Part 1:
1. The for-profit legal person is registered and established according to law, and the date of issuance of the business license is the date of establishment of the business legal person.
2. The establishment, alteration, transfer and extinction of the real right of immovable property shall be registered in accordance with the law, and shall take effect when it is recorded in the real estate register; The establishment and transfer of the real right of movable property shall take effect upon delivery, except as otherwise provided by law.
2. The term of the invention patent right is 20 years, and the term of the utility model patent right and the design patent right is 10 years, counting from the date of application; The period of validity of a registered trademark is 10 years, counting from the date of approval of registration.
3. If the guarantor of joint and several liability guarantee and the creditor have not agreed on the guarantee period, the creditor has the right to ask the guarantor to assume the guarantee responsibility within 6 months from the date of expiration of the independent debt performance period.
3. The insurance liability for all risks of construction projects begins when the insurance project starts at the construction site or the materials and equipment used for the insurance project arrive at the construction site, and ends when the project owner issues the completion acceptance certificate or passes the acceptance of part or all of the project, or the project owner actually occupies or uses or receives part or all of the project, whichever comes first.
4, the construction unit shall start within 3 months from the date of receiving the construction permit. If the project cannot be started on schedule for some reason, it shall apply to the issuing authority for an extension; The extension is limited to two times, each time not exceeding 3 months.
5, the implementation of the construction project commencement report system, for some reason can't start on schedule for more than 6 months, it shall re apply for approval of the commencement report.
6, the construction enterprise qualification certificate is valid for 5 years. After the expiration of the validity period of the qualification certificate, if the enterprise needs to extend the validity period of the qualification certificate, it shall apply to the original qualification licensing authority for extension 3 months before the expiration of the validity period of the qualification certificate.
7. If the tenderee makes necessary clarifications or amendments to the issued tender documents, it shall notify all recipients of the tender documents in writing at least 05 days before the deadline for submission of tender documents required by the tender documents.
8. The project subject to tender according to law shall be no less than 20 days from the date when the tender documents are issued to the deadline when the bidder submits the tender documents. The validity of the bid shall be calculated from the deadline for submitting the bid documents.
9. The time for submitting pre-qualification application documents for projects that must be subject to tender according to law shall not be less than 5 days from the date when the pre-qualification documents stop selling.
10, the tenderer and the winning bidder shall conclude a written contract in accordance with the tender documents and the bidding documents of the winning bidder within 30 days from the date of issuance of the bid-winning notice.
The second part:
1. If the bidder withdraws the submitted bid documents and the tenderee has collected the bid bond, it shall return it within 5 days from the date of receiving the written withdrawal notice from the bidder.
2. For a project subject to tender according to law, the tenderer shall publicize the successful candidate within 3 days from the date of receiving the bid evaluation report, and the publicity period shall not be less than 3 days.
3. Bidders or other interested parties who have objections to the bid evaluation results of projects that must be subject to tender according to law shall raise them within the publicity period of the successful candidate. The tenderer shall make a reply within 3 days from the date of receiving the objection; Before giving a reply, the tendering and bidding activities shall be suspended.
4. The performance bond shall not exceed 10% of the winning contract amount.
5. Bidders or other interested parties may complain to the relevant administrative supervision departments within 10 days from the date when they know or should know that the bidding activities do not conform to the provisions of laws and administrative regulations. The administrative supervision department shall decide whether to accept or not within 3 working days from the date of receiving the complaint, and make a written decision within 30 working days from the date of accepting the complaint.
6, the construction market integrity behavior record information published within 7 days after the decision of administrative punishment, the publication period is generally 6 months to 3 years; The information disclosure period of good behavior records is generally 3 years. The minimum time limit for releasing bad behavior record information shall not be less than 3 months.
7. If the parties dispute the actual completion date of the construction project, it shall be handled as follows: (1) If the construction project has passed the completion acceptance, the completion acceptance date shall be the completion date; (2) If the contractor has submitted the completion acceptance report and the Employer delays the acceptance, the date when the contractor submits the acceptance report shall be the completion date; (3) If the construction project is used by the Employer without completion acceptance, the date of transfer of possession of the construction project shall be the completion date.
8. If the parties have not agreed on the payment time or the agreement is unclear, the following time shall be regarded as the payment time: (1) If the construction project has been actually delivered, it shall be the delivery date; (2) if the construction project is not delivered for use, the date of submission of the completion settlement document; (3) If the construction project has not been delivered and the project price has not been settled, the date when the parties file a lawsuit.
9. The limitation period for applying for labor dispute arbitration is one year. The limitation period for arbitration shall be counted from the date when the parties know or should know that their rights have been infringed. If a party to a labor dispute refuses to accept the arbitration award, it may bring a lawsuit to the people's court within 15 days from the date of receiving the arbitration award.
10. If mechanical equipment is used in the urban construction process, which may cause environmental noise pollution, the construction unit must declare the project name, construction site and construction period, possible environmental noise value and environmental noise pollution prevention measures to the competent administrative department of environmental protection of the local people's government at or above the county level before the project starts 15.
The third part:
1. The safety production license is valid for 3 years. If the expiration of the safety production license needs to be extended, the enterprise shall go through the extension formalities with the original safety production license issuing management authority 3 months before the expiration.
2. If a construction enterprise changes its name, address and legal representative, it shall, within 10 days from the date of change, go through the formalities of safety production license with the original safety production license issuing management authority.
3. The construction unit shall, when receiving the construction permit, provide relevant information on the safety construction measures of the construction project, and approve the construction project to have the commencement report according to law. The construction unit shall, within 5 days from the date of approval of the commencement report/kloc-0, submit the measures to ensure safe construction to the construction administrative department of the local people's government at or above the county level or other relevant departments for the record.
4, the construction unit shall, within 3 months after the completion of the project acceptance, submit a set of construction project files to the urban construction archives.
5. The fire control institution of the public security organ shall organize fire control acceptance within 20 days from the date of accepting the application for fire control acceptance, and issue opinions on fire control acceptance.
6, the project quality supervision institutions shall, within 5 days from the date of project completion and acceptance, submit the project quality supervision report to the filing authority.
7. Under normal use conditions, the minimum warranty period of the construction project is: (1) the foundation project, foundation project and main structure project of the building, that is, the reasonable service life of the project specified in the design documents; (2) Roof waterproofing works, the leakage prevention of bathrooms, rooms and external walls with waterproof requirements, is 5 years; (3) The heating and cooling system consists of two heating periods and cooling periods; (4) Installation and decoration of electrical pipelines, water supply and drainage pipelines and equipment, with a construction period of 2 years.
8. The defect liability period starts from the date when the project passes the completion acceptance. If the project cannot be completed and accepted within the specified time limit due to the contractor's reasons, the defect liability period shall be calculated from the date when the project actually passes the completion acceptance. If the project cannot be completed and accepted within the specified time limit due to the reasons of the Employer, the project will automatically enter the defect liability period 90 days after the contractor submits the completion acceptance report.
9. The employer shall reserve the deposit in the way agreed in the contract, and the total proportion of the reserved deposit shall not be higher than 3% of the total settlement amount of the project price.
10, the limitation period of ordinary litigation is usually 3 years. The period of limitation of action shall be counted from the day when you know or should know that your rights have been damaged. However, if more than 20 years have passed since the right was violated, the court will not protect it; Under special circumstances, the people's court may decide to extend the time limit upon the application of the obligee.
The above is the "Digital Test Site of the Age of Engineering Laws and Regulations for Second-Class Builders" brought by Bian Xiao. If you want to know other relevant information about the test center of the second-level constructor. Pay attention to Bian Xiao's timely push.