Finely decorated houses are a means used by many real estate developers to attract customers. When the owner signs a house purchase contract, a decoration contract for a furnished house will be presented. So how to write a decoration contract for a furnished house? Below we will bring you a detailed sample of the hardcover house decoration contract, we hope it will be helpful to you.
______Fine Decoration Contract Template
Party A: _______ Real Estate Development Co., Ltd. (hereinafter referred to as Party A)
Party B: _________________________ (hereinafter referred to as Party B) )
According to the "Contract Law of the People's Republic of China", the "Construction Law of the People's Republic of China" and related laws and regulations and in combination with the "Tender Documents" 》Relevant content and actual situation, Party A agrees to contract the "_______ fine decoration and renovation project to Party B for construction. In order to clarify the rights and obligations of both parties and ensure that the project is completed on time and with high quality, both parties reached an agreement and signed it after consultation This contract.
1. Project Overview
1. Project Name: _______ Fine Decoration and Renovation Project
2. Project Address: ____________________________________
3. Project structure: frame shear wall structure
4. Building area: _______________ square meters
5. Project quality: ensure 100% one-time acceptance pass rate, quality Achieve excellent quality.
6. Construction unit: _______ Real Estate Development Co., Ltd.
2. Project contracting method
Take labor, materials, machinery, The contract shall be contracted in the form of time limit, quality, civilized construction, security, security and finished product protection.
3. Project Contracting Scope: According to the construction drawings. All items in the _______ fine decoration and renovation project shown
IV. Party B’s contracting indicators
1. Construction period: _______ days
2. Project Quality: Ensure that the one-time acceptance rate is 100% and the quality is excellent.
3. Safety production:
3.1 Strictly implement the relevant regulations of local government industry management and Party A's regulations. system;
3.2 Prevent casualties;
3.3 No major mechanical equipment accidents and major fire accidents;
3.4 Any safety hazards that occur due to Party B’s fault during the construction process In the event of an accident, Party B shall bear all responsibilities and losses;
4. Civilized construction: in line with the requirements of _______ municipal standard construction sites;
5. Technical information: timely and Accurately and completely file the files, and be responsible for organizing the project completion archives in accordance with government industry regulations and submitting them to Party A for unified filing.
6 Applicable specifications:
A. Construction of electrical engineering projects. Quality acceptance specifications; B. Construction and acceptance specifications for building ground projects; C. Quality acceptance specifications for building water supply, drainage and heating projects; D. Construction project management specifications; E. Construction project document archiving regulations; F. All others apply to this article Current standard specifications, procedures, and regulations for the project.
5. Contract Duration
1. Construction Period: The start date is _____ year ___ month ___ day; the total construction period is _____ calendar days (including The project will be completed during public holidays and bad weather) or within the period extended in accordance with the terms of the contract documents.
2. If Party B is unable to complete the project within the time stipulated in the contract, Party B shall be liable for breach of contract and shall pay liquidated damages to Party A; if there is an additional project or delay caused by the contract issuing party, the contract issuing party shall be actually hindered. Written notification of postponement.
If after all the extension notices plus the completion date listed above, the project still cannot be completed on time, compensation will be paid at 50,000% of the contract amount for each day of delay; Party A may deduct this compensation from any amount payable to Party B or other means to recover this amount. The payment of this compensation does not relieve the contractor of its responsibility to complete the project or other responsibilities stipulated in the contract.
3. Party B must organize production according to the "Construction Organization Design" approved by Party A, participate in regular production meetings organized by Party A, and complete construction tasks on time or in advance according to Party A's schedule requirements, and accept Party A's Inspection and supervision of progress. When the actual progress of the project is inconsistent with the confirmed progress, Party B shall propose corrective measures according to Party A's requirements, which shall be implemented after Party A's confirmation.
VI. Quality Standards
1. Quality objectives: The first-time acceptance pass rate reaches the standard of 100; the quality reaches excellent; projects without acceptance standards must achieve results that are satisfactory to Party A and the designer.
