Power of Attorney for Supervision1* * * * * * Company:
According to the spirit of the regulations of the Ministry of Construction and provinces and cities on the implementation of engineering construction supervision, in order to improve the comprehensive economic benefits of engineering construction, our unit entrusts * * * * * * * * company to supervise the whole process of the construction stage and warranty stage, and hopes that your unit will obey the supervision and management of the supervision company in accordance with the regulations of the competent construction department on construction supervision. The authority granted to the supervisor is hereby notified as follows:
1, aiming at the technical problems in engineering design, and according to the principle of safety and optimization, make suggestions to designers; If the proposed proposal may increase the project cost or extend the construction period, the consent of the client shall be obtained in advance. When it is found that the engineering design does not meet the current national quality standards for construction projects, the supervisor shall report to the client in writing and ask the designer to correct it.
2, the project construction organization design, technical scheme, according to the principle of quality, time limit for a project and reduce the cost, the supervision unit can put forward a request to the contractor, if this requirement leads to the project cost increase, time limit for a project extension, it should obtain the consent of our unit in advance.
3. Have the right to preside over the organization and coordination of relevant engineering construction cooperation units, and report important coordination matters to our unit in advance.
4. After the shutdown report is submitted to our unit for examination and approval, the supervisor can issue a commencement order, a shutdown order and a resumption order.
The client entrusts XXX as the agent (or defender) of XXXX (first instance, second instance or retrial) case (indicating the nature of the case and the other party), and the agency authority is as follows:
5. Have the right to check the materials used in the project and the construction quality. Review the list, specifications and quantity of the contractor's materials, components and equipment, and have the right to notify the contractor to stop using materials, components and equipment that do not meet the design requirements and national standards; Supervise and inspect the contractor's strict performance of the contract during the whole construction process; Implement national technical specifications, standards and superior documents; Carry out the construction in strict accordance with the design and construction drawings, and have the right to notify the contractor to stop work, repair and rework the procedures, sub-projects and unsafe construction operations that do not meet the design drawings, construction specifications and quality standards. The contractor can only resume work after obtaining the resumption order from the supervision company. Orders to stop work and resume work should be reported in advance. If you can't report in advance in case of emergency, you should report in writing to our unit within 24 hours.
I _ _ _ _ _ _ _ _ (name) is the legal representative of _ _ _ _ _ _ _ _ (company name), and I hereby authorize _ _ _ _ _ _ _ _ _ _ _ _ (name) of our company to come to your company in the name of our company (to handle affairs). We acknowledge all the documents signed by the agent in this process and all the affairs related to it.
6. The right to inspect and supervise the construction progress of the project, and the right to sign and acknowledge that the actual completion date of the project is ahead of or beyond the completion period stipulated in the project contract.
7, within the scope of the project price agreed in the project contract, audit the project payment and have the right to audit and settle the project payment. During the project, the economic visa for the construction site must be communicated with us in time.
8. Analyze the potential factors in the contract signed by the employer and the contractor, and provide the basis for the risk analysis and risk management of the employer.
9, in the process of engineering construction, to ensure smooth information transmission channels, to provide comprehensive, timely and reliable information for predicting the future development of engineering construction.
10, check and urge the contractor to do a good job of civilized and safe construction on site according to relevant regulations.
1 1. Within the scope of the entrusted project, the supervision unit assists our unit in making claims or counterclaims.
12, the right to review and confirm the engineering technical data during the project construction.
13. During the warranty period, be responsible for checking the engineering conditions; Identify the responsibility for quality problems and urge the contractor to fulfill the warranty obligations according to the contract requirements.
14, the supervision unit or supervisor has the right to propose punishment suggestions for the construction unit's violation of the relevant provisions of project management.
Matters not covered shall be supplemented separately.
***************
date month year
2. Power of Attorney for Supervision of China Mobile Communications Group Beijing Co., Ltd.:
I authorize _ _ _ _ _ _ _ (hereinafter referred to as the agent), My ID number is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
I hereby confirm that any business handled by the agent in your company and any agreement signed by the agent are regarded as my behavior, and all consequences and responsibilities arising therefrom shall be borne by me.
