With the general improvement of people's legal awareness, contracts are indispensable on many occasions, and the signing of contracts is the best norm for the rights and obligations of both parties. I believe many of my friends are very uneasy about the proposed contract. The following is a sample of the contract for processing plastic products (generally 5) that I have carefully arranged. Welcome to read the collection.
Principal of plastic products processing contract1:_ _ _ _ _ (hereinafter referred to as Party A)
Trustee: _ _ _ _ _ _ (hereinafter referred to as Party B)
Party A entrusts Party B with processing, and according to the provisions of the Contract Law of People's Republic of China (PRC), this contract is hereby concluded through full consultation between both parties for mutual compliance.
Article 1 Finished products: Article 2 Quality requirements of finished products: (If samples need to be sealed for processing customized articles, the representatives of both parties shall personally seal them and keep them properly as the basis for acceptance).
Article 3 Mode, specification, quantity and quality of raw materials: Party A provides plastic molds to Party B, and Party B provides raw materials. When Party B conceals the defects of raw materials or uses raw materials that are not in conformity with the contract, which affects the quality of ordered crops, Party A has the right to request rework, price reduction or return.
Article 4 Methods of providing technical data and drawings:
1. In the process of working according to Party A's requirements, if Party B finds that the drawings or technical requirements provided are unreasonable, it shall notify Party A in time; Party A shall reply and propose amendments within the specified time. If Party B fails to get a reply within the specified time, Party B has the right to stop working and notify Party A in time, and Party A shall compensate the losses caused thereby.
2. If required by Party A, Party B shall strictly abide by the confidentiality provisions of the contract work, and Party B shall not keep technical materials and copies without Party A's permission.
3. Party A shall provide technical data and drawings according to the specified date.
Article 5 Prices or gratuities: Prices or gratuities shall be implemented in accordance with the provisions of the state or competent authorities. If there is no provision, it shall be agreed by both parties.
Article 6 Acceptance criteria and methods:
1, according to the quality requirements stipulated in the contract, with drawings and samples as the acceptance criteria.
2. Party A shall accept the work completed by Party B within the time limit stipulated in the contract. Before acceptance, Party B shall submit necessary technical data and relevant quality certificates to Party A. For crops or projects that are difficult to find quality defects in short-term inspection, both parties shall negotiate and stipulate the warranty period in the contract. If there is any problem during the warranty period, except for the quality problem caused by improper use or storage by Party A, Party B shall be responsible for repair or return.
3. When both parties have disputes over the contracted crops and the quality of the project during the inspection, the inspection certificate can be issued by the legal quality supervision and inspection institution.
Article 7 Delivery time: Party B shall deliver the 8000.00- 10000.00 plastic box to Party A before 20th of each month. If either party requests to deliver (deliver) the ordered crops in advance or later, it shall reach an agreement with the other party in advance and implement it according to the agreement.
Article 8 Packaging requirements and expenses: Party B shall be responsible.
Article 9 Transportation and expense burden: Party B shall be responsible.
Article 10 Settlement method and time limit: the payment of last month shall be settled on 25th of each month.
Article 11 Others:
1. According to the relevant national regulations, Party A shall deliver the deposit contract to Party B, and has no right to demand the return of the deposit. If Party B fails to perform the contract, it shall double the deposit.
2. According to the relevant national regulations, Party A may pay Party B the advance payment with the consent of both parties. If Party B fails to perform the contract, it shall not only bear the liability for breach of contract, but also repay the advance payment in full. If Party A fails to perform the contract, it may take the advance payment as liquidated damages and compensation; If there is a balance, you can ask for a refund.
Article 12 Party B's liability for breach of contract:
1. If Party A agrees to use the ordered crops or fails to complete the work according to the quality stipulated in the contract, the price shall be determined according to the quality; If it does not agree to use it, it shall be responsible for replacing it and bear the responsibility for overdue delivery; After the replacement, if it still does not meet the requirements of the contract, Party A has the right to reject it, and Party B shall be responsible for the losses caused thereby. ..