2. If the quality of the project fails to meet the above requirements, the contractor will deduct the performance bond and directly deduct it from the settlement price of the project, and must unconditionally rework it to the quality and satisfaction of Party A and the designer. If after rework If you still fail to meet the requirements, you will bear all losses caused thereby.
3. Party B shall be responsible for the quality assurance of its construction projects. The quality assurance content covers all construction quality issues related to the decoration and renovation projects.
4. The quality warranty period is two years. During the warranty period, Party B should send someone to repair it within 24 hours after receiving the warranty notice. Otherwise, Party A can entrust a third party to repair it, and the costs incurred will be borne by Party B. Party A deducts it from the warranty fee, and the shortfall can be regarded as a debt and claimed from Party B.
5. The warranty deposit is in the nature of a performance bond and does not include interest.
7. Contract Price
1. This contract is contracted on a lump sum basis, and the total lump sum price of the contract is _______ yuan (_______ yuan).
2. The construction project business tax shall be borne by Party A. Party A shall provide Party B with a tax exemption certificate, and Party B shall provide an official project invoice.
3. The above price includes the labor costs required to complete the project (including overtime, rush work, etc.), material costs, machinery costs (including entry and exit fees), vertical transportation fees, and fees paid to government departments. , certification fees, insurance premiums, work-related injury medical fees, sewage fees, garbage removal fees, cleaning fees inside and outside the site, safe and civilized construction fees, coordination fees for surrounding residents, on-site seedling protection fees, urban pipe network and pipeline protection fees in and around the site , remedial measures fees, risk fees, management fees and other unforeseen expenses and other expenses.
4. This contract includes all decoration and renovation projects in the drawings.
5. Confirmation of project quantity:
① The total lump sum price has fully considered the increase in Party B’s workload and materials due to quality deviations in the construction of the main structure. Some visa procedures will not be processed and additional fees will be charged.
② If there are design changes, technical approval orders, work contact orders (all need to be confirmed by the design institute), and Party A’s work instructions, Party B must report the changes that occurred this month before the 25th of each month. The budget is submitted to Party A. Party A will review the budget as agreed in the contract within 5 days after receiving it, and notify Party B to confirm the project quantity within 24 hours after verification. The project quantity and budget confirmed by both parties will be increased. Within the total final settlement price, Party A will not approve the submission if it is not submitted within the time limit.
③ If there is an additional project site visa form (which must be signed and confirmed by the project manager), Party B must submit the visa form and budget for this month to Party A before the 25th of each month. Party B shall complete the review within 30 days after receiving the budget as agreed in the contract, and notify Party B to confirm the project quantity within 24 hours after verification. The project quantity and budget confirmed by both parties will be added to the final total settlement price. If reported to Party A, Party A will not recognize it.
④ Party A will not approve Party B’s work quantity that exceeds the scope of the design drawings and causes rework due to the contractor’s reasons.
⑤ If Party B does not participate in the verification of project quantities and pricing within 5 days after receiving the notice, the final result shall be the project quantities and pricing results verified by Party A.
⑥The approval of visa and change project quantities shall be subject to the final approval of Party A. Party B shall assist Party A in processing visa and change.
⑦The contractor has the right to arrange the project quantity of the winning bidder based on the project situation and the capacity of the construction unit; after winning the bid, if the construction unit cannot start work on time to ensure the construction period and meet the construction quality requirements, etc., the contractor will make adjustments at any time The construction unit's construction work quantity may be withdrawn from the construction unit, and the resulting losses shall be borne by the construction unit.
4. The water and electricity bills required for construction shall be paid in advance by Party A; they will be deducted through negotiation between both parties during settlement; however, there will be penalties for wasting electricity on site. Party B shall be responsible for the water and electricity expenses required for accommodation and daily life; if provided by Party A, Party B shall pay relevant expenses according to Party A's regulations.
