As people’s understanding of the law deepens, contracts appear more and more often. The signing of a contract is the best standard for the rights and obligations between the parties. So what should you pay attention to when drafting a contract? The following is a simple factory building construction contract template (5 general articles) that I compiled for you. I hope it will be helpful to you. Simple factory building construction contract 1
Construction unit (Party A):
Construction unit (Party B):
According to the "Contract Law of the People's Republic of China and the People's Republic of China" 》 and the spirit of relevant laws and regulations. Based on the principle of equality and mutual benefit, Party A and Party B unanimously agreed to sign the contract through friendly consultations.
1. The rights and responsibilities of Party A are as follows:
1. The amount of advance deposit in RMB from the date when Party A and Party B sign the contract: RMB 10,000.
2. Party A is responsible for the procurement and acceptance of materials. Party B will build the factory building without including materials, and will pay according to the progress of the project. (Construction according to the drawings provided by Party B)
3. Party A helps Party B provide workers with convenient accommodation (meal expenses are charged based on actual expenses).
4. Party A requires Party B to complete and deliver the project before December 31, 20xx. If Party B fails to complete the project on time, Party A has the right to require Party B to compensate for the economic losses caused by delayed use and production.
2. The rights and responsibilities of Party B are as follows:
1. Party B takes full responsibility for safety during the construction process, and Party A does not bear any related responsibilities.
2. Party B shall design, manufacture and install according to the incoming sample drawings. If there are any untrue circumstances, Party A has the right to reduce the payment amount and require Party B to re-build until the standards are met.
3. Party B requires construction workers to respect the factory’s employee living system and not make loud noises, gamble, make trouble, litter cigarette butts, etc. in the factory area, and keep the production and living areas safe, hygienic, and clean.
4. Party B shall complete the project and deliver it for use before December 31, 20xx, as specified in the contract between the two parties.
3. Construction Project and Unit Price
1. The curved roof factory building will be constructed according to the drawings confirmed by both parties. If there are changes during the construction process, the unit price will be settled based on the actual quantity after the changes are completed. constant.
2. The quantity is about 20xx square meters, the unit price is 425 square meters/square, and the settlement is based on the actual projected area after completion * the unit price.
IV. Payment method:
1. As agreed upon by both parties, Party A shall pay according to the following table:
2. After the installation is completed, Party A will pay the Before the payment is paid in full, the ownership of the steel structure construction project belongs to Party B.
3. If Party A fails to pay on time, Party B shall have the right to dismantle the construction project 30 days after the due date and all costs shall be paid by Party A, and a fine of 3% of the total contract amount will be imposed for each day overdue. , compensate Party B for all losses.
5. Installation layout and acceptance procedures
1. Production and installation period: After the contract is signed and Party B receives the advance payment, Party B will enter the site for installation and production, and Party A will deliver the goods to Party B Production and installation will be carried out within the second working day after the erection site and electricity are in place; if Party B is unable to perform normal construction due to rain, natural disasters or Party A's factors, the corresponding construction period shall be made up for the corresponding working days.
2. On the day when the installation is completed, Party A shall send a relevant person in charge to cooperate with the person in charge of Party B to handle the relevant acceptance procedures and check the project quantity. If Party A does not send the relevant person in charge to check and accept the project for more than 3 working days and After checking the project quantity, Party B will consider Party A's acknowledgment that the construction of the project constructed by Party B is qualified and the settlement will be based on the project quantity proposed by Party B.
3. The remaining 100,000 yuan will be used as a quality deposit, which will be paid off after half a year of normal use.
VI. Project Quality Standards and Warranty Conditions
1. Party B must bear the safety responsibilities that occur during steel structure construction (except those not caused by Party B); the projects constructed by Party B shall have It must have the ability to withstand external damage. The quality warranty period of the main project is half a year. If any quality problems occur during the warranty period, Party B will always repair them free of charge. If the reason is not Party B, the price will be negotiated separately.
2. Party B is responsible for any damage caused by quality problems of Party B in the steel structure construction project; Party B does not bear any relevant responsibility for damage caused by natural disasters, force majeure, or man-made damage.
7. Matters not covered in this contract shall be supplemented by negotiation between the two parties in the spirit of friendly cooperation. The supplementary agreement shall have the same legal effect as this contract.
8. This contract will come into effect on the date it is signed by both parties. If any dispute arises during the performance of this contract, the two parties will resolve it through negotiation. If the negotiation fails, the dispute will be submitted to the court where Party B is located for settlement.
9. This contract is made in two copies, with Party A and Party B each holding one copy
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________year____month____day______year____month____day Simple factory building contract 2
Contractor: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In accordance with the Contract Law of the People's Republic of China and the People's Republic of China " and the "Construction Law of the People's Republic of China" and other relevant laws, following the principles of equality, voluntariness, fairness and good faith, both parties reached consensus on this construction project and entered into this contract.
1. Project Overview
1. Project name: Phase III factory building of Shiyan Beili Industry and Trade Co., Ltd.
2． Project location: No. 33, Bailang East Road, High-tech Industrial Development Zone, Shiyan City.
3. Project content: The list of the third phase factory buildings (steel structure + civil engineering + decoration) is as follows:
①The sub-items of ground beams, ground and earthwork works.
②The civil engineering quantity above ±0.00 for the exterior wall of the building in the drawings includes: masonry walls and interior and exterior wall decorations for a-d*1, 1-12*a-axis; outdoor water distribution and ramps;
p>
③Except for 12*a-g, g*5-12, 5*d-g, d*1-5 exterior wall enclosures with axis elevations below 4.65 meters in steel structure projects (including color plates, wall beams, etc.) ), everything else shall comply with the scope of drawing requirements and the written drawing review notice submitted by Party A.
2. Construction period
Starting from the third day of signing the contract, the total effective working days of the project are 60 days. The specific construction period is as follows:
① Basic engineering 30 days;
② 15 days for the installation of the main steel structure;
③ 5 days for the installation of the roof and roof drainage system;
④ 10 days for the installation of doors, windows and enclosure systems sky.
⑤ 10 days for other ancillary and finishing works.
Party B must complete the work as scheduled within the agreed construction period. For every day of unreasonable delay, Party B will be fined RMB 1,000, with a maximum penalty of RMB 15,000. If the delay exceeds 15 days, Party A will regard Party B as abandoning the construction and may need to find another unit for construction. The completed project will be settled at 50% of the actual completion amount. In the following circumstances, the extension can be extended with the signature of Party A’s on-site representative:
1. Rain, snow and other weather unsuitable for installation.
2. Spring Festival.
3. Design errors, inaccurate information and project changes proposed by Party A.
4. Construction is suspended due to Party A and third parties.
5. Work consultation that may affect Party A’s normal production.
3. Contract price and payment method
1. Contract price:
The contents of this project contract are lump sum of RMB 850,000 yuan (￥850000.00).
2． Payment method:
Party A pays 30% of the total project price if the total project price is paid in advance; 20% of the total project price is paid after the roof and enclosure system are completed; payment will be made after all finishing projects are completed and accepted. 15% of the total project price; the remaining balance (5% of the total project price) is used as a warranty deposit.
3. Change of project price: For new projects that involve additional engineering and technical changes other than the content of the contract project, the engineering and technical change notice and construction visa jointly signed and approved by the site representative and the project manager shall prevail. The main raw materials incurred shall be based on market price quotations. For accounting, the changed cost shall be subject to mutual agreement and approval by both Party A and Party A. Matters involving tax regulations shall be implemented in accordance with national regulations.
4. Material supply
1. Party A has clearly specified the supply of raw materials for the main steel structure and enclosure system, that is, the medium-thick plates used in the main steel structure must be purchased from the original factory of Wuhan Iron and Steel Co., Ltd., and the color steel plates must be made from Baosteel. During the steel structure assembly, color plate rolling Before manufacturing, Party B must provide Party A with a valid factory certificate from the manufacturer. For the base materials used in the main steel structure, Party B should promptly notify Party A to witness sampling and inspection. The welded components of the main steel structure must be inspected for weld flaw detection in accordance with national regulations, and a test report must be issued. The solder used, the welding process, the welder's technical level certificate, and the inspection method must comply with the relevant national mandatory regulations.
2. Party B shall purchase the remaining materials by itself. All purchased materials must comply with the requirements of the design and construction unit and various technical standards. The quality certificate and factory certificate must accompany the goods. After the materials arrive at the site, they must be witnessed and accepted by Party A’s on-site representative before they can be used. If the purchased materials are used without authorization by Party B and the quality of the project is unqualified, Party B will be responsible for repair or dismantling and bear all costs incurred. The construction period due to this delay cannot be postponed and Party B will compensate Party A for the economic losses caused thereby.
5. Project quality
1. Project acceptance: The quality of the project must meet the standards and specifications specified in the contract. If within 30 days after the completion of the project (calculated from the date when Party B submits the main project acceptance notice to Party A), if Party A does not organize acceptance due to reasons, the project will be deemed to have been accepted.
2． Party B must carefully organize the construction in accordance with the design drawings approved by Party A. In case of special circumstances where changes are required, the agreement must be obtained from Party A’s on-site representative and project manager and must be jointly signed before it becomes effective.
3. Party B must accept the quality supervision and normal work inspection of Party A’s on-site representatives and shall not obstruct it without reason.
4. Basis for project acceptance:
a. Construction drawings signed by Party A, construction change notices, construction visas, relevant construction standard atlases and drawing review records.
b. Relevant national standards:
"Uniform Standards for Quality Acceptance of Construction Projects" gb50300-2001
"Specifications for Acceptance of Construction Quality of Building Foundation Projects" gb50202 -2002
"Code for acceptance of construction quality of masonry projects" gb50203-2002
"Code for acceptance of construction quality of concrete structure projects" gb50204-2002
"Steel structure "Quality Acceptance Code for Project Construction" gb50205-2001
"Quality Acceptance Code for Roofing Projects" gb50207-2002
"Quality Acceptance Code for Underground Waterproofing Projects" gb50208-2002
"Code for Quality Acceptance of Building Ground Engineering Construction" gb50209-2002
"Code for Quality Acceptance of Construction Decoration and Renovation Project" gb50210-2002
c. The drawing specifications are not explained or are not detailed. Party A’s existing practices for the first phase of the factory can be referred to for acceptance inspection. Projects that have not been confirmed by Party A’s on-site representative and project manager will be deemed to be unqualified.
6. Safety in production
Party B shall strictly abide by the safety production operating procedures and work with a certificate to prevent safety and quality accidents. If a safety accident occurs during Party B's construction, causing personal and property losses to itself and other parties, Party B will be solely responsible for it. 7. Rights and obligations of both parties
1. Party A
a. Provide necessary construction conditions to Party B. Such as on-site water supply, electricity supply, smooth roads, smooth construction site and hoisting conditions, etc.
b. Two copies of design drawings and project-related technical information shall be provided to Party B. Three days before the start of construction, relevant units will be organized to participate in the joint review of construction drawings and project disclosure.
c. Responsible for approving the construction organization design (construction plan) prepared by Party B, and has the right to stop Party B's violations of the approved construction organization design.
d. Responsible for obtaining necessary construction site access certificates for Party B to ensure the passage of Party B’s main and auxiliary materials, construction machinery and personnel. e. Organize relevant parties to participate in project acceptance in a timely manner.
f. Allocate project funds in a timely manner according to progress.
2． Party B
a. Party B foresees that certain factors that restrict the entry, exit and stay of Party personnel that have nothing to do with this project may affect Party A’s production. Party B shall immediately inform Party A and discuss solutions. . If Party B fails to notify in time, all losses resulting from the impact on Party A's production shall be borne by Party B. Unless necessary for construction, Party B's construction personnel and their construction equipment are not allowed to enter or exit Party A's production site at will.
b. Prepare the construction organization design (construction plan) three days before the start of construction and submit it to Party A for review in a timely manner. After the review is approved, the construction will be carried out in strict accordance with the construction organization design.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________year____month____day_________year____month____day Simple Factory Building Contract 3
Contractor: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
Project name:
Project location:
Project design reasonable service life:
Design Certificate level:
Contract signing time:
According to the "Contract Law of the People's Republic of China", "Construction Law of the People's Republic of China", "Construction Engineering Survey" "Design Management Regulations" and "Guizhou Province Construction Project Survey, Design Quality and Market Management Measures", this contract was signed by Party A and Party B through consensus.
Article 1 Party A entrusts Party B to undertake the engineering design of the above factory building construction project, and Party A shall pay corresponding remuneration (design fee).
The second project design includes:
1. General plan design;
2. Construction design of comprehensive buildings, factories and warehouses;
3. Fire protection, water and electricity construction design;
4. Wastewater treatment facility design and 1 copy of the overall design renderings of the factory building.
Article 3 On the date of signing of the contract, Party A shall provide Party B with a copy of the land redline map approved by the competent government department.
Article 4 Within 10 days after the conclusion of the contract, Party B will complete all design materials required for the first approval and submit them for review and ensure that the planning department passes the approval. Party B will obtain approval from the planning department within 10 days after passing the first approval. All design materials (4 copies of civil construction drawings, 4 copies of fire protection, water and electricity construction drawings, 4 bound texts of standardized design plans, and 1 copy of the overall design renderings of the factory building) are delivered to Party A.
Article 5 The design fee is based on the total building area (including factory building area, comprehensive building building area, warehouse building area, and duty room building area) in the plan approved by the planning approval department, which is 10 yuan/ m2 calculation, Party A advances the design fee of RMB 20,000 to Party B within 3 days after the contract is signed. Party A advances the design fee of RMB 24,000 to Party B within 3 days after the planning approval department approves the design plan for the first time. All design materials are completed and planned Party A will pay the remaining balance of the design fee to Party B within 3 days after department approval.
Article 6. Party B is responsible for coordinating the planning approval department to handle relevant matters and ensure that the design materials pass the approval smoothly. Party B is responsible for the coordination costs, and Party A agrees to compensate the coordination fees in RMB. If the planning approval department refuses to approve the documents and materials designed by Party B, Party A has the right to refuse to pay Party B’s design fee, and Party A has the right to claim back the design fee that has been paid.
Article 7 After the construction of this project starts, if Party A cannot solve the technical problems related to the design, Party B is obliged to cooperate with Party A to solve them. If the relevant departments require Party B to participate in the work related to this project according to regulations, Party B shall send personnel to participate in the activities.
Article 8 During the performance of the contract, if Party A changes or adds design content, causing Party B to rework the design, Party A shall pay Party B corresponding remuneration based on the workload previously consumed, and the payment amount shall be negotiated separately by both parties.
Article 9 During the performance of the contract, Party A shall provide necessary working, living, transportation and other convenient conditions for the staff sent by Party B to the site to deal with relevant design issues.
Article 10 Without the consent of Party B, Party A shall not modify the design data and documents delivered by Party B without authorization or transfer them to a third party or use them for projects outside this contract. If the above situation occurs, Party B has the right to claim compensation from Party A.
Article 11
Party B shall not disclose or transfer the information and documents in this contract to a third party. When this happens, Party A has the right to claim compensation from Party B.
Article 12 If Party A does not pay the design fee as stipulated in Article 5 of this contract, if Party B has completed the design data and submitted it to the planning department for approval as stipulated in Article 4 of the contract, Party A will not pay the design fee. , Party A shall pay a liquidated damages of RMB 5,000 to Party B, and at the same time has the right to require Party A to continue to perform the contract; if Party B has completed all design materials in accordance with Article 4 of the contract and has been approved by the planning department, Party A will not pay the design fee , Party A shall pay 20% of the total price of the design fee as liquidated damages to Party B, and at the same time has the right to require Party A to pay the balance of the design fee and the compensation stipulated in Article 6 of this contract.
Article 14 Party A agrees that Party B entrusts its branch in Guizhou, Sichuan Meicheng Architectural Planning and Design Co., Ltd. Bijie Branch, to perform this contract and complete the design work and subsequent services. Invoices will be provided by Bijie Branch Issuance, design fees will be collected from the account of the branch.
Article 15 During the performance of the contract, if either party requests to terminate the contract, it must obtain the consent of the other party, otherwise the contract shall not be terminated. Article 16 If a dispute arises during the performance of this contract, it shall be resolved by both parties through negotiation. If the negotiation fails, both parties can only choose to litigate to the People's Court of Zheng'an County where the contract was signed.
Article 17 For matters not covered above, both parties may sign a supplementary agreement, which shall be an integral part of this contract.
Article 20 If there is a conflict in the completion time of the design results due to Party A’s reasons (what reasons?), the delivery completion time of the relevant design results will be postponed.
Article 21 After delivering the design materials and documents, the designer shall participate in the relevant design review as required, and shall be responsible for making necessary adjustments and supplements based on the review conclusion within the original scope. The review fee shall be Party A drafts it by himself (what other reviews are required after the materials are completed?).
Article 22 This contract is made in 6 copies, 3 copies for the employer and 3 copies for the contractor. It will take effect from the date when Party A pays the design fee of 20,000 yuan to Party B in accordance with Article 4 of the contract.
Contractor:
Contractor:
Date: Simple Factory Construction Contract 4
Construction Unit: (hereinafter referred to as Party A)
Construction unit: (hereinafter referred to as Party B)
In accordance with the "Contract Law of the People's Republic of China", the "Construction Law of the People's Republic of China" and other relevant laws , laws and regulations, following the principles of equality, voluntariness, fairness and good faith, Party A and Party B reach consensus on relevant matters and enter into this contract. ***Same compliance and implementation.
1. Project Overview
Project Name: Enterprise Exhibition Hall of Henan Fengyuan Hepu Feed Co., Ltd.
Project Location:
2. Project Contracting Scope
According to the needs of project construction, Party A entrusts Party B to be fully responsible for the construction of Fengyuan Enterprise Exhibition Hall, and the actual drawings shall prevail. (Including civil engineering, floors, embedded parts, steel structures, doors and windows, etc.). The engineering steel structure is mainly used, the walls are filled with air bricks, the interior and exterior are painted, and the front glass curtain wall.
3. Project contracting method: Under the unified supervision and coordination of Party A’s supervision, Party B contracts the work and materials to ensure quality, construction period, safety, civilized construction and qualified qualifications (the information ensures that Party A can pass the quality inspection), subcontracting or subcontracting is not allowed.
IV. Contract period:
Party B promises to complete the construction of the steel structure project within one calendar day from the date of signing this contract. The completion date is March 2015.
5. Quality Standard
The quality requirement standard of this project is: qualified.
For this reason, Party A requires Party B to use standard materials for all building construction, and the overall project must comply with national construction standards. And it should be able to pass the acceptance of the relevant quality inspection department.
6. Contract Price
The project includes materials, labor, production, transportation, installation, loading and unloading fees, invoices and various unforeseen expenses incurred accordingly (if none For major design changes, the total price cannot be adjusted; if there are major design changes, the total price can be adjusted by negotiation within ±5%)
The total fixed contract price of this project is 10,000 yuan (ie: RMB)
(1) The project design drawings are attached as attachments to this contract.
(2) If there are major changes, both parties will use signatures as the basis for settlement.
VII. Payment method
After the signing of this contract, an advance payment of RMB 10,000 (10% of the total cost) will be paid within one week after the completion of the civil construction.
The project payment of RMB 10,000 (30% of the total cost) shall be paid within one week after the steel columns and steel beams are brought into the site. The project fee of 10,000 yuan (20% of the total cost) will be paid within one week after the wall painting is completed. The project payment of RMB 10,000 (20% of the total cost) shall be paid within one week after the completion of the project. The project payment of 10,000 yuan (15% of the total cost) will be paid within one week after the project is accepted and accepted. The remaining 5% will be used as a warranty deposit, which is 10,000 yuan. The balance will be paid after one year when no quality problems occur.
8. Party B promises to carry out construction in accordance with the contract and assume the responsibility for project quality warranty during the quality warranty period. Within one year after the project is delivered, Party B will be responsible for free maintenance of any quality problems in the steel structure that are not caused by Party A's faults; within five years, Party B will repair the waterproofing of the built project free of charge (except for factors irresistible to manpower). After the project is delivered, Party B is responsible for the lifetime paid maintenance and services of the project, only charges the cost and is responsible for the transformation of Party A's project.
9. Party A promises to Party B to pay fees in accordance with the time limit and method agreed in the contract
10. Party B promises to Party A that it will fully perform the contents of the contract. If it cannot be completed on time, it will Voluntarily bear the liability for breach of contract to Party A at the rate of 2‰ yuan per day. If the quality fails to meet the requirements, Party A will be voluntarily liable for breach of contract at a rate of 50 yuan per square meter. Party B also promises that the payment of the above liquidated damages will not affect Party B's other compensation claims for losses caused by construction delays and quality problems.
11. For this project, Party A will appoint a comrade, and Party B will appoint a comrade as the person in charge of the on-site construction to coordinate and solve related problems during the construction.
12. Implement relevant national production safety regulations to ensure safe construction. Party B will be responsible for any work-related injuries that occur during construction. Party B is required to purchase workers' work injury accident insurance.
13. Party A is responsible for the interpretation of this contract. Matters not covered in this contract can be resolved through negotiation. If a dispute occurs, it can be settled by arbitration at the arbitration committee where the contract is signed or brought to the people's court for settlement.
13. The contract takes effect
Time of conclusion of contract:
Place of conclusion of contract:
This contract shall take effect after both parties A and B sign and seal it. .
Contractor (Party A): Contractor (Party B)
(Official seal) (Official seal)
Legal representative: Legal representative:
Authorized agent: Authorized agent: Simple Factory Construction Contract 5
Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
Party A and Party B reached the following agreement after discussion:
1. Party A needs to build a factory building (steel frame building), so it contracts to Party B to build it at a unit price of eighty yuan per square meter. The materials consist of angle iron, round pipes, steel bars, etc. All materials are provided by Party B.
2. Steel specifications: Party A requires Party B to use No. 6 round pipes with a thickness of 2.3 mm, angle irons of 4×4 national standard, each weighing 8 kg, steel tiles with a thickness of 0.326 mm, and steel bars of 0.8 centimeters.
3. When the steel is pulled to the construction site, Party A pays Party B 30% in advance, and an additional 30% when the tiles are laid. The balance will be settled after acceptance.
4. Work quality and life safety: If the steel specifications, work attitude, etc. cannot meet the requirements of Party A, Party A can ask Party B to stop the construction and use another builder to build it. If Party B has safety problems, Party B is responsible for the accident and all consequences have nothing to do with Party A. The factory building must be built according to Party A's requirements, and Party B is responsible for guaranteeing the quality for three years after completion. If water leakage, factory collapse, etc. causes casualties, or machinery is damaged causing Party A to be unable to produce, all responsibilities shall be borne by Party B and compensation shall be paid.
(Note: Except for the collapse of our steel shed due to natural disasters or heavy snowfall, we have no responsibility to Party B.
5. Party B cannot ask for leave or stop work from the beginning of construction except for special circumstances. After completion, Party A will accept it. Settlement will be made after passing the test.
6. This contract is in duplicate and will take effect after being signed by both parties.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________year____month____day_________year____month____day