Signature of the Principal: _ _ _ _ _ _ _
ID number:
Time: Year Month Day
Signature of agent: _ _ _ _ _ _ _
ID number:
Time: Year Month Day
Power of Attorney for Supervision 3 I. Entrusted supervision unit:
XX supervisory co., ltd
Second, the chief supervision engineer:
XXX professional supervision engineer: XXX supervisor: XXX
Three. Scope and content of entrusted supervision project:
1. Scope of supervision: See the construction contents specified in the construction drawing for the building, structure, water supply and drainage, electricity, etc. The second phase project of resettlement house in XX District, XX County.
2. Supervision work content: supervision in the construction stage.
Four, supervision units within the scope of the entrusted project, enjoy the following rights:
1 Review the construction organization design, construction technical scheme, construction progress plan, construction quality assurance system and safety assurance system and supervise their implementation.
2. Participate in the audit of project settlement.
3, choose the right to suggest the project general contracting.
4. Select the project subcontractor's approval authority.
5. The right to put forward project construction suggestions to the client, including project scale, design standards, planning and design, production process design and functional requirements.
6. For technical problems in engineering design, make suggestions to designers according to the principles of safety and optimization. If the proposed proposal may increase the project cost or extend the construction period, the consent of the client shall be obtained in advance. If it is found that the engineering design does not meet the quality standards of construction projects promulgated by the state or the design contract, the supervisor shall report to the client in writing and ask the designer to correct it.
7. According to the principle of ensuring quality, time limit for a project and reducing cost, examine and approve the project construction organization design and technical scheme, make suggestions to the contractor, and submit a written report to the employer.
8. Be responsible for the organization and coordination of relevant cooperative units in engineering construction, and report important coordination matters to the entrusting party in advance.
9. With the consent of the client, the supervisor has the right to issue a commencement order, a shutdown order and a resumption order, but shall report to the client in advance. If it is impossible to report in advance due to emergency, it shall make a written report to the client within 24 hours.
10, the right to inspect the materials used in the project and the construction quality. Have the right to notify the contractor to stop using materials, components and equipment that do not meet the design requirements, contract provisions and national quality standards; For processes, divisions, subdivisional works and unsafe construction operations that do not meet the specifications and quality standards, the contractor has the right to notify the contractor to stop work, rectify and rework. The contractor can only resume work after receiving the resumption order from the supervision organization.
1 1, the right to inspect and supervise the construction progress, and the right to sign and approve the actual completion date of the project in advance or beyond the completion period stipulated in the construction contract.
12, within the scope of the project price agreed in the project construction contract, the right to review and sign the project payment, the right to confirm and veto the project settlement. Without the signature of the chief supervision engineer, the client will not pay the project payment.
According to the authorization of the client, the supervisor may propose changes to the contractual obligations of any contractor. If this seriously affects the project cost or quality or schedule, such changes must be approved by the customer in advance. In case of emergency, if it fails to be approved by the client in advance, the supervisor shall also inform the client of the changes made as soon as possible. If the contractor is found to be ineffective in the supervision process, the supervision institution may require the contractor to replace the relevant personnel.
Within the scope of the entrusted project, any opinions and requirements (including claims) of the other party's client or contractor must be submitted to the supervision institution first, which will study and deal with the opinions, and then negotiate with both parties to determine. When there is a dispute between the client and the contractor, the supervision institution shall make independent judgment and mediate fairly according to its own functions. If the dispute between the two parties is mediated by the administrative department of construction of the government or arbitrated by the arbitration organ, it shall provide the factual materials to prove it.
Five, the power given by the construction unit to the supervision engineer is:
1. If it is found that the design of the construction project does not meet the quality standards of the construction project or the quality requirements agreed in the contract, it shall report to the construction unit and ask the design unit to correct it.
2, think that the project construction does not meet the design requirements, technical standards and contract, or may produce engineering quality or safety hazards, have the right to ask the construction unit to correct.
3. Without signature, building materials, building components and equipment that affect the quality and safety of the main structure of the construction project shall not be used or installed in the project; For other unqualified building materials, components and equipment, the construction unit is required to stop using them; Without the signature and approval of the supervision engineer, building materials, components and equipment shall not be used or installed in the project, and the construction unit shall not carry out the next process.