5. The total lump sum price shall fully consider all possible impacts on Party B's construction and increase in workload due to connection and cross-construction with other professional types of work and contractors.
6. Party B is responsible for the repair work of wall grooves and holes caused by the mechanical and electrical contractor within its own construction area. This cost is included in the total package price.
8. Payment method
1. Party A will not pay any relevant advance payment, material preparation payment, workers’ living expenses and deposit, etc. for this project;
2. After the completion of the project and Party A's acceptance, payment will be made to RMB 85; after Party A's audit, the total price will be paid to RMB 95, leaving a warranty deposit of RMB 5 to be paid within one month after the expiration of the warranty period.
3. Party B will be responsible for repaying all claims and debts incurred by Party B during the implementation of this project, and Party A does not bear any responsibility.
4. Any increase or decrease in the contract price due to changes shall be borne by Party A; the delayed construction period will not be extended unless major design changes occur (subject to the determination of the tenderer or engineer). postponed.
9. Construction Safety
1. Party B shall abide by the relevant management regulations on safety production in engineering construction, organize construction in strict accordance with standardized construction site standards, and accept industry safety inspection personnel and Party A at any time Supervision and inspection shall be carried out in accordance with the law, and necessary safety precautions shall be taken to eliminate hidden dangers of accidents. Party B shall be responsible for any accident liability and resulting expenses caused by Party B's failure to comply with safety rules and regulations or ineffective measures.
2. Party B, with the cooperation of Party B’s on-site safety management personnel, shall conduct safety education for all workers at its construction site and establish corresponding information. Party B shall not allow personnel who have not received safety education to enter the construction site. , Party A shall not require Party B to carry out construction in violation of safety management regulations. For safety accidents caused by Party A, Party A shall bear the corresponding responsibilities and related expenses.
3. If a major safety accident or other safety accident occurs to Party B’s personnel, both parties shall try their best to rescue and protect the scene. Party B shall conduct investigation and appraisal according to relevant departments. After the casualty accident is determined to be Party B's responsibility or the accident occurs due to Party B's illegal operation, Party B will provide financial compensation to the injured workers or their families in accordance with national regulations. Party A does not bear any economic and administrative legal responsibility, but Party A should actively assist Party B to do a good job Aftercare work; for casualties that are caused by Party A's responsibility, in addition to dealing with those responsible in accordance with regulations, Party A will provide financial compensation to Party B's injured employees or their families in accordance with relevant national regulations, but the specific aftermath work will be arranged and handled by Party B. Party B will not directly deal with Party B’s employees or family members.
4. Party B shall, at its own expense, provide and maintain all lights, guards, fences, warning signals and watches at the time and place required, or in accordance with the requirements or regulations of the relevant authorities, as well as protect the project or provide services to the public. Provide security and convenience.
5. Party B should have full-time safety production management personnel and prepare special safety construction plans for sub-projects with greater risks.
6. Party B shall take all reasonable measures to protect the environment near the site during the implementation of the contract to avoid damage or obstruction to the public or public property caused by pollution, noise and other factors caused by its construction.
7. When unavoidable pollution and noise caused by Party B's responsibility need to be dealt with, Party B shall propose a plan and submit it to the engineer for approval before implementation, and Party B shall bear the costs incurred.
8. Party B must pay a safety management deposit of RMB 20,000 in accordance with Party A’s on-site safety management regulations. If Party B's on-site management and operating personnel violate safety management regulations, Party B must accept the management and punishment of Party A's on-site safety management personnel, and the fines will be deducted from the safety management deposit. If the deposit is insufficient, additional payment will be required.
9. Prevent casualties; there will be no major mechanical equipment accidents or major fire accidents.
10. Civilized Construction
1. Party B shall organize construction according to the standards of standardized construction sites and civilized construction sites to ensure that the construction site is a municipal standardized construction site and a municipal civilized construction site. If Party A, If the supervision and relevant government departments fail to meet the standards when inspecting civilized construction, Party B shall bear the fines caused by its own reasons.