2. The quantity of ordered crops delivered or the work completed is less than the quantity stipulated in the contract. If Party A still needs it, it shall make up according to the quantity, and the overdue part shall be treated as overdue delivery; If the part that Party A no longer needs fails to pay, Party A has the right to terminate the contract, and the losses caused thereby shall be compensated by Party B. ..
3. If Party A demands compensation for the loss but does not demand repair or repackaging, Party B shall pay Party A the part of the unqualified package that is lower than the value of the qualified package. If the ordered crops are damaged or lost due to unqualified packaging, Party B shall compensate for the losses.
4. If the ordered crops are delivered late, Party A shall pay RMB as liquidated damages; (If there is no specific agreement in the contract, the liquidated damages shall be paid to Party A according to the regulations of the People's Bank of China on deferred payment and the total price of the overdue part. ) If the payment is calculated by remuneration, a penalty of 1/1000 of the total remuneration of the overdue part shall be paid for each day overdue. Without Party A's consent, Party A has the right to refuse the ordered crops delivered in advance.
Article 13 Party A's liability for breach of contract:
1. If the quantity, specifications, quality or design of the ordered crops are changed midway, Party B shall compensate for the losses caused thereby.
2. If Party A fails to collect the ordered crops for six months within the time limit stipulated in the contract, Party B has the right to sell the ordered crops, and the proceeds will be returned to Party A after deducting the remuneration, storage and maintenance fees; When the income from selling the ordered crops is lower than the remuneration and storage maintenance fee, Party A shall also compensate the insufficient part; If the ordered crops cannot be sold, Party B shall be compensated for the losses.
3. If the payment is made beyond the date stipulated in the contract, Party B shall be paid liquidated damages according to the regulations of the People's Bank of China on deferred payment; According to the remuneration, the penalty shall be paid at one thousandth of the total remuneration for each overdue day.
4. If Party B refuses to accept the ordered crops without reason, it shall compensate the losses caused to Party B..
5. Change the delivery place or receiving unit (person) of the ordered crops, and the extra expenses shall be borne by myself. Article 14 Force Majeure: If the crops or raw materials ordered are damaged or lost due to force majeure during the performance period stipulated in this contract, Party B may be exempted from the liability for breach of contract after obtaining the legal certificate, but shall actively take measures to minimize the losses. If it occurs outside the performance period stipulated in the contract, it cannot be exempted from liability; If Party A delays the acceptance or unreasonably refuses, Party A shall bear the responsibility and compensate Party B for the losses caused thereby.
Article 15 Settlement of disputes: In case of disputes over processing contracts, both parties shall settle them through consultation; If negotiation fails, either party may apply to the contract management authority for mediation or arbitration, or bring a lawsuit directly to the people's court.
This contract shall come into effect after being signed or sealed by both parties, and shall become invalid after the completion of the contract. During the execution of this contract, both parties shall not change or terminate the contract at will. If there are any matters not covered in this contract, both parties shall make supplementary provisions after consultation, and the supplementary provisions shall have the same effect as this contract.
This contract is made in duplicate, one for each party, with the same legal effect.
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Principal II of Plastic Products Processing Contract: _ _ (hereinafter referred to as Party A)
Contractor: _ _ _ _ _ _ (hereinafter referred to as Party B)
Through friendly negotiation, Party A and Party B have reached the following terms on Party B's undertaking of Party A's processing business for both parties to abide by:
1. Party B intends to undertake the processing business of Party A's products. During the contract period, Party B will complete the processing business with its own personnel, equipment and technology.
Second, the contract period:
Tentative one year, from _ _ _ _ to _ _ _ _. At the expiration of the time limit, both parties may extend the time limit.
Three. This contract is a framework contract for both parties to establish processing contracting business. The specific operation steps are as follows:
1. If Party A has outsourcing processing business, it shall notify Party B (usually by telephone), and Party B shall come to Party A within the day after receiving the notification. If Party B confirms that it can complete the processing business according to Party A's requirements (including delivery time and quality, etc.). ), send people to Party A to receive the workpieces (or raw materials) to be processed, handle the handover procedures, and sign the Notice of External Processing and the Process Quality Document for confirmation (if there are special process quality requirements). The Notice of External Processing and the Process Quality Document are the basis for settlement between the two parties, and the Notice of External Processing serves as the receipt certificate of Party B. ..