4, concealed engineering acceptance; Without the signature and approval of the supervision engineer, the next procedure shall not be carried out. All concealed works, engineering changes and related engineering costs involved in the increase or decrease of engineering cost shall be reported to the construction unit for review and signed by the representative of the construction unit and the chief supervision engineer.
5. It is suggested to replace unqualified units, project leaders or relevant personnel undertaking construction projects.
6. It is suggested to replace the unqualified project leader of the construction unit and have the right to report to the relevant competent department.
7. Confirmation and rejection of schedule and construction period.
8. Confirmation right and veto right in engineering measurement, project payment and settlement.
9, the host of construction organization and coordination.
Under special circumstances, if there is an emergency that endangers life, engineering or property safety, the supervision engineer has the right to instruct the contractor to carry out operations to eliminate this danger or take other necessary measures.
XX company
Legal representative:
20xx June 20th
According to the current national laws and regulations, our company decided to grant Jiuquan Chengxin Engineering Construction Supervision Company the following rights:
I. Our company recognizes the rights granted to the supervisor by the supervision contract.
1, choose the suggestion right of the general contractor.
2. Select the project subcontractor's approval authority.
3, the project payment approval authority.
4. The right to make suggestions to the client on matters related to project construction (project scale, design standards, planning and design, production process design and functional requirements).
5. For technical problems in engineering design, according to the principle of safety and optimization, make suggestions to designers. If the questions raised may increase the project cost or extend the construction period, the consent of the client shall be obtained in advance. When it is found that the engineering design does not conform to the quality standards of construction projects promulgated by the state and the design contract, the supervisor shall report to the client in writing and ask the design unit to correct it.
6, examination and approval of the project construction organization design and technical scheme, according to the principle of quality, time limit for a project and reduce costs, put forward suggestions to the contractor, and submit a written report to the employer.
7. Be responsible for the organization and coordination of relevant cooperative units in engineering construction, and report important coordination matters to the entrusting party in advance.
8. The supervisor has the right to issue a commencement order, a shutdown order and a resumption order.
9, engineering materials and construction quality inspection. Have the right to notify the contractor to stop using materials, components and equipment that do not meet the design requirements, contract provisions and national quality standards; For processes, divisions, disciplines, inspection lots and unsafe construction operations that do not meet the specifications and quality standards, the contractor has the right to notify the contractor to stop work, rectify and rework. The contractor can only resume work after receiving the resumption order from the supervision organization.
10, the right to check and supervise the construction progress, and the right to sign the actual completion date of the project ahead of or beyond the completion period stipulated in the construction contract.
1 1. The supervisor may propose changes to the contractual obligations of any contractor according to the authorization. If this seriously affects the project cost or quality or schedule, this change must be approved by the customer in advance. If the customer's approval is not reported in advance in an emergency, the supervisor will also inform the customer of the change as soon as possible. In the process of supervision, if the employees of the project contractor are found to be ineffective, the supervision institution may require the contractor to replace the relevant personnel.
12, within the scope of the entrusted work, any opinions and requirements (including claims) of the client or contractor to the other party must be submitted to the supervision institution first, and the supervision institution will study and handle the opinions and negotiate with both parties. When there is a dispute between the client and the contractor, the supervision institution shall make independent judgment and mediate fairly according to its own functions. If the dispute between the two parties is mediated by the administrative department of construction of the government or arbitrated by an arbitration institution, the factual materials to prove it shall be provided.
Second, the rights granted to the supervisor by the regulatory code recognized by the Company.
(1) has the right to check the materials used in the project and the construction quality.
1. The professional supervision engineer shall review the application form of engineering materials, components and equipment submitted by the contractor and its quality certification documents, and conduct spot checks on the physical objects entering the site according to the proportion stipulated in the entrusted supervision contract or relevant engineering quality management documents. For engineering materials, components and equipment that have not been accepted by the supervisor or are unqualified, the supervisor shall refuse to sign for recognition, and issue a notice to the supervision engineer, and notify the contractor in writing to evacuate the unqualified engineering materials, components and equipment from the site within a time limit.
2. The supervisor shall refuse to sign the process that has not been accepted or qualified by the supervisor, and ask the contractor to prohibit the next process.
(b) Right to stop work and resume work
1, in order to ensure the engineering quality, it is necessary to stop work, and the chief supervision engineer issued a stop work order.