2. The contract signed by Party A and Party B for the project shall be reported to the Municipal Construction Management Office for registration and relevant procedures shall be completed.
3. Before entering the site, Party B must provide a roster of employees, with copies of the employees’ ID cards, temporary residence permits (original), work unit record certificates (original), and special operation personnel employment certificates (original) , and pay industry-related fees on time (including changes in Party B’s personnel, which must be reported to Party A in a timely manner. Party B will be responsible for fines and other related expenses caused by irregular labor employment.
4. Party B shall comply with Party A’s requirements Full-time personnel such as the general person in charge of the site, technicians, quality and safety officers, material technicians, construction workers, logistics, and electricians must be equipped for independent management. The corresponding personnel have corresponding employment certificates and the actual management complies with the general contractor's standards to ensure this contract. Fulfillment.
5. Party B should strengthen the management of labor fee distribution to avoid the occurrence of labor disputes.
6. Party A must abide by the rules and regulations, and no gambling or gambling shall occur. In case of fighting or other disciplinary violations, Party B shall use healthy male citizens over 18 years old and under 50 years old in this project, and shall not use outsiders or employees of Party A's unit. If this occurs, Party B shall be responsible for all consequences.
7. The company provides housing and a place for workers to eat, but the construction unit must obey the company's unified arrangements and management. Party B's accommodation personnel must observe dormitory hygiene and must not damage public items in the dormitory. Party B's accommodation area must be kept clean and tidy. The wages of personnel are arranged by Party B.
8. Party B is not allowed to bring family members or children to the construction site for accommodation. All employees must eat in the canteen and are not allowed to use electric stoves, rice cookers, electric woks, and kerosene stoves in the dormitories. Waiting for cooking tools.
9. During the construction process, personnel should be arranged to clean up the supporting shelves and formwork on each floor immediately until Party A passes the inspection.
10. Party B. On-site personnel accommodation and office location shall be provided by Party A.
11. Materials and equipment management
1. Control of materials purchased by Party B:
A. The material brands are purchased according to the first-line brand standards.
B. They conform to the types and standards specified in the contract documents.
C. Party B must obtain Party A’s approval before using its own materials. Before ordering bulk materials, Party B must provide free samples for approval purposes.
D. Party B must keep the samples approved by the contractor at the construction site as a standard for acceptance of the project.
E. Party A's approval of any sample will not relieve Party B of its responsibilities under the contract.
F. If the materials or technology originally specified are in short supply or time is tight or unavailable. For better options, Party B can submit suggestions for alternative materials or technologies to the contractor for consideration. The contractor has the absolute right to approve or disapprove the alternative suggestions before they are approved. Approved suggestions cannot increase costs. Any approval or disapproval by the Contractor will not relieve the Contractor of its responsibilities under the Contract Documents unless it is accepted at the time of approval.
G. The original or additional project price should include any royalties related to any patented products, processes or inventions. If Party B infringes or is suspected of infringing the patent rights of any article, process or invention, causing Party A to suffer claims, litigation, compensation costs and expenses, Party B shall compensate it.
H. Party A does not consider the loss of Party B’s self-supplied materials and the loss of labor and materials caused by segmented construction. Party B has considered and included it in the unit price, and shall not use any excuse to ask for compensation or work-by-point calculation. .
2. Party B is responsible for the safety and security of the site.
3. The materials, machinery and equipment entering the site shall be managed by Party B by itself.
4. Party B will assign a certified electrician to be responsible for on-site electrical work outside the secondary box (including on-site duty for switch line maintenance, lighting, and maintenance).
5. The inspection costs of various materials shall be borne by Party B.
6. Party B is responsible for the transfer of various materials within the construction site (including horizontal transportation and vertical transportation), and they shall be classified and stacked according to the construction site layout plan to keep the construction site clean and civilized and the roads smooth.
7. During the construction process, Party B will be responsible for any material loss caused by rework caused by Party B.