2. After completing the processing business, Party B shall make (or fill in) the delivery note and send the delivery note and processed parts (and iron filings, etc.). ) according to the delivery note to Party A, pile it in the place designated by Party A, and mark the products according to Party A's requirements.
3. Party A's staff shall check the quantity according to the quantity of Party B's delivery note, and sign for the quantity delivered by Party B, but the signing for the quantity shall not be used as the basis for both parties to settle the processing fee.
4. The inspector of Party A shall inspect the appearance quality (such as size and surface condition) of the products within three working days after Party B delivers the workpieces, and sign the delivery note. Party A's warehouse staff will put the processed qualified workpieces into the warehouse with the inspection certificate of Party A's inspector, and issue the warehousing certificate or sign the delivery note to Party B..
4. The workpieces shall be delivered by Party A, and the responsibilities and expenses during transportation shall be borne by Party B. ..
Five, margin and processing fee standards.
1. If Party B undertakes Party A's processing business for the first time, Party B shall pay the deposit to Party A upon receipt of the first batch of processed workpieces, and the deposit will be returned after months depending on Party B's performance of the contract.
2. If Party B keeps all the processing fees in Party A, the processing fees kept by Party B will be used as the security deposit.
3. The deposit amount shall not be less than RMB, and Party B shall make up the difference in time. If Party B breaches the contract or causes losses to Party A, Party A may directly deduct relevant liquidated damages or losses from the deposit.
4. The processing fee shall be settled according to Party A's foreign processing fee settlement regulations. If there are special processing requirements, the price will be settled separately, and both parties will reach a supplementary agreement on processing fees separately.
Rights and obligations of party a:
1. Pay the processing fee as agreed.
2. Track and supervise the progress and quality of Party B's processing. If Party B fails to fulfill the processing obligations as required, Party A may unilaterally terminate this contract.
3. During the contract period, Party A has the right to conduct processing business with other units other than Party B. ..
Seven. Rights and obligations of Party B:
1. Complete the processing business according to the Outgoing Processing Notice and the requirements of the processing drawings, and abide by Party A's Outgoing Processing Management System.
2. Complete the processing business on time and with good quality, and it is forbidden to hand over the contracted business to a third party.
3. Party A's business secrets and technical secrets (including drawings, etc.). ) The information learned during the processing must be kept confidential. After each processing business is completed, the drawings and other materials shall be returned to Party A with the workpiece, and shall not be copied or duplicated without the written consent of Party A..
4. When Party B's personnel come to Party A's company, they must abide by Party A's rules and regulations, otherwise all losses caused thereby shall be borne by Party B. ..
5. Before the workpiece is processed, Party B shall check whether the appearance, size, marking material, work order number and part number of the workpiece to be processed are consistent with the External Processing Notice and processing drawings, and notify Party A immediately if they are inconsistent. If Party B fails to check and handle, the losses caused thereby shall be borne by Party B. ..
6. The warranty period of Party B for the internal quality of the processed workpiece is two years from the date of delivery. During the warranty period, all losses (including but not limited to the material cost, processing cost and freight cost of the workpiece itself) caused by the quality problems of the workpiece processed by Party B (whether Party A or its customers use it or not) shall be borne by Party B. The inspection of the workpiece by the inspectors of Party A cannot exempt Party B from the responsibilities due to the quality problems of the processed workpiece.
Eight, processing fee payment:
At the end of each month, Party B shall go to Party A's finance for settlement with the Notice of Entrusted Processing and the Bill of Lading for Entrusted Processing signed by Party A's inspector and warehouse keeper, and issue the corresponding VAT invoice according to the amount determined by the settlement, and Party A shall pay within 90 working days after receiving the invoice.