2, addicted to construction safety, the chief supervision engineer has the right to stop working, in order to eliminate the safety addiction.
3. In case of emergency, the construction must be stopped temporarily.
4. The contractor carries out construction without authorization, or refuses to accept the management of the project supervision agency.
5. When the conditions for resumption of work are met, the contractor shall apply to the project supervision machinery department for resumption of work, and attach the rectification plan signed and sealed by the head office, the application form for resumption of work signed by the chief supervision engineer and relevant materials to instruct the contractor to continue the construction.
(3) Approval and issuance of engineering change orders
1. Before the chief supervision engineer issues the engineering change order, the contractor shall not implement the engineering change.
2, without the consent of the supervision engineer review and implementation of engineering changes, project supervision institutions will not be recognized measurement.
Three. The rights granted to the supervisor by the State Council No.279 approved by our company.
1, the construction unit must be in accordance with the engineering design requirements, construction technical standards and the contract, the building materials, building components, equipment and commercial concrete inspection, inspection should be recorded in writing and signed by a special person, without inspection or unqualified inspection, shall not be used.
2. Without the signature of the supervision engineer, building materials, building components and equipment shall not be used or installed in the project, and the construction unit shall not absorb or construct the next process. Without the signature of the chief supervision engineer, the construction unit will not allocate the project funds and will not carry out the completion acceptance.
Four. Other rights (including the right of punishment) granted to the supervisor at any time, with the seal of our company.
Power of Attorney for Supervision 5 This power of attorney states that this project is now awarded to XXXX Construction Supervision Co., Ltd. for supervision work, and the supervisor is granted the following rights:
The supervisor shall enjoy the following rights within the scope of the project entrusted by the client:
(1) The approval authority for selecting project subcontractors.
(2) the right to make suggestions to the client on matters related to engineering construction, including design standards, production process design and functional requirements.
(three) according to the principle of safety and optimization, put forward suggestions to designers on technical problems in engineering design; If the proposed proposal may increase the project cost or extend the construction period, the consent of the client shall be obtained in advance. When it is found that the engineering design does not meet the current national quality standards for construction projects, the supervisor shall report to the client in writing and ask the designer to correct it.
(4) According to the principle of ensuring quality, time limit for a project and reducing cost, examine and approve the project construction organization design and technical scheme, make suggestions to the contractor, and submit a written report to the employer.
(5) Be responsible for the organization and coordination of relevant cooperative units in the project construction, and report important coordination matters to the entrusting party in advance.
(6) With the consent of the client, the supervisor has the right to issue a commencement order, a shutdown order and a resumption order, but shall report to the client in advance. If it is impossible to report in advance due to emergency, it shall make a written report to the client within 24 hours.
(7) the right to check the materials used in the project and the quality of the project. Have the right to notify the contractor to stop using materials, components and equipment that do not meet the design requirements, contract provisions and national quality standards; For processes, sub-projects and unsafe construction operations that do not meet the specifications and quality standards, the contractor has the right to notify the contractor to stop work, rectify and rework.
(8) the right to inspect and supervise the construction progress of the project, and the right to sign and recognize that the actual completion date of the project is ahead of or beyond the completion period stipulated in the construction contract.
(9) Have the right to review and sign the project payment within the scope of the project price agreed in the project construction contract.
Second, within the scope of the entrusted project (contract and supplementary agreement), any opinions and requirements (including claims) of the client or contractor to the other party must be put forward to the supervision institution first, and the supervision institution will study the disposal opinions and then negotiate with both parties. When there is a dispute between the client and the contractor, the supervision institution shall make independent judgment and mediate fairly according to its own functions.
Hereby entrust!
Authorized person (seal):
Date of authorization: year month day.
Power of Attorney for Supervision 6 Client: (hereinafter referred to as Party A):
Last name:
Decoration address:
Contact information:
E-mail:
Construction unit:
Trustee: (hereinafter referred to as Party B):
Name: Jilin Baijiaan Decoration Supervision Co., Ltd.
Contact telephone number:
Project leader:
Engineering inspection:
Authorization fee: in words: in figures: supervision type: () area:
Supervision Jifeng Supervision Tel: xxxxxxxxxxxxxxxx
Technical consultation telephone number: xxxxxxxxxxxxx
Customer service hotline: xxxxxxxxxxxxx
(Please read it carefully and leave a message online during the construction. )
Use it to explain.
1. The text of this contract is only applicable to family bedrooms within the administrative area of Jilin Province.
Maintenance and supervision projects,
2. The entrusted project supervisor (Party B) shall have the legal business license of the administrative department for industry and commerce.
3. The contractor of the supervision project shall implement the unified home renovation contract of the industrial and commercial administrative department and Jilin industrial system.
4. If Party A and Party B sign this contract directly, this contract is made in duplicate, with each party holding one copy.
(Contract Text) Part I: Purpose and Purpose
According to the Code for Quality Acceptance of Architectural Decoration Engineering issued by the Ministry of Construction, the Construction Department of Jilin Province and industry associations, in order to standardize and rectify the home decoration industry and safeguard the legitimate interests of consumers, we only accept the entrustment of decoration customers; Give full play to the positive role of professional home improvement supervision in four controls, two controls and one coordination, and adhere to the enterprise purpose of "being objective and fair, abiding by contracts, strictly supervising and serving wholeheartedly"; On the basis of equality, voluntariness and consensus through consultation, Party A and Party B have reached the following consensus on matters related to Party B's acceptance of Party A's entrustment to supervise and manage Party A's home improvement project.
Part II: Responsibility of Party A
A: After signing this power of attorney, before starting construction, Party A shall promptly provide copies of the construction contract text, budget, design drawings and bill of materials signed by Party A and the constructor, and submit them to Party B for supervision; In order to effectively supervise the construction enterprises in the construction process according to the contract and drawings. If the above information is not completely provided by Party A, the quality problem shall be borne by Party A..
B: If it is really necessary to dismantle or change the original building structure due to decoration, Party B shall be presented with the corresponding examination and approval procedures of relevant departments, the remedial measures of the constructor and the specific construction plan; Party A shall bear the responsibility for failing to provide it.
C: Party A shall actively cooperate with Party B's supervision work and clearly inform the constructor of Party A's authorization to Party B in this project. D: Party A must sign the supervision diary and acceptance data recorded by Party B for confirmation. Party B has informed it three times. If Party A still fails to sign the contents, Party B will not assume any responsibility for any project quality problems. Party A may entrust others to sign, but it will take effect only if a written power of attorney is provided.
E: If there are any additional items in the construction, Party A shall apply to the audit department of the company for a second additional audit. If Party A fails to apply for audit and notify the audit department of the company, it shall be deemed that the increase is not within the supervision scope of Party B, and Party B shall not bear any responsibility.
Part III: Responsibility of Party B
A: From the date of signing this power of attorney, Party B is responsible for reviewing the design scheme, construction drawings, budget, process description and contract terms of the construction enterprise selected by Party A. ..
B: Party B is responsible for supervising and managing the quality, schedule, cost and time limit control of this project.
C: Be responsible for the acceptance of materials provided by the construction unit (check according to the contract), concealed works (carpentry base and wall foundation treatment), facing, topcoat, wall and floor tile laying, mid-term acceptance and completion acceptance.
D: Party B is responsible for supervising the materials purchased by the construction unit according to the supervision procedures, such as spot-checking the quality grade of the wall and floor tiles, the actual quantity and quality acceptance of the water circuit renovation, the actual workload measurement of the completion acceptance, the accounting of the project payment payable, and the supervision of the suppression test. E: Be responsible for putting forward rectification opinions on the quality problems of the inspected projects, which shall be signed by the owner for approval.
F: Be responsible for providing Party A with the required technical support, and giving an easy-to-understand explanation of process production.
Part IV: Service types and charging standards.
A: A full-time supervision (cleaning accessories) b full-time supervision (cleaning accessories+main materials)
C full-time supervision (on-site) D single supervision
B: The construction period of Class A, B and C cleaning fittings shall be subject to the contract construction period between Party A and the constructor. Party A chooses a decoration company that is not officially registered and has no time limit agreement. The time limit agreed in the entrusted supervision contract is:/kloc-40 days within 0/00 square meter, 100-/kloc-50 days within 0/50 square meter, depending on the decoration area. If the project is overdue, Party A and Party B shall sign a supplementary supervision contract in written form through consultation, and the supervision fee shall be charged according to the daily 50 yuan.