12. Rights and Obligations of both Parties
(1) Rights and Obligations of Party A
1. Party A entrusts Comrade ______ to review this Subcontract "" is responsible for the comprehensive implementation of supervision, and comprehensive and whole-process support, service, supervision, management, coordination and control of Party B's performance of the contract.
2. Party A is responsible for handling various approvals and certificates for construction in ____ City, and Party B shall bear the costs.
3. Inspect and urge Party B to do a good job in project quality, safety production, civilized construction, comprehensive management, standard implementation and other management work in accordance with the relevant regulations of the country and ____ city, so as to achieve the goal of corporate brand name.
4. Review the construction organization design prepared by Party B, participate in the discussion and implementation of major technical issues during the construction process; have the final approval authority for the construction plan and construction sequence of the project.
5. Participate in the handling of safety and quality accidents. The costs of accident handling shall be borne by Party B; monitor the construction progress, help Party B achieve the predetermined plan goals, and collect project progress payments from the owner on time. Control the rational use of funds to ensure the smooth progress of the project.
6. When Party B is at the construction site, the water and electricity costs consumed by the project will be deducted at the time of settlement based on the quota.
7. Party A handles project progress payments and project final payments in a timely manner, and allocates project funds in a timely manner.
8. Guide and supervise Party B to make the helmet logo, badge, management system, and image layout, and Party B will bear the expenses incurred.
9. Supply A’s materials according to the materials list, and the actual amount will be deducted when paying for the project.
10. Provide Party B with a set of construction drawings, and provide design modifications and other drawings in a timely manner.
11. If Party A believes that Party B’s construction progress cannot meet the construction period requirements, Party A has the right to allocate part of the workload within Party B’s contract scope and hand it over to other contractors for completion. The project quantity shall be settled and all losses caused thereby shall be borne. Party B shall not raise any objection.
12. Party A has the right to impose various penalties on the projects constructed by Party B due to quality, safety, civilized construction and other factors. Such fines must be signed by the project manager and notified or delivered to Party B’s representative. , Party A’s fine will take effect soon, and its amount will be directly deducted from the verified settlement amount.
(2) Rights and Obligations of Party B
1. Party B entrusts Comrade ______ to be fully responsible for the implementation of this Contract and shall be established according to the scale of the project and the requirements of Party A Strong project management team.
2. Party B has the right to organize independent construction, but it must be carried out under the unified leadership of Party A. According to Party A’s construction schedule, sufficient labor and machinery must be organized to ensure that The project is completed on schedule, otherwise, all impacts and losses caused will be borne by Party B.
3. Party B shall, based on Party A’s requirements and the actual conditions of the construction site, prepare various construction plans in advance and submit them to the project technical department for approval, arrange the construction sequence and cooperation of various types of work, and fully understand the construction site situation and make reasonable arrangements to ensure work efficiency.
4. When the project starts, Party B will provide Party A with a quality and safety officer, who is required to hold a valid certificate to work, and Party A will arrange the work uniformly.
5. During the construction process, if Party B causes the construction sequence and construction parts to be crossed or reversed due to restrictions on construction site conditions or other special requirements, Party B must be responsible for the construction as required, and the costs will not be borne by Party B. Increase; if after the construction of a large area of ??engineering parts is completed, there are still a few scattered parts that are abandoned for construction, Party A will arrange other teams to carry out the construction, and Party B will deduct 3 times the price of the amount payable for this part.
6. Party B must ensure that the construction is carried out according to the drawings.
7. Accept the instructions from Party A and the supervisor regarding safety production, quality, and construction period requirements. Party B will be fully responsible for the economic and legal responsibilities arising from this aspect.
8. Party B is responsible for the family planning management of its own team. Any penalties and fines imposed by any party as a result shall be borne by Party B.
9. Party B shall be responsible for the comprehensive cleaning work inside and outside its construction site and accommodation place according to the relevant requirements of Party A, so as to make it comply with the relevant regulations of ____ City. If Party B is subject to any Any penalties and fines imposed by Party B shall be borne by Party B.
