall arrive at the site within 4 hours after receiving the maintenance notice from Party A and handle it in time.
3. During the free warranty period, Party B shall designate a special person to be responsible for the warranty work of this project, and communicate with Party A twice a month on a regular basis, subject to written records. At the same time, it is necessary to ensure smooth communication so that Party A can get in touch with Party B at any time. If Party B changes the warranty personnel or contact telephone number, it shall notify Party A in time. If Party B delays shirking due to poor communication or deliberate non-answer, Party A will regard Party B as giving up the warranty responsibility and have the right to solve it by itself, and Party B will bear all the expenses and add 10% service fee.
4. Payment method of warranty money
4. 1 After the specified warranty period expires, if there is no quality problem, the quality warranty fund shall be paid to Party B at one time without interest.
4.2 During the free quality warranty period, if there is any quality problem, and Party B fails to carry out maintenance within the time specified in Article 2 after receiving the maintenance notice from Party A, it shall be deemed as authorizing Party A to organize maintenance, and all expenses and quality responsibilities shall be borne by Party B, and at the same time, Party A shall charge _ _ _ _ _% of the maintenance fee as a service fee. After the above expenses are directly deducted from Party B's quality guarantee fund, Party B is responsible for making up the quality guarantee fund.
4.3 During the free warranty period, if there are quality problems and Party A cannot get in touch with Party B due to Party B's reasons, the provisions of the preceding paragraph shall apply.
Article 9 Rights and obligations of both parties
1. Party A is responsible for coordinating construction water and electricity consumption for Party B, and the expenses shall be borne by Party B..
2. Before signing this contract, Party B shall provide Party A with enterprise qualification certificate, copy of business license, legal person code certificate and other relevant qualification certificates.
3. Party B is responsible for construction, installation, completion acceptance, quality assurance service, submission of fire control acceptance report and communication with the design unit designated by Party A. ..
4. Party B must carry out the construction and installation according to the construction drawings confirmed or provided by Party A in writing and the installation scheme and method confirmed by Party A, and shall not change them without authorization. If there is any change, the written notice of change shall prevail.
5. Party B shall carry out process inspection and final inspection on concealed works such as fire-fighting electrical circuit and fire-fighting water supply pipeline in combination with main working procedures such as construction, installation, debugging and acceptance, and make quality records in stages. Party B shall be responsible for the whole fire control system before the installation and construction of the fire control project is completed but fails to pass the fire control acceptance. After the acceptance of fire protection, Party B must actively provide Party A with installation and commissioning records, opening reports, concealed works records, fire protection engineering manuals and other documents, conscientiously perform the handover procedures, and take the initiative to do a good job in the later maintenance of the project.
Article 10 Liability for breach of contract and claim
1. If Party A fails to make payment as agreed in this Contract without justifiable reasons and fails to make payment within ten days after receiving Party B's written dunning notice, Party A shall pay Party B a penalty of 2‰ of the payable amount from the date when the dunning expires.
2. Before the project fails to pass the acceptance, if Party A uses it without authorization and causes damage, Party A shall bear the corresponding responsibilities in addition to the quality reasons of the project itself.
3. If the project is not completed within the time agreed in the contract, Party B shall pay Party A a penalty of two thousandths of the total project cost for each day of delay.
4. Due to the quality of materials and equipment provided by Party B and the construction quality of Party B, Party B shall bear all losses caused by quality accidents, safety accidents or fire accidents during the use of this project.
5. If the project fails to meet the quality acceptance standard stipulated in the contract or fails to pass the acceptance of the government fire department, Party B shall bear all the losses caused to Party A, and at the same time, Party B must rework it for free within the time limit stipulated by Party A until it passes the fire acceptance.
6. Party B shall deliver the completion materials and other materials related to the project to Party A within seven days after the completion of the project, otherwise, Party B shall pay Party A a penalty of two thousandths of the total project cost for each day overdue.
Article 11 Settlement of disputes
Any dispute arising from this contract shall be settled by both parties through consultation; If negotiation fails, a lawsuit may be brought to the people's court where the project is located.
Article 12 Other agreements
1. This contract is made in duplicate, with each party holding one copy; Four copies, three copies for Party A and one copy for Party B. ..
2. This contract shall come into effect as of the date of signature and seal by both parties.
3. For matters not covered in this contract, both parties may sign a supplementary agreement. The annexes and related explanations of this contract are an integral part of this contract and have the same legal effect as this contract.
Party A (signature): _ _ _ _ _ _ _ _ _ _ Party B (signature): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Advertising project construction contract agreement 4
Party A:
Party B:
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, Party A subcontracts the marble treads and skirting lines of staircases, outdoor floors of residential areas and dry-hung marble walls of outlets to Party B for construction, and the following contract terms are reached through full consultation between Party A and Party B. ..
I. Overview of the Project:
1, project name: residential area
2. Project location: Jiangbei
3. Project content: marble footwork, skirting line in the building, outdoor terrace, and dry hanging on the external wall of residential socket.