C: If Party A requests to stop work. The service time shall be extended, but the cumulative extension time shall not exceed the agreed supervision time. D: If there is geothermal construction, you can enjoy a single preferential price of 300 yuan/geothermal. (belonging to the project of increasing supervision cost). E: Agreement on the installation and acceptance of service-oriented main materials B: The supervision period of main materials is set to complete the installation of main materials within 30 days after the completion of cleaning accessories, and the supervision scope of main materials includes the supervision of installation process and the acceptance of installation completion. (cabinets, floors, doors, lights
And)
Part V: Matters needing attention of both parties
Answer: If Party A finds that Party B's supervisor does not actively safeguard Party A's interests and has a special close relationship with decoration companies, construction teams, designers and material suppliers, it should actively report it after finding out so as to adjust the supervisor; Party A shall be responsible for the compensation for the economic losses caused by failure to report or perfunctory customer service call.
B: The quality evaluation criteria are: GB 50210-2001,GB 50327-2001,and DBJ/T 0 1-43. For high-grade home decoration with a cost of 2000 yuan per square meter, refer to "DBJ/T0 1-27-XXX".
C: If Party A commits any of the following acts, this contract will be automatically terminated:
(1) During the construction period, Party A gives money and things to the person in charge of Party B, and invites him to eat and drink or do private affairs for the person in charge;
(2) During the construction period, Party A entrusts Party B's supervisor to purchase materials and recommend construction units or workers. D: After the construction site starts, Party B's supervisor shall explain to Party A Party B's service specifications, supervision procedures, service purposes and various problems that should be paid attention to, and shall be responsible for reporting the site construction to customers.
E: This power of attorney shall come into effect after being signed by both parties, and the time agreed by the supervisor shall be counted from the date when the workers enter the site to start construction.
F: In case of quality problems during the warranty period, Party B shall conduct on-site investigation in time, issue written opinions at the same time, and cooperate with the owner and the construction party to solve them through consultation.
G: If Party A doesn't find a regular construction team to carry out decoration construction, our company is only responsible for quality supervision and acceptance in the construction stage, and issues such as expenses, construction period, warranty and disputes will be settled through consultation between Party A and the construction party, and it is not responsible for the coordination of quality assurance in the later stage. H: If Party A's renovation project has been partially completed, the completed project before Party B's intervention in supervision does not belong to Party B's scope of work. 1: If the construction party fails to complete the decoration work as agreed or part of the quality fails to meet the agreed standards or has been completed by the completion acceptance date of the project, and the completion acceptance is delayed due to the settlement between Party A and the construction party, Party B will only provide supervision.
Records as engineering evidence. If legal evidence or legal help is needed, the quality exploration commission or lawyer commission shall be handled separately. J: After the construction party provides the concealed engineering drawings, Party A will pay the final payment to the construction party according to the construction contract.
K: In the course of the project, if the contract cannot be executed normally due to a dispute between Party A and the construction party, and the contract needs to be terminated, Party B shall be responsible for the acceptance of the quality and quantity of the project before the end of the contract, and make reasonable suggestions to Party A on matters related to the termination of the contract.
Part VI: Liability for breach of contract
Answer: If one party fails to perform the agreement, it shall notify the other party in time. If no agreement can be reached through negotiation, the supervision fee shall be paid according to the actual date of the supervisor.
B: In case of quality accidents caused by technical reasons during construction, Party B is responsible for making compensation according to the unqualified items, and the maximum compensation amount is 200% of the total value of the unqualified items.
C: When the normal execution of entrustment is affected by irresistible factors, this entrustment agreement will be automatically terminated. (War, mountain torrents, earthquake, loss of civil capacity of either party, etc. ).
Part VII: Supplementary Provisions
A: From the date of signing this power of attorney, Party A will automatically become the supervisor of Party B, and Party A will be responsible for informing the supervision company of the contact number of the foreman within one week of commencement to ensure the smooth progress of the project.
B: This power of attorney is made in duplicate, one for each party.
C: This contract will be terminated automatically after the completion of performance.
D: The final interpretation right of this contract belongs to Baijiaan Supervision Company.
Part VIII: Other agreed matters
Party B's unit:
Legal representative:
Signature of Party A: signature of entrusted agent:
20xx Year Month Day 20xx Year Month Day