Nine, liquidated damages and loss calculation:
1. If Party B fails to deliver the goods on time, it shall pay a penalty of RMB yuan for each day overdue and RMB yuan.
2. Party B must process according to Party A's technological requirements and quality requirements. If Party B fails to process according to Party A's technological requirements and quality requirements, it shall pay a penalty of 5%-30% of the cost price of the processed workpiece. If Party A suffers losses due to quality problems, it shall compensate the losses separately (the losses shall be calculated according to paragraphs 3 and 4 of this article).
3. If the workpieces with quality problems can be reworked, all rework costs (including transportation costs) shall be borne by Party B. If the delivery is delayed due to rework, Party B shall pay liquidated damages separately according to the agreement in the first paragraph of this article.
4. For scrapped workpieces with quality problems (the repair welding of forgings is considered as scrapped), Party B shall compensate Party A for all losses. The calculation method of loss is as follows: loss of raw materials (calculated by the weight of processing blanking)+processing fee before the workpiece is delivered to Party B (the standard of processing fee is settled according to the annex to the contract)+liquidated damages and compensation paid by Party A to customers+expected profit (calculated by 20% of the workpiece price)-salvage value of scrapped workpiece (converted by the market scrap price of this material).
X. others:
1. Annex to the contract: settlement clause of external processing fee.
2. This contract is made in duplicate, one for each party, and shall come into effect after being signed or sealed by both parties.
(There is no text below)
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
Authorized representative: _ _ _ _ _ Authorized representative: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Plastic Products Processing Contract 3: _ _ _ _ _ _ _
Customer: _ _ _ _ _ _ _
In order to clarify the rights and obligations of both parties, this contract is hereby concluded through friendly negotiation in accordance with the Economic Contract Law of the People's Republic of China and its relevant provisions.
First, the contract standard.
Name: _ _ _ _ _ _ _
Material: _ _ _ _ _ _
Specification (mm): _ _ _ _ _ _ _
Unit of measurement: _ _ _ _ _ _ _
Unit price (including tax): _ _ _ _ _ _
Amount (Yuan): _ _ _ _ _ _ _
Remarks: _ _ _ _ _ _ _
see annex
Total (in words): _ _ _ _ _ _ The specific amount is subject to the actual delivery.
Second, the quality requirements and technical standards:
Subject to the confirmation of the manuscript provided by the customer! According to national standards.
Third, the responsibility and quantity of the page fee:
All packages are made by Yuncheng Plate Making Company, and the printing fee is 65,438+049,000 yuan in advance by the entrusting party. If the cumulative value of each set reaches150,000 yuan, the organizer will refund the publishing fee in full. The modification fee shall be borne by the entrusting party. See the attachment for the minimum order quantity.
Four. Payment settlement method and time:
The contractor shall provide 17% VAT invoice at the end of each month, and the entrusting party shall pay it before 20th of the following month. Unless otherwise stipulated by the contractor in writing, payment shall be made by remittance to the bank where the contractor opens an account listed in this contract.
Verb (abbreviation of verb) acceptance criteria and methods:
In accordance with the relevant national standards or the acceptance criteria and methods agreed by both parties in writing.
Intransitive verb mode of transportation and delivery time:
The contractor is responsible for the delivery to the entrusting party, and the freight contractor is responsible for it. Delivery time of the new version: 20 days after the customer confirms the manuscript, and 15 days after the contract is signed.
Seven, processing contract:
The location of the contractor.
Eight, after the contract comes into effect, the contractor shall pay the developer a quality deposit of 20000 yuan, which will be deducted at the time of settlement.
Nine. After the contract comes into effect, the entrusting party proposes to change the subject matter of the contract halfway. If no losses are caused to the contractor, the entrusting party may request to change the order, and the contractor shall deliver the goods according to the changed order. If the contractor has carried out the construction, all the manuscript fees, edition fees, material fees and working hours shall be borne by the entrusting party, and the entrusting party shall not refuse to pay the relevant fees.
X. Agreement on delivery date:
The delivery date shall be determined by both parties through consultation according to the technical requirements of the product, and the time shall be counted from the time when the entrusting party finally determines and places the order. Due to the delay in finalizing or placing orders, the delivery date will be delayed.