4. Duration: 20 _ _ _10.25-20 _ _ 6.30
Two. Scope of project contracting: All the projects are contracted to Party B for supply. ..
3. Contract price: 65,438 yuan +025 yuan/㎡ for marble treads, skirting lines and outdoor terraces in residential areas in the building, and 365,438 yuan +00 yuan/㎡ for dry hanging marble on the external walls of outlets. Contract price: eight hundred and twenty-two thousand yuan only (￥ 8,020 _ _ _ _). 00 yuan, subject to the actual reduction scale).
Four. Payment method: After both parties sign the contract, Party A shall pay Party B RMB100,000 Yuan only, and pay 80% of the project amount for each building on schedule according to the engineering quantity, and pay the project amount in one lump sum within 15 days after Party B completes all the projects and is accepted by Party A.. ..
Fourth, the construction quality requirements:
1, the quality grade is qualified;
2. Specification of slate: It shall be manufactured and installed according to the stone specified by Party A. ..
3. During the construction period, Party B shall pay attention to safety, do a good job of protection, clean up the site after work, and conduct civilized construction. The garbage of this project shall be removed in time.
Verb (abbreviation of verb) construction period
According to the construction period of Party A, make the construction plan to ensure the completion on schedule.
The responsibility of both sides of intransitive verbs
1. Party B must obey the command and arrange management, and Party A shall provide construction drawings for Party B's construction.
2. Party B must arrange skilled and experienced workers to carry out the construction, and carry out the construction according to the operation specifications. In case of quality and safety accidents, Party B shall be responsible.
3, homework personnel to enter the construction site should abide by the system of safety civilization, if illegal depending on the seriousness of the criticism and education of the parties, if repeated admonitions can be cleared.
4. During Party B's entry into the construction site, Party A shall provide all convenient conditions for Party B's construction.
This contract is made in duplicate, with Party A and Party B holding one copy respectively, which will naturally become invalid after the contract is fulfilled. If there are any outstanding matters, both parties shall sign a supplementary agreement after consultation. As an annex to this contract, the supplementary agreement has the same legal effect as the main contract.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Advertising project construction contract agreement 5 pages
Party A:
Party B:
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction of the marble pavement project and concluded this construction contract.
I. Project Name: _ _ _ _ _ Marble Paving Project: Paving Project
Second, the way of contracting: contracting for labor and materials. All materials shall be purchased by Party B, but they must be qualified products.
Three. Term of the contract: completed before June, 20__ _165438+1October 5. If it is not completed within the specified time, it will be fined RMB 1000.00 yuan for each day of delay. In case of force majeure or Party A's reasons, the construction period shall be postponed.
Four. Engineering quality standard: qualified, with a warranty period of two years, counting from the date of completion acceptance. If there are quality problems during the warranty period, Party B shall go to the site for maintenance within 24 hours after receiving the notice, otherwise Party A has the right to terminate the contract and send someone to repair it, and pay Party B a double fine according to the losses caused.
Five, engineering practices and comprehensive unit price:
1, trenching, the compaction density of plain soil is greater than 92%;
2. 150 thick 3:7 lime soil;
3. 100mm thick C 15 concrete cushion;
4. The following slabs are paved with 30-thick 1:3 cement mortar, and the comprehensive unit price and contract price are verified according to the current market materials and labor costs:
Payment method of intransitive verbs: 20% of the total contract cost is paid after the engineering cushion is completed and the acceptance certificate is issued by the development company and the engineering management department * * *, and 90% of the total project cost based on the actual visa is paid after the marble slab is laid and the acceptance certificate is issued by the development company and the engineering management department * * * *. And 95% of the total project cost will be paid one year after the completion and acceptance, and the remaining 5% quality guarantee money will be paid in one lump sum after two years of completion and acceptance without quality problems. Party B shall provide a complete invoice at each settlement.
Seven. Party A's responsibilities:
1. Party A is responsible for examining and approving Party B's construction organization plan, supervising and inspecting Party B's construction quality at any time, organizing the project completion acceptance, and handling relevant settlement as stipulated in the contract.
2. Party A is responsible for coordinating the cooperation between Party B and other subcontractors.
Eight. Party B's responsibilities:
1. Party B shall carry out the construction according to the current national technical specifications and standards, establish a perfect quality and safety system, and equip relevant personnel for quality and safety management.
2. Party B is responsible for the quality control and safe and civilized construction management in the whole construction process, and for meeting Party A's requirements in terms of safety protection, temporary electricity use safety, mechanical safety and site management, so as to prevent the occurrence of safety accidents. Party B shall bear all civil and economic responsibilities for safety accidents caused by improper management of Party B's project leader.
3. Party B shall terminate the workers' petition. If there is any complaint, Party B will be punished according to 40% of the total project cost.
