Patent disclosure in wallpaper printing industry

Engineering Contract Both parties to this contract: the Employer (hereinafter referred to as Party A): the Contractor (hereinafter referred to as Party B): Address: Address: ID number: ID number: Tel: Tel: In accordance with the Economic Contract Law of the People's Republic of China, the Regulations on Construction and Installation Contracts and other relevant national laws and regulations, combined with the family room decoration regulations, Party A and Party B, on the basis of equality, voluntariness, mutual benefit and consensus, Project overview: 1, project address: 2. See the decoration design construction drawing for details of the project content and process. 3. Project contracting method: Party B contracts the project decoration (see the catalogue of interior decoration projects). 4. Total contract price: in words: 5 yuan. Party A is responsible for purchasing engineering materials. 6. Party B's labor service fee shall be paid by Party A in installments according to the contract price of the project: (1) Payment time: construction date; (3) Payment time: hydropower project and civil decoration are completed; (5) Payment time: After the woodworking project is completed, Party A is qualified; (7) Payment time: carpentry paint is completed and Party A's acceptance is qualified. 7. The quality deposit paid by Party B to Party A for this project is RMB, in words. 8. The construction period is days, the commencement date is year month day, the completion date is year month day, and every Thursday is the appropriation day. Party B's funds must be allocated on the specified date, otherwise Party A has the right to refuse. 2. Party A's work 1, the designer's design and construction drawings, and the size and text shall be clearly marked; 2. Party A is responsible for design consultation and technical disclosure, and communicates with Party B; 3. According to the actual situation of the project, Party A can arrange an excellent project manager as the person in charge of the project site to conduct unified scheduling and command of the project. In order to better ensure the progress and quality of the project, Party B shall adopt and implement the rationalization suggestions put forward by Party A at the construction site, otherwise, Party A has the right to deal with Party B; 4. Party A shall create entry conditions for Party B two days before Party B enters the site, and pay the living expenses in advance; 5. Party A has the right to strictly supervise the project quality and construction progress of Party B.. Party A has the right to punish those who are not conducive to the progress of the project or whose quality is unqualified. If the circumstances are serious, Party A has the right to terminate the contract and impose penalties according to relevant regulations. 6. In order to ensure the smooth progress of the project, Party A shall cooperate closely with Party B; 7. Other work related to Party A. III. Work of Party B 1. Be familiar with the construction drawings carefully, clarify their specific practices, find and raise problems, and submit them to the designers for modification or clarification, so as to obtain a perfect construction drawing, and keep in touch with the designers of Party A at any time to fully understand their design intentions and reduce the occurrence of unnecessary changes. For unsigned construction drawings, Party A has the right to refuse Party B's construction. 2. Carefully review Party A's budget quotation, make clear the quantity, unit price and total contract amount of each item, and then sign the project contract on the premise that Party A and Party B have no objection to the quantity and price of the contracted project. 3, organize construction personnel, clear time limit for a project arrangement, admission on schedule. 4, to carry out the specific list of construction personnel, put forward specific construction requirements, construction team leader for five people, timely reflect all problems related to the project cost, especially the design changes or new projects. 6, civilized language, cooperate closely with each other, keep the construction site orderly, save costs, safe and efficient. 7. The person in charge of Party B keeps close contact with Party A and listens to Party A's opinions and requirements carefully; 8. Strictly implement the construction specifications, safety operation specifications, fire safety regulations and environmental protection regulations. Organize the construction according to the requirements, ensure the quality and quantity, complete the contract objectives on schedule, and solve all matters that Party B is responsible for. Each construction team shall be responsible for the engineering quality within the scope of its construction, which shall be implemented in person. 