XI。 Acceptance time:
As the contractor delivers the products, the entrusting party shall inspect the quantity and quality of the products as agreed in the contract. If the quantity or quality of the products do not meet the requirements of the contract, the entrusting party shall raise a written objection to the contractor within 15 days from the date of receiving the products, and shall not use the products, otherwise the quantity and quality of the products shall be deemed to meet the requirements of the contract. For quality defects that are difficult to find in short-term inspection, the contractor shall be responsible for returning the goods except those caused by improper use or storage by the entrusting party. If there are other problems, both parties should solve them through consultation.
Twelve. Intellectual property:
If the products ordered by the entrusting party involve registered trademarks or intellectual property rights such as design patents and copyrights. , the entrusting party shall provide the ownership or use license to the contractor. The entrusting party shall also provide the contractor with the power of attorney, a copy of business license (with official seal), barcode certificate, QS certificate, etc. The entrusting party shall be responsible for the authenticity and legality of all the information provided. If the client fails to provide or the information provided is untrue, the client shall bear all economic and legal responsibilities.
Thirteen. The contractor shall provide the client with a copy of business license (with official seal), QS certificate, a copy of printing license (with official seal) and a third-party inspection report.
Fourteen Exemption from liability:
The delay or non-delivery of products caused by accidents such as force majeure, power failure and main equipment failure shall not be regarded as the contractor's breach of contract, but the contractor shall notify the entrusting party in writing within 12 hours after the above accidents, and the contractor is still obliged to take all necessary measures to deliver the products as soon as possible. If the force majeure lasts for more than one week, the entrusting party has the right to cancel this contract.
Fifteen. Liability for breach of contract:
1. If the contractor fails to deliver the crops according to the quality stipulated in the contract and the entrusting party agrees to use them, the price shall be determined according to the quality; If it does not agree to use it, it shall be responsible for replacing it and bear the responsibility for overdue delivery; If the replacement still does not meet the requirements of the contract, the entrusting party has the right to refuse, and the losses caused thereby shall be compensated by the contractor.
2. If the quantity of delivered crops or completed work is less than that stipulated in the contract, if the entrusting party still needs it, it shall make up according to the quantity, and the overdue delivery shall be handled according to the fourth paragraph of this article; If the underpaid part of the client is no longer needed, the client has the right to terminate the contract, and the losses caused thereby shall be compensated by the contractor.
3. If the crops are damaged or lost due to packaging problems, the contractor shall compensate for the losses.
4. If the delivery is overdue, the contractor shall bear 0.2% of the total contract price as liquidated damages for each day of delay (delivery of qualified products according to the agreed quantity shall be regarded as delivery); Without the consent of the entrusting party, the ordering party has the right to refuse to deliver the crops in advance.
5. If the crops cannot be delivered or the work cannot be completed, a penalty of 20% of the total contract price shall be paid.
If the client misses the best opportunity to sell products because the contractor's work schedule or product quality does not meet the contract requirements, causing losses to the client, the contractor shall not only refund all the money paid by the buyer in the early stage, but also bear the direct and indirect economic losses of the client according to the actual situation.
16. After the conclusion of this contract, both parties shall be bound by this contract for the order business increased by the entrusting party and confirmed by the undertaking party.
17. Matters not covered in this contract shall be handled in accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC).
18. Any dispute arising during the performance of the contract shall be settled by both parties through consultation. If negotiation fails, it shall be settled by the court with jurisdiction where the entrusting party is located.
19. This contract is made in duplicate, one for each party, and shall come into effect as of the date when both parties affix their seals. However, if the contract stipulates that there is an advance payment, it will take effect from the date of delivery of the advance payment.
The contract is valid from _ _ _ _ _ _ _ _ _ _ _ _ _ _ to _ _ _ _ _ _ _.
Contractor: _ _ _ _ _ _ Customer: _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Plastic Products Processing Contract 4 Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Through negotiation between Party A and Party B, Party A entrusts Party B to process according to the specifications and models provided by it, and the raw materials are provided by.
1. Product name, model, quantity and amount:
Total amount: RMB _ _ _ _ _ _
Total contract price: RMB _ _ _ _ _ _ (in words: _ _ _ _ _)
2. Quality requirements: The construction in strict accordance with the drawings provided by Party A is qualified.
3. Place and method of delivery (delivery): self-delivery.
Four. Delivery time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Verb (abbreviation for verb) Terms of payment and settlement period:
Liability for breach of contract of intransitive verb: Party B shall not produce if Party A fails to pay in time; If Party B fails to deliver the goods on time, it shall bear the losses for breach of contract.
Seven. Ways to resolve contract disputes: both parties shall negotiate or submit to Xi Arbitration Commission for settlement.
8. This contract shall come into effect as of the date of signature by both parties, and shall automatically become invalid after payment is settled.
9. Party B can handle the information needed by Party A according to the fax file provided by Party A, and the fax file has the same legal effect as the original.
X this contract is made in duplicate, one for each party. Have the same legal effect.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Five copies of plastic products processing contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
B: _ _ _ _ _ _ _ _
The first general rule
1. Based on the principles of friendly cooperation, equality and mutual benefit, both parties reached the cost agreement through friendly negotiation.
2. Based on this agreement, Party A entrusts Party B to produce the products specified in this agreement, and Party B accepts the entrustment and guarantees to provide qualified products to Party A. ..
Article 2 Scope of application of this Agreement
1. This agreement is applicable to all specific entrusted orders signed by both parties under this agreement and confirmed in writing (see Article 3).
2. All written instructions for entrusted processing, if unclear or not detailed, will be implemented in accordance with the relevant provisions of this agreement.
Three. Any supplement or modification to this Agreement shall be confirmed by both parties in writing before being incorporated into this Agreement, and shall have the same binding force as this Agreement.
Article 3 Entrusting Processing Orders
1. Before each production, Party A needs to issue a specific entrustment order. The general terms of the entrustment order are stipulated in this agreement, and the supplementary terms are stated in the order, which will take effect after being confirmed, signed and sealed by both parties.
2. The main content of the consignment note is the name, quantity and specific requirements of the processed goods. After confirmation, signature and seal by both parties, it has the same legal effect as this agreement.
3. The entrustment sheet is attached to this agreement, which conforms to the general provisions of this agreement and is an indispensable annex to this agreement.
Article 4 Project Agreement
1. The products processed and produced by Party A and Party B are exported hydraulic parts and other products, and Party B promises to process them according to the entrusted processing orders determined by both parties and the drawings provided by Party A. ..
2. Party A is responsible for drawing the drawings and documents of the products produced, as well as all the materials required by the production process requirements of the products, and providing necessary technical support to Party B's technicians. ..
Third, the products processed by Party A and Party B will be finally tested by Party A's measuring tools and other testing equipment and the data detected by Party A's technicians to determine whether the products processed by Party B are qualified.
4. Party B promises not to disclose or divulge the relationship between Product A and Party B to any third party, so as to protect the stability of Product A, and shall not disclose or transfer any relevant information of the product to any third party, nor authorize any third party to handle it on its behalf.
5. The technical ownership, intellectual property, technical information, commercial information and financial information of the products processed and produced by Party B belong to Party A, and Party B has the obligation to keep confidential. Without the written consent of Party A, Party B shall not copy, modify or imitate, keep technical data and copies, process and sell them to third parties by itself, or use Party A's technology to develop similar products. ..
6. The lathes, measuring tools, cutters, fixtures, inspection equipment and other equipment required by Party B shall be purchased by Party B itself. If Party A needs to manufacture and purchase, Party B shall pay the price and other amounts reasonably proposed by Party A. The lathe currently provided by Party A will be terminated on _ _ _ _ _. The raw materials needed for Party B's processing are provided by Party A, and the by-products (iron filings, aluminium scrap, etc.). ) After being handled by Party B, it will be recorded as the cost of Party B. ..
7. Due to the complexity of product testing procedures, if Party B has no conditions to provide testing, Party A can provide equipment and venues through negotiation. Party B only arranges employees to go to the site provided by Party A for testing or training and guidance.
Article 5 Product quality standards and responsibilities
1. The processed products delivered by Party B shall be accepted according to the quality inspection standards of Party A, and the performance and quality of the products shall meet the quality inspection standards (see Article 4, Item 3). If it does not meet the acceptance criteria, Party A has the right to ask Party B to repair it until it meets the acceptance criteria of Party A. ..
2. The quantity of scrapped products with different specifications in each batch shall be accounted according to the scrap rate, and the excess part shall be compensated according to the corresponding unit price specified by Party A, and the excess part shall not be compensated. For each batch of products with different specifications, if the quantity is less than or equal to _ _ _ _ _ _ _ _, the scrap rate is _ _ _ _ _%, and for other specially processed products, the quantity is _ _ _ _ _ _ _ _%.
3. If the defective products are caused by the materials provided by Party A, or due to Party A's design reasons, or the information provided is incorrect, Party A shall pay the repair expenses or repair them by itself. One-to-one exchange of defective materials.
Article 6 Ordering and Supply
I. Delivery date:
After receiving the technical data and raw materials provided by Party A, Party B shall arrange production in time to ensure delivery on the delivery date required by Party A. ..
2. Once the purchase order of Party A and Party B is signed, it shall not be cancelled. If changes are needed, both parties shall reach an agreement through consultation. Party B must supply the goods to Party A according to the specified time, quantity and quality requirements.
3. Party B shall inspect the appearance and deformation of the raw materials provided by Party A, and shall not conduct other inspections. If the raw materials do not meet the requirements or the quantity is insufficient, Party A shall be informed immediately. If there is no objection, it shall be deemed that Party A has provided the raw materials that meet the requirements.
4. Party B shall take good care of the raw materials, equipment, packaging materials and other articles provided by Party A, and pay the corresponding losses if they are damaged or lost.
Article 7 Labor remuneration
1. The transaction price of Party A and Party B shall be settled as follows:
The prices of other special products shall be confirmed by both parties through negotiation and written signature.
2. Payment method: settle the payable amount of this month on _ _ _ _ _ every month. Pay the salary of the previous _ _ _ _ month on _ _ _ days every month.
If there is any delay, both parties shall settle it through consultation.
Article 8 Labor protection
1. Party B shall arrange all matters for its employees.
2. Party B shall be responsible for the industrial and commercial accidents or other disputes caused by the employees employed by Party B to produce the products processed with nail plates, and Party A shall not bear any responsibility.
Article 9 Liability for breach of contract
1. Both parties must abide by the above terms and conditions. Violators shall be punished according to the terms agreed in this agreement, and matters not covered shall be agreed by both parties separately.
Second, the principle of penalty for breach of contract: the breaching party unconditionally compensates the other party for the direct and related losses caused by breach of contract.
Article 10 Force Majeure Clause
1. In case of breach of contract caused by force majeure factors, such as natural disasters, wars, national policies, both parties shall not pursue each other and bear corresponding losses.
Article 1 1 Arbitration principle
1. In case of any dispute during the execution of this agreement, including purchase orders and other relevant annexes, both parties shall settle it through consultation. If negotiation fails, the notifying party can submit it to the local arbitration conference for arbitration.
2. The arbitration principle is based on this agreement and its annexes, and shall be implemented in accordance with the contract.
Article 12 Validity of the Agreement
1. This agreement shall come into effect as of the date of signature by both parties, and the validity period of the agreement shall be _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 13 Others
1. If there are any matters not covered in this agreement, both parties can negotiate separately and make supplementary amendments on the basis of consensus.
2. This agreement is made in duplicate, each party holds one copy, which has the same legal effect.
Party A (seal): _ _ _ _ _ _ _ _ _ Party B (seal): _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ _ _ _ _ _ Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date: _ _ _ _ _ _ _ _ Date: _ _ _ _ _ _ _ _ _ Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
;