4. Party B is responsible for protecting the underground pipeline during the construction and garbage removal, and ensuring the smooth flow of the pipeline. If the damage is caused by Party B, Party B shall promptly repair it free of charge.
5. Party B shall be responsible for water and electricity.
6. Within five days after the project completion acceptance, Party B shall clean up the temporary facilities and construction waste on site, otherwise Party A will entrust the cleaning, and the expenses shall be borne by Party B, and Party B shall be fined 5% of the total project price.
9. Liability for breach of contract: All losses caused by quality problems shall be borne by Party B, and other problems shall be borne by the breaching party. If Party B fails to meet the requirements of the contract in terms of quality, safety and construction period, which causes losses to Party A, all losses shall be borne by Party B, and Party A has the right to terminate the contract, require Party B to withdraw from the construction site, deduct 65,438+00% of Party B's project price as liquidated damages, and arrange another construction team.
X. Ways to resolve contract disputes:
1. Mediation by both parties.
2. If mediation fails, bring a lawsuit to Qingzhou People's Court according to law.
XI。 This contract is made in quintuplicate, four for Party A and one for Party B. This contract shall come into effect as of the date when both parties sign and seal it, and shall be terminated after the project payment is settled.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Advertising project construction contract agreement 6 pages
Employer: (hereinafter referred to as Party A)
Contractor; (hereinafter referred to as Party B)
According to the Contract Law of People's Republic of China (PRC), the Trial Measures for Decoration Management of the Ministry of Construction and the specific conditions of this project, Party A and Party B reach the following agreement on the basis of voluntariness, equality and consensus:
I. Overview of the project;
1, decorate the construction site:
2. Decoration construction content: (see Annex I, Construction Drawing)
3. Contracting method;
4. Cost: (See Annex II, Quotation)
5. Construction period; The construction period is days, from the commencement date to the completion date.
Second, the main and auxiliary materials and equipment supply agreement:
1. Party A is responsible for purchasing main and auxiliary materials.
2. The materials provided by Party A shall be kept by Party B, and the losses caused by improper keeping shall be borne by Party B.
3. The materials supplied by Party A shall be used in the project specified in this contract, and Party B shall not move without Party A's consent.
Three. Project quality and acceptance agreement
1, this project implements DBJ-62-97 technical specification for architectural decoration engineering and DB3 1/T30- 1999 decoration.
2. Party A shall provide the construction drawing of this project.
3. In the process of construction, if Party B changes the project content without authorization, Party B shall bear all consequences.
4. Party B shall carry out the next working procedure in time three days before each construction acceptance stage. Without acceptance, Party B shall be responsible for the losses caused thereby, and Party A reserves the right to impose additional fines on the progress. After receiving the written notice, Party A shall organize the acceptance within the specified time. If it is not accepted for more than three days, it shall be deemed that Party B has passed the construction and agreed to the construction of the next project.
Four. Safety construction agreement
1. Party B must strictly implement the safety production requirements and carry out civilized and safe construction. Party B shall be responsible for all safety accidents caused by Party B during the construction.
2. Party B is responsible for the safety of operators and related jobs during construction. In case of any safety accident due to Party B, Party B shall bear all expenses and responsibilities arising therefrom.
Verb (abbreviation of verb) Project progress and payment method:
1. After both parties sign this contract, Party B must ensure that the number of construction workers shall not be less than. Party A shall pay Party B 15% of the project payment after 10 day.
2. After the construction, Party A shall pay Party B 60% of the total project price.
3. After the acceptance of the project is completed, after accounting by both parties, Party A shall pay Party B 30% of the total project price.
4. The remaining 10% shall be used as the maintenance payment, and Party A shall pay the project payment to Party B within ten days after the expiration of one-year maintenance.
5. Party B shall ensure that the project is completed on time and with good quality. If the project is delayed or losses are caused to Party A due to the quality and progress problems of Party B, Party B must compensate.
Liability for breach of contract of intransitive verbs
1. If the construction period is delayed or stopped halfway due to Party A's reasons, the construction period will be postponed. If it exceeds ten days, Party A will compensate the workers stranded at Party B's site accordingly.
2. If the completion of the project is delayed due to Party B's reasons, Party B shall pay a penalty of 65,438 yuan+0,000 yuan for each day overdue, and delay for three days.
Seven. Alteration and termination of the contract
1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. After the signing of this contract and before the commencement of construction, any party who wants to terminate this contract shall put forward a written proposal, pay the other party% of the total contract price as penalty, and go through the termination procedures.
2. After this contract is signed, the project shall not be subcontracted.
Eight. supplementary terms
1. This contract is made in duplicate. Party A and Party B each hold one copy. The annex is an integral part of this contract and has the same legal effect. After the contract is completed, this contract will automatically become invalid.
2. Party B shall be responsible for the personnel arrangement during the construction of this project, and Party A shall not be responsible for all matters of Party B's workers. Party B's construction personnel must all have construction qualifications.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _