Labor Contract for Hydropower Project 1
Employer: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In order to clarify the responsibilities, division of labor, cooperation, mutual cooperation, mutual promotion and joint efforts of the contractor and the contractor to complete this project, this contract is signed by both parties through consultation in accordance with the Contract Law of People's Republic of China (PRC), Construction Law of People's Republic of China (PRC) and other laws and regulations, following the principles of equality, voluntariness, fairness and good faith, and according to the actual situation of this project.
1. Project name: 37 1 Phase II Project of Building 3 of Hospital Affordable Housing
2. Project address: No.201Wenhua Street, Xinxiang City
Three. General situation of the project: 1 underground floor, 11 floors above ground, shear wall structure.
Fourth, the contracting method: the contractor does not include materials. Ensure safety, quality, construction period and safe and civilized construction.
Verb (abbreviation of verb) contract scope: 37 1 The water, electricity, heating, fire fighting, weak current and air conditioning eyes of the second phase project of No.3 affordable housing in the hospital are all reserved for installation, including temporary water and electricity cooperation on site.
The contract price and settlement method of intransitive verbs:
1. The contract price is thirty-one yuan/square meter (3 1 yuan/square meter) based on the construction area per square meter. The peripheral area of the basement is calculated by one floor, and the construction area exceeding 0.000 is calculated by quota calculation rules (the balcony is calculated by half).
Seven. Construction date: This project will be completed from (to), and the construction period will be postponed accordingly due to Party A's reasons.
Eight, the city's high-quality structure, provincial civilized construction site.
Nine, safe and civilized construction:
During the construction period, Party B shall strengthen the safety education for the construction personnel, strictly implement various safety operation procedures, and designate a special person to be in charge to avoid safety accidents. In the event of a safety accident, all responsibilities and expenses shall be borne by Party B. ..
X payment method: 25% of the contract price shall be paid according to the completed construction area during the main construction period; Pay 35% of the image progress payment after the plastering of internal and external walls is completed; Pay 45% of the image progress payment after the construction of floors, upper and lower water pipes and main branch pipes is completed; Pay 60% of the image progress payment after all wires, switches and sockets are completed; 80% of the image progress payment shall be paid after the project is completely completed, 90% of the total price shall be paid after the completion acceptance, and the remaining 10% shall be the warranty payment, which shall be paid in one lump sum after the warranty period expires.
XI。 Responsibilities of both parties:
Party A's responsibilities
1. Assist Party B to determine the building axis position of each floor on site;
2. Provide Party B with a construction drawing before commencement;
3. Appoint Qin Yongkang as the representative of the site manager to supervise and inspect the project quality, progress, safety and civilized construction. Partial acceptance of the project and other matters.
4. Provide temporary water and electricity for the construction site.
5. Provide large-scale mechanical equipment.
6. Pay Party B's labor wages according to the payment method agreed in this contract.
Party B's responsibilities
1. Obey the unified command and management of Party A (the general contractor) and be responsible to Party A. ..
2, in strict accordance with the design drawings and construction specifications.
3. Ensure that qualified projects are achieved. If the standards agreed in the contract cannot be reached due to Party B's reasons, Party B will be fined 20% of the total contract price of the labor service project.
4. If Party B has any quality problems in the construction process, Party A has the right to order rework (compensation for materials according to the price), stop work and even terminate the contract. The completed project shall be settled at 65% of the contract unit price, and the losses caused thereby shall be borne by Party B, who must leave the site within 3 days.
5. In the process of engineering construction, Party B shall report to the project department for acceptance after each working procedure is completed, and cooperate with the project supervisor and the on-site personnel of the construction unit for inspection. Only after signing can the next process be carried out, otherwise the consequences will be at your own risk.
6. Party B promises not to default on the wages of any migrant workers, otherwise all consequences arising therefrom shall be borne by Party B. ..
7. If Party B's personnel fight, fight, make trouble or disobey Party A's management during the construction, all the consequences arising therefrom shall be borne by Party B. If the circumstances are serious, Party B will bear civil or criminal responsibilities.
Twelve. Supplementary terms:
1. Party B is responsible for the safety helmet, safety belt and safety rope.
2. Party A requires Party B to use young and healthy workers for construction, otherwise, Party B will be responsible for the casualties of sudden diseases, and all the responsibilities and expenses of safety accidents will be borne by Party B..
3. Party B must take out personal accident insurance for every worker who enters the site. Otherwise, Party A will purchase on behalf of Party B, and the expenses shall be borne by Party B. ..
4. Material loss: the loss exceeding 1% shall be paid by Party B to Party A according to the price.
5. The materials needed for the construction shall be made in declare in advance, and the work shall not be stopped due to material delay, otherwise Party B shall be responsible for everything.
6. Mechanical operators must hold relevant certificates, and Party B shall be responsible for mechanical maintenance.
7. Party B shall not subcontract the project to others again, otherwise Party A has the right to terminate the contract, and all consequences arising therefrom shall be borne by Party B. ..
8. During the construction period, the project department will no longer sign any hourly workers.
9. Materials and reusable materials shall be neatly stacked in the place designated by Party A. ..
Thirteen. This contract is made in triplicate, two for Party A and one for Party B, and shall come into effect after being signed and sealed by both parties.
Party A: Party B:
Legal representative:
Authorized Agent: Authorized Agent:
Year, month, sun, moon, sun.
Labor Contract for Hydropower Project II
Party A:
Party B:
Whereas Party A agrees to hand over its hydropower installation project to Party B for construction, both parties reach the following terms.
Article 1 General situation and contents of the project
1. 1 project name: decoration project
1.2 scope of contract: completion of water and electricity installation and commissioning, erection of temporary water and electricity, etc.
Article 2 Contract Price
The contract price is subject to the following Article 2.2:
2. 1 The estimated total price is determined as RMB/Yuan (in words: RMB/).
2.2 according to the fixed unit price and the actual completion of the settlement of quantities. (Final settlement will be made according to the as-built documents)
2.3 according to the construction area _ fixed unit price settlement.
2.4 unit price of water and electricity installation 30 yuan /m2 temporary water and electricity installation unit price 1 yuan /m2.
The third construction period
3. 1 Start date: 20_ _ _ _
3.2 Completion Date: 20_ _ _
3.3 The total term of this agreement is days.
3.4 Each specific completion node within the above-mentioned construction period shall meet the schedule requirements of Party A..
3.5 Liability for breach of contract during the construction period: If each specific completion node fails to meet the schedule requirements of the project department, Party A has the right to give Party B corresponding economic benefits according to the actual situation.
Article 4 Engineering quality standards
/The quality of general contractor materials is consistent, and the construction shall be carried out in strict accordance with Party A's construction requirements and technical requirements. If the overall requirements of the project reach various awards, the Construction Department of Party B shall
4.2 If the project quality fails to meet the agreed quality standards or promised awards due to Party B's reasons, Party B shall bear 5% of the contract amount to Party A.
4.3 During the construction period, Party B shall protect some finished products by itself, so as to meet Party A's requirements and actual protection functions. no
4.4 Party B must prepare the labor service construction progress plan and submit it to Party A for review. The inspection, handover and acceptance procedures of related projects must conform to/
4.5 Quality warranty: After the project is completed, accepted and delivered for use, Party B shall guarantee the defects of the project according to relevant national regulations, and the warranty period is as follows.
Article 5 Project Settlement
5. 1 Contract price agreed in 2. 1: final settlement price of this project = agreement price.
5.2 Contract price agreed in Clause 2.2: agreed unit price × actual engineering quantity.
5.3 Except all taxes and fees paid by Party A, all expenses including engineering insurance in this contract project shall be borne by Party B. ..
Article 6 Payment of project funds
6. 1 Unless otherwise agreed, the payment method, time and reality of Party B's project funds and the contract signed between Party A and the constructor/owner/general contractor.
6.2 After receiving the project payment, Party B shall allocate funds to ensure the normal construction of the project, and provide the same amount when paying the project payment.
6.3 Unless otherwise agreed: 1. After Party B completes 100% of the workload, Party B shall pay 90% of the final settlement amount of the project one month after Party A completes the completion acceptance.
2. Settlement next year (20_ years) 10% of the final settlement amount of the project.
3. The warranty period of Party B is 2 years after the completion of the project (from the time when the completion documents are signed).
Article 7 Project management
7. 1 Party B shall accept the management of Party A, and all personnel involved in the operation shall receive the technical and safety training and education organized by Party A; Accept Party A's opinions on the project.
7.2 Party B shall strictly implement relevant standards and requirements such as quality acceptance evaluation standards of construction projects, construction safety technical specifications, acceptance specifications, etc., strictly implement safety operation procedures, fire safety regulations and environmental protection regulations, carry out construction in strict accordance with the design and Party A's requirements, and complete the construction tasks with good quality and quantity on schedule.