9, the project manager completes the site engineering quality inspection records. Participate in the completion acceptance, handle the completion data, as-built drawings, change fee visa, completed quantities and final accounts (project increase or decrease, practice change), and submit them to Party A after improvement, so as to provide a basis for the preparation of project settlement for inspection. 10. The project manager shall verify the quality of materials provided by Party A and make good suggestions on the use of materials. 1 1. Abide by the national or local governments, relevant government departments and property management departments on construction, do a good job in construction site protection and garbage collection, and deal with the problem of construction disturbance and the relationship with surrounding residents. 12. Party B must cooperate with the installation of air conditioners and furniture provided by Party A and the pipeline installation project undertaken by Party A. Before the project is completed and handed over, Party B is responsible for protecting all facilities and finished products on site. 13. Party B shall cooperate with Party A to go through the renovation procedures stipulated by the property management department, pay the renovation deposit and apply for a temporary work permit. Four. If the project changes need to change the project and practice, Party B must take the initiative to apply for a fee visa and work order from Party A, and Party A can only start work after issuing the design changes and recording the change fees in the project settlement. V. Liability for breach of contract and arbitration 1. If Party B delays the construction period due to its own reasons, all the increased labor costs shall be borne by Party B. 2. If the construction period is affected by force majeure factors such as engineering change or water stoppage and power outage, the construction period will be postponed. 3. After the contract comes into effect, Party B shall not subcontract the contract works to others in any form, otherwise, Party A will be fined 65,438+00% of the total contract amount. 4. If either party fails to perform the contract or violates national laws and regulations, causing economic losses to the other party, the responsible party shall bear the responsibility and pay 65,438+00% of the contract price to the other party as compensation. The party causing heavy losses may apply for arbitration. 5. If the contract can't be continued due to the reasons of either party, that party shall notify the other party in time and handle the contract termination procedures, and the responsible party shall compensate the other party for the corresponding losses. 6. If Party A fails to pay the project progress payment on time and pays the liquidated damages 100 yuan/day for more than 3 days, Party B shall bear the liquidated damages 1000 yuan for the unqualified project quality after the second rectification. 7. As Party B fails to complete the project on time, it will be fined 100 yuan for each day of delay. 8. In case of any dispute during the execution of the contract, if both parties fail to reach an agreement through negotiation, they may apply to the following authorities for arbitration: (1) the competent authority of the industry where the project is located; (2) The arbitration commission where the project is located; (3) The people's court where the project is located. Engineering quality and acceptance of intransitive verbs 1. This project is in strict accordance with the national construction and acceptance standards such as Code for Construction and Acceptance of Building Decoration Engineering (JGJ73-9 1) and Unified Standard for Quality Inspection and Evaluation of Building Installation Engineering (GBJ300-88), combined with the quality inspection standards issued by our company. 2. Party B shall notify Party A of the inspection and acceptance of concealed works and intermediate works in stages. 3. Acceptance grade of project quality: qualified. Seven. Material supply 1. Party B shall list the required engineering materials according to the design and construction drawings provided by Party A, indicating the type, model, quantity and delivery time of the required materials, and submit them to Party A three days before the construction site, so that Party A can purchase the materials. If Party A fails to supply the engineering materials in time due to Party B's failure to provide the engineering materials list on time, Party B shall bear the corresponding responsibilities and losses. 2. Party A is responsible for purchasing and supplying engineering materials according to the list of engineering materials provided by Party B, and supplying them to the site according to the progress of the project. Eight. During the period of safe production, civilized construction and fire fighting construction, Party B shall strictly abide by relevant laws and regulations, such as Technical Regulations for Safety in Building and Installation Engineering, Rules for Safe Operation of Workers in Building and Installation Engineering, People's Republic of China (PRC) Fire Protection Regulations and Chongqing Civilized Construction Standards for Construction Sites. If Party B violates the above-mentioned laws and regulations in the process of construction and production, Party B shall bear the responsibilities and all economic losses caused thereby. 