10. Party B is responsible for cooperating with local government departments in various inspections of the labor force to ensure the legality and completeness of its employment procedures. Any penalties and fines imposed by any party as a result shall be borne by Party B bear.
11. During the construction process, Party B encounters temporary additional projects from Party A and the supervisor and requires on-site confirmation. Party B cannot stop the construction because Party A fails to issue the visa in time, otherwise it will be treated as a breach of contract.
12. Party B must register all personnel entering the site according to Party A’s requirements and submit the project for record. At the same time, Party B must provide third-level education to workers entering the site.
13. Party B must apply for insurance and pay insurance premiums for the lives and property of its own personnel and construction machinery and equipment at the construction site.
14. Party B promises to Party A to carry out construction and completion in accordance with the contract and assume the responsibility for project quality warranty within the quality warranty period.
15. During the construction process, all matters involving material sample identification, pricing, and material use must be carried out in accordance with the requirements of the project department.
16. Bear all risks of corresponding construction projects during the performance of the contract.
17. Cooperate with Party A’s instructions on the work of subcontractors and bring them into the management scope of Party B. Any resulting delays in construction period, substandard quality and other losses will be borne by Party B.
13. Other Agreements
1. Party B shall set up management personnel including project managers. The project management team must be no less than 5 people to meet the needs of on-site construction. The list and resume of the established personnel shall be and a copy of the qualification certificate, which shall be reported to Party A for confirmation within one week after the signing of this contract. After Party A’s confirmation, the main management personnel shall not be replaced without Party A’s consent. If Party B replaces the main management personnel confirmed by Party A on its own or Party B fails to replace unqualified management personnel as required by Party A, Party A will impose a penalty of 5,000 yuan per day on Party B.
2. Party B shall not subcontract this project to others in any form. If Party A regards this project as a subcontracted project or Party B subcontracts a special professional construction project to others without the owner's consent, Party A has the right to impose financial penalties on Party B.
3. If Party A is dissatisfied with Party B during the performance of the contract, Party A has the right to unilaterally terminate the subsequent construction contract at any time, and any direct or indirect damage caused to both parties will be borne by Party B. .
4. Any changes to this contract must be stated in writing and signed by all parties to be effective.
14. Project Inspection and Warranty
1. The project meets the conditions for completion acceptance. Party B shall submit complete completion information and completion report to Party A’s representative in accordance with relevant national project completion regulations. At the same time, 3 copies of as-built drawings will be provided to Party A.
2. Party A’s representative shall organize acceptance within 10 days after receiving the completion acceptance report.
3. If the project fails to pass the inspection, Party B will be responsible for repairs and bear all costs. If the quality of the project fails to meet the authorized requirements, all fines and penalties incurred therefrom shall be borne by Party B.
4. After the completion acceptance is passed, both parties should complete the handover procedures within 2 days. Within 2 days after completing the handover procedures, Party B must evacuate the site and hand over all materials to Party A in accordance with the relevant national project completion regulations. Relevant completion information.
5. When the project is completed and accepted and enters the warranty period, Party B shall carry out project warranty according to the warranty scope stipulated in the "Project Quality Warranty Letter". During the warranty period, all expenses and liabilities incurred due to warranty reasons will be borne by Party B. Party B shall bear it.
15. Archives and Information Management
1. Party B needs to provide a complete set of information, including a copy of ID card and a copy of performance information, so that Party A can archive it for future reference.
2. During the construction process, Party B must strictly follow the construction procedures and specifications, prepare concealed acceptance, intermediate acceptance, construction logs and other documents, and assist Party A in preparing completion acceptance documents when the project is completed and accepted. .
3. The relevant information of the project is coordinated by Party B, and Party A compiles and manages it uniformly. If the information is incomplete due to Party B’s fault and it is necessary to contact the relevant departments, the travel expenses and expenses for the connection will be borne by Party B.
4. Party B’s production statistics, financial accounts, labor, equipment and other reports shall be submitted to the responsible departments to establish files.
5. Party B will cooperate with Party A in preparing construction management data, and the final completion data will be compiled by Party A.
16. Breach of Contract and Disputes
1. If there is a breach of contract during the performance of this contract, it shall be enforced in accordance with the relevant laws of the People's Republic of China.
2. If Party B leaves the site midway without Party A’s permission, Party B will be responsible for all losses caused. At the same time, the settlement price of Party B’s completed project will be reduced by 20%.
3. After one party breaches the contract, when the other party requires the breaching party to continue to perform the contract, the breaching party must continue to perform the contract after assuming the above-mentioned liability for breach of contract.
4. If Party B fails to complete the construction in time according to the construction period stipulated in this contract or the construction quality fails to meet the conditions stipulated in this contract or fails to perform other obligations stipulated in this contract, Party A’s representative may notify Party B. According to the terms of the agreement Pay liquidated damages and compensate for the losses caused to Party A due to breach of contract.
5. Both parties A and B agree that the liquidated damages shall be 10% of the final settlement cost of the contract.
6. If any dispute arises during the performance of this contract, the parties shall resolve it through negotiation based on the friendly principle of seeking truth from facts. If negotiation fails, they may apply for arbitration to the arbitration committee where the construction project is located, but must:
① Projects that do not involve arbitration shall proceed as usual;
② Those involving Party B’s withdrawal shall first withdraw before arbitration;
③ Upon completion or expiration of the contract The work should be handed over first and then arbitrated;
④ If Party B refuses to perform the provisions of Article 11, Paragraph 2, ② and ③ of this Agreement in other ways or for any reason, Party A may apply to the arbitration committee (or court) The application shall be executed in advance to eliminate obstacles, and Party B shall be responsible for all losses incurred thereby.
17. Force majeure
1. Force majeure refers to explosions, fires and the following natural disasters caused by war, turmoil, falling flying objects or other reasons that are not Party A’s responsibility. Facts or reasons affecting the project:
(1) Earthquakes with a magnitude of 7 or above on the Richter scale;
(2) Strong winds of magnitude 10 or above issued by the Hubei Provincial Meteorological Observatory for more than 48 consecutive hours Heavy rain;
(3) Rain, snow, flood, etc. declared by the municipal government as natural disasters;
(4) Other reasons of force majeure.
2. After the force majeure event occurs, Party B shall notify Party A immediately and take measures as quickly as possible to reduce losses. If Party A deems it necessary to temporarily stop the construction, Party B shall suspend the construction in the event of force majeure. Within 48 hours after the end of the force majeure event, Party B shall report the damage and losses to Party A; if the force majeure event continues to occur, Party B shall report the damage to Party A every 7 days; within 14 days after the end of the force majeure event, Party B shall submit to Party A the cleanup and repair official reports and related information.
3. The costs and delays caused by force majeure events shall be borne separately according to the following methods:
(1) Party A shall be responsible for the damage to the project itself.
(2) Their units shall be responsible for the casualties of both parties and bear relevant expenses.
(3) The cost of cleaning and repair required for the project shall be borne by Party A.
(4) The delayed construction period will be postponed accordingly.
18. Effectiveness and Termination of the Agreement
1. This Agreement is made in six copies. Party A and Party B each hold three copies, which are equally valid.
2. This agreement shall take effect from the date when representatives of both parties sign and affix their official seals. After the "Project Contracting Agreement" is completed, the project warranty period expires, and various payments are settled, this agreement will automatically termination. Matters not covered in this agreement shall be resolved through negotiation between the parties.
3. Other matters not covered shall be resolved through negotiation between Party A and Party B.
Construction unit: ______ Real Estate Development Co., Ltd. Contracting unit: ____________
Representative: ____________ Representative: ____________
The above is what the editor brings to you How to write a decoration contract for a furnished house? All contents of the hardcover house decoration contract template.