7.3 Party A may inspect Party B's construction at any time according to the industry quality and safety standards and the requirements of the contract signed between Party A and the owner/general contractor. If Party B fails to implement the standards and disobeys the supervision and management of Party A during the project construction, which damages the interests of the constructor/owner/general contractor and Party A, and damages the reputation and image of Party A, Party A has the right to order rectification until the contract is dissolved, and the contract is dissolved when the notice arrives at Party B. At the same time, Party B shall bear the liquidated damages of 100% of the contract cost and all the losses actually suffered by Party A. ..
7.4 Party B shall carry out the work according to the design and construction requirements and strictly control the losses. If the site is not in conformity with the drawings, it shall be submitted to Party A in time, otherwise Party B shall be responsible for the compensation for the losses caused thereby. ..
7.5 Party B shall strictly implement relevant standards and requirements such as quality acceptance evaluation standards of construction projects, technical specifications for construction safety, acceptance specifications, etc., strictly implement safety operation procedures, fire safety regulations and environmental protection regulations, carry out construction in strict accordance with drawings, ensure quality and quantity, and complete construction tasks on schedule.
7.6 Party B shall apply for materials according to Party A's requirements, keep them and accept Party A's supervision.
Article 8 Safe and civilized construction
8. 1 Party B shall educate its construction personnel on safe and civilized construction, abide by the construction site system of Party A and the owner//,and sign a letter of commitment on safe and civilized construction with Party A ... Strengthen the safety inspection on the construction site, and stop or correct the violation of construction safety technical standards, specifications and operating procedures in time; Take timely measures to eliminate potential safety accidents found. Once a safety accident occurs, it shall be reported to the project department immediately, and the site shall be maintained and emergency measures shall be taken. According to accidents and incidents, find out the reasons, distinguish the responsibilities and bear the corresponding losses. If Party B operates illegally, all responsibilities shall be borne by Party B. ..
Article 9 Employment of Workers and Payment of Wages
9. 1 Party B shall sign an employment contract with the workers employed in the project construction, all operators shall hold relevant certificates, and special types of work must hold relevant certificates. Party B shall pay all employment expenses according to law, pay the wages of workers on time, and submit the employee list to Party A for filing (with copies of ID card, work permit, operation certificate and temporary residence permit). The labor contract disputes between Party B and the hired workers, as well as accidental injuries and deaths in the construction process, shall be solved by Party B itself. If losses are caused to Party A due to the above disputes. Party B shall make full compensation.
9.2 Party B must ensure that workers' wages are paid in full in accordance with relevant national laws. If Party B fails to pay workers' wages in time, causing workers to make trouble or complain to relevant departments, Party A has the right to pay directly from the remaining project funds, and Party B shall still bear the following liabilities for breach of contract:
(1) Pay Party A the total wages of workers that have not been paid in time, and Party A has the right not to pay the unpaid project funds;
(2) If Party A is claimed by the construction/owner or punished by the administrative department, Party B shall bear the economic losses caused to Party A; The above liquidated damages and losses that Party B shall bear shall be directly deducted by Party A from the project payment payable to Party B; Party B shall pay the insufficient amount to Party A within 7 days after receiving Party A's claim notice.
Article 10 Without the written consent of Party A, Party B shall not sign any contract related to this project, such as sales contract, lease contract, labor contract, etc. In the name of Party A, if a lawsuit or arbitration is caused due to violation of this Agreement, Party B shall bear the legal fees and other legal fees in addition to the obligations specified by Party A in the judgment document. Party A has the right to terminate this contract.
Article 11 All expenses related to Party B in the construction process, including but not limited to project quality, construction period, safety protection, environmental protection, civilized construction, public security establishment, fire prevention and theft prevention, industrial accidents, etc., shall be borne by Party B. All losses caused to Party A due to disputes caused by Party B's failure or improper handling shall be borne by Party B. ..
Article 12 The liquidated damages that Party B shall bear to Party A in this contract, as well as related compensation or expenses and losses, shall be directly deducted from the amount payable to Party B by Party A, and the insufficient amount shall be paid to Party A within one week from the date when Party A issues the notice of claim.
Article 13 For matters not covered in this contract, both parties shall negotiate separately.
Article 14 Any dispute arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, it shall be decided by Wuxi Labor Arbitration Commission.
Article 15 This contract is made in duplicate, with each party holding one copy. It shall take effect after both parties sign and seal and Party A receives the performance bond from Party B. ..
Article 16 Supplementary Provisions
16. 1 attachment 1: agreement unit price.
16.2 appendix ii: (supplementary provisions).