1. All site construction personnel of Party B must have a clear and definite history. It is strictly forbidden to employ female workers, children under 16 and sick people, and register their identity cards by themselves. 2. Party B shall be responsible for handling diseases, injuries, disabilities and death accidents that occur during construction and production. 3. If unsafe factors are found in the construction and production, Party B shall report to Party A in time, and the construction can be continued only after rectification, and rectification is not allowed without authorization. 4. The plumber employed by Party B must have a job license and qualification certificate, otherwise it will not be requisitioned. It is forbidden to use unlicensed personnel, and offenders will be fined 200 yuan/person. Nine. Other matters 1. During the construction process, Party B dismantled and changed the original structure, various equipment management and waterproof layer of the building without the consent of Party A or the approval of relevant departments, and the responsibilities, losses or accidents (including fines) caused thereby shall be borne by Party B. 2. Party B must be equipped with complete electric tools and other tools needed for the project, and strictly regulate the operation of electric tools. 3. Party B shall restrain all construction personnel by itself, and Party A shall be responsible for any influence caused by improper words and deeds. 4. During the construction period, Party A's (owner's) articles (furniture, sanitary ware, electrical appliances, etc. ) It is strictly prohibited to use, and the accident losses caused by Party B's illegal operation shall be borne by Party B. X. Warranty 1, decoration construction design and construction drawings signed by Party A and Party B, Party A's visa form and other engineering contents and related supporting civil works. 2. Warranty period: free warranty for water and electricity installation for two years, free warranty for decoration for two years, and lifelong maintenance. XI。 Supplementary clauses 1, annexes (subject to the signatures of both parties) (1) Decoration construction drawings (II) Catalogue of interior decoration works (II) This contract shall come into effect after being signed (sealed) by both parties. 3. For matters not covered in this contract, the newly added supplementary clauses shall have the same legal effect as this contract after negotiation by both parties. 4. This contract is made in duplicate, each party holds one copy, and it will automatically terminate after the contract is fulfilled. Signature of the Employer (Party A): Signature of the Contractor (Party B): Attachment 1: Catalogue of Interior Decoration Works 1. Top surface engineering 1, corridor ceiling, as shown in figure 2, dining room ceiling, as shown in figure 3, living room ceiling, as shown in figure 4, kitchen and bathroom gusset ceiling 5, top putty plastering 6, top latex paint 2, wood 1, door and window cover 2, big bag, small bedroom, kitchen door 3, stone, table top installation 4, shoe cabinet 5 and wine cabinet 6. As shown in Figure 8, the cabinet of the laundry tank III, wall project 1, wall putty plastering 2, wall hand-painted latex paint 3, new brick wall 4, kitchen, bathroom, life balcony wall tile 5, living room TV wall as shown in Figure 6, wall opening technology treatment 7, wall wallpaper pasting as shown in Figure 1 kloc-0/,living room and dining room wall decoration modeling as shown in Figure 4, ground project/kloc. High-grade floor tiles are attached to the living room, 2. The skirting line 3. The kitchen, bathroom and balcony are treated with secondary waterproofing, 4. Anti-skid floor tiles are attached to the kitchen and bathroom, 5. Floor tiles are attached to the balcony, and the bedrooms are leveled. 7. Floor mat 8. Renovation of PVC sewage in kitchen and bathroom 5. Water and electricity engineering: 1. Installation of kitchen and bathroom sanitary wares, valves and faucets, 2. Install the manufacturer's packaging, 3. Installation of indoor lamps, switches and sockets. 4. In addition to installing the manufacturer's packaging. 5. Water pipe assembly. 6. Other hydropower projects not completed by Party A.. Handyman works 1, bricklayer's trunking, water pipe trough, etc. 2. Masons demolish walls and dig. Note: The above items have been listed in the construction drawing, which will serve as the construction basis together with the construction drawing. Except those marked as outsourced, the construction drawings shall be included in the above projects. Items not indicated in this table shall be subject to the construction drawing. If the project is increased or decreased according to the construction drawing, the cost shall be calculated separately.