Party A: Address: Tel: Bank of deposit: account number: signing date:
Party B: ID card (temporary residence permit)No.: Tel: bank of deposit: account number: signing date:
Labor Contract for Hydropower Project 3
Employer: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
According to the negotiation between Party A and Party B, Party A will contract out the sub-project of water and electricity heating installation in residential building project to Party B for construction. Referring to the relevant economic and labor contract provisions, according to the provisions of the national labor law and other relevant laws and regulations, both parties reached an agreement through consultation to sign this contract.
Article 1 General situation of the project
1, project name:
2. Project location:
3, the number of projects:
Article 2 Scope of Contract and Precautions
1, construction content
The whole process from foundation excavation to project handover (construction blueprint and technical description, project contact list, etc.). ) and the warranty quantities within the warranty period of the contract scope (except the wages of formwork workers, masons, paints and coatings, roof waterproofing, steel reinforcement workers and tower crane drivers, except temporary facilities construction but including demolition and material utilization).
2. Construction quality
Must meet the national acceptance standards and pass the acceptance. According to the acceptance specifications of each subdivisional work, strictly control the project quality and put an end to common quality problems. Pay special attention to the quality of beam-slab column steel binding. All losses caused by rework due to construction quality problems shall be borne by Party B..
3. Party A shall timely organize materials according to Party B's plans and requirements. Based on the principle of economy, Party B shall abide by professional ethics, and it is strictly forbidden to waste materials at will.
4. Actively cooperate with each type of work to reasonably arrange the labor force, ensure the construction period (control the construction period according to the total schedule), and work overtime when necessary.
5. Actively cooperate with the supervision and quality inspection of the superior quality department, and mortar king is strictly prohibited in the construction.
Article 3 Safe and civilized construction
1. Party B shall abide by the national regulations on safe and civilized production, implement Party A's regulations on safe and civilized construction, strictly implement operating procedures, stack materials in an orderly manner, and actively cooperate with the inspection of superior departments to achieve safe and civilized construction.
2. You must wear a safety helmet when entering the construction site, and you must fasten your seat belt when working in high-altitude dangerous areas without safety protection. In case of violation, Party B shall be responsible for the fines incurred and deduct the corresponding amount at the time of settlement.
3. During the construction process, the breaching party shall be responsible for all safety casualties caused by illegal command and operation.
4, it is strictly prohibited to drink mount guard, offenders dissuade.
5. Party B shall manage its own employees well, especially in case of conflict, it shall stop handling in time. Fighting is strictly prohibited on the construction site. If it happens, it will be handed over to the police station for handling, and Party B will bear all the responsibilities. At the same time,
6. Special reminder: Party A will not be responsible for all safety accidents outside the construction site. Take good care of your scooter. Party A is not responsible for any loss or damage.
Article 4 Wage price and payment ratio:
1, area calculation: (fixed-area contract) shall be settled by the apartment area × number of households, that is, 129. 16m2× 80 households = 10 140m2.
2. Price calculation: 10332.8m2× 20 yuan /m2.
3. Settlement ratio:
Pay in installments according to the progress (the completion time of the last building), and the payment base is 80% of the total price (about 654.38+600,000 yuan). During the main period, each floor (four buildings) will pay 7500 yuan after the structure is completed.
The work can be completed before the Spring Festival, the salary will be paid to 95%, and the rest will be settled after settlement (or both parties will negotiate separately). After the end of the year, the salary will be paid to 80% of the actual progress before the Spring Festival. Pay wages according to this clause after returning to work next year.
Article 5 Liability for breach of contract
The breaching party shall bear all the responsibilities for the economic losses caused by the breaching party. When Party B is fined or forcibly dissolved by a third party (regulatory department or competent department) due to other problems such as quality and safety, Party B shall bear the economic losses and terminate the contract, and Party A shall pay 70% of Party B's actual progress.
Article 6 Matters not covered in this contract can be settled by both parties through consultation, and a supplementary agreement can be signed. Sign another safety production contract.
This contract is made in triplicate, with Party A 1 copy, Party B 1 copy and Party A's company 1 copy, which shall come into effect after being signed.
Party A: Party B:
Year, month, sun, moon, sun.
Three clauses related to the labor contract for hydropower projects:
★ Template of Labor Contract for Hydropower Installation Project (3)
★ 3 copies of contract model for hydropower project.
★ 3 copies of model engineering labor service contract.
★ 3 copies of water and electricity contract model.
★ 3 copies of model labor contract for installation project.
★ 5 copies of simple hydropower installation contract
★ 3 Labor Contract Agreement
★ Template of Labor Contract for Hydropower Installation Project
★ 3 simple personal labor contracts
★ Article 3 of the Labor Contract Agreement