In the era of continuous progress, agreements are needed in many cases, and signing agreements can protect their rights and interests from infringement. You didn't even know when you drafted the agreement? Here are seven engineering agreements that I have compiled for you, hoping to help you.
Project Agreement 1 Project Construction Cooperation Agreement
Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
On the principle of equality, voluntariness and mutual benefit, Party A and Party B carry out strategic cooperation in the project construction. After discussing the cooperation in the first phase of the project, Party A and Party B reached the following agreement:
A comprehensive overview of the project
1, project name:
2. Project address:
3. Project construction scale: the construction area is about xxxx㎡.
4. Structure and story number: xxxx story frame-shear structure.
Second, the way of cooperation in engineering construction
1. Party A agrees that after Party B invests the initial funds for the project construction, Party B will contract the construction of some projects of this project in the form of contracting labor and materials for cooperation, so the unit price of this project is xxxx yuan/㎡ (including tax), and the project construction inspection fee (excluding physical inspection) shall be borne by Party A. ..
2. Within five days after the signing of this agreement, Party B shall pay Party A the project construction deposit (RMB): twenty million yuan; Party A shall assume the responsibility of capital guarantee with the company's project land, and guarantee to start construction before xx, xxxx, and the date of earthwork excavation of pile foundation shall be the project start time. If the project cannot be started before xx, xxxx, Party A shall pay interest on Party B's funds from xx, xxxx; That is to say, before the 5th of each month, Party B shall be paid the interest of RMB xx million per month. If the project cannot be started on xx, xx, Party A must calculate the interest from the date of payment by Party B and pay it to Party B at xx% of the monthly interest. Party A will unconditionally return all the deposit of 20 million yuan and interest of xx million yuan from xx to xx, xxxx, totaling xxxx million yuan. It must be paid within 5 working days (before xx, xx, xxxx). If the payment is not made in full, it shall be implemented according to Article 2 of the second project construction cooperation mode of this contract, that is, Party A shall assume the guarantee responsibility for the payment with the company's project land, and this project construction cooperation agreement shall remain valid.
3. Party A's contracting scope: According to the complete set of construction drawings of this project submitted by Party A, except for basement earthwork, aluminum alloy doors and windows, elevator door cover and curtain wall, outdoor hydropower and landscape engineering, fire protection, civil air defense, elevator equipment and dry hanging marble in podium, all civil works, hydropower installation, backfill earthwork and muck transportation within two meters of the external wall of this project include (but not limited to): the unit price includes (1) pile foundation engineering. (2) the basement project; (3) Major projects; (4) Roof engineering; (5) Indoor and outdoor decoration works; (6) Indoor water supply and drainage, strong and weak electricity installation works; (7) Energy-saving and thermal insulation project; (8) Hall decoration (the buried depth of pile core shall not exceed 10m, and the designed steel content shall be 58kg/m2).
4. Price calculation basis:
(1) The increase or decrease of the project, settlement and fee collection shall be carried out according to Hunan Construction Project Valuation Method (Xiang Jian Jia [20xx] No.406) and corresponding supporting documents, and the wages of migrant workers shall be adjusted according to 56 yuan/day.
(2) Price adjustment of main materials (steel bars, commercial concrete, cement, bricks): it will be issued and implemented according to Hengyang project cost during the construction period, and it will not be adjusted within 3% of the difference between the weighted comprehensive average release price of each period and the release price of the same period when the contract is signed during the construction period of the main contract project. If it exceeds 3%, the prices of the above four main materials will be adjusted. Specific in the "construction contract" for clear.
5. Payment method of project funds:
(1) Party A shall submit the construction drawings approved by relevant departments to Party B for budget and construction organization design. Both parties sign the construction contract according to the relevant provisions of this agreement. Within five working days after Party B enters the site to start construction, Party A will return the project construction deposit of 8 million yuan to Party B to start construction, 2 million yuan to Party B within five working days after the foundation project is completed, 3 million yuan to Party B within five working days after the basement project is completely completed, and 3 million yuan to Party B within five working days after the main project is completed. Pay Party B 4 million yuan within five working days after the main project is capped.
(2) After Party B completes the engineering foundation and all basement projects, Party A shall pay the project progress payment to Party B at the unit price of 1.600 yuan /m2. Party A shall pay the project progress payment to Party B at the unit price of 1 1,000 yuan/m2 (including water and electricity installation project) every time the second floor of the main project is completed. Within the scope of the project, Party A shall pay the project progress payment to Party B at the unit price of 230 yuan/m2 (each payment period shall not exceed 10 day).
(3) After the completion acceptance is approved by the relevant municipal departments in accordance with the regulations, the project settlement will be carried out after the data is handed over, and the time will be completed within four months.
(4) After the project acceptance and settlement, Party A will allocate the project to Party B until it reaches 97% of the total cost, and keep 3% as the project quality deposit, which will be paid within one month after the project warranty period expires.
(5) Content and basis of allowable adjustment during the construction period: both parties shall sign a construction contract separately. Party B shall carry out the construction in strict accordance with the approved construction drawing, and contract the construction according to the lump sum price of 65,438+0 square meters in 420 yuan agreed by both parties. If the total cost is affected by policy adjustment, design change and material price, both parties can adjust the lump sum cost if it is confirmed that the cost of a single project is more than 50,000 yuan.
Three, the treatment of engineering construction enterprises and the calculation of major design changes.
1. Party A shall be responsible for the three links and one leveling on the construction site, and its expenses are not included in the lump sum fee.
2. Party B must have its own financial strength and corresponding engineering construction contracting qualification, and handle relevant construction filing procedures according to legal procedures.
3. For major design changes (referring to the structure, scale and standard), the engineering drawing design department shall issue a description of the changes, and Party B shall be responsible for the construction. This fee is not included in the progress payment, and the total fee will be adjusted according to the visa amount actually issued by both parties at the time of completion settlement.
Fourth, the project engineering warranty
1. The warranty of this project shall be implemented in accordance with the Regulations on Quality Management of Construction Projects (Order No.279 of the State Council of the People's Republic of China).
Verb (abbreviation of verb) and other related matters
1. Party B is responsible for the contracting qualification (with corresponding construction contracting qualification), and the labor insurance fund paid by Party A will be returned to Party B according to the policy, and the bid-winning work will be completed according to legal procedures, and Party A will cooperate.
2. Party A only recognizes the construction unit that signed the construction contract, and Party B shall not subcontract the project construction and ancillary works to others under any excuse. In case of the above situation, Party A has the right to take back the construction project signed with Party B, and the expenses and liabilities for breach of contract arising therefrom shall be borne by Party B, and Party A will choose another construction unit.
3. The project quality, safety and civilized construction management and time limit for a project will be implemented in strict accordance with the contract terms and general contract terms of the competent construction department.
Liability for breach of contract of intransitive verbs
If either party breaches the contract, it shall pay the other party a penalty of RMB 3 million only.
Seven. This agreement is made in quadruplicate, one for each party.
The above agreement shall come into effect after being sealed and signed by the responsible persons of both parties, and Party B shall pay the project construction deposit of 20xx yuan before September 10. Before the project starts, this agreement will automatically become invalid after both parties sign a construction contract separately.
Party A: (Seal) Party B: (Seal)
Legal representative: (signature) Legal representative: (signature)
Agent: (signature) Agent: (signature)
Year, month, year, month, year
Part II of Project Agreement Party A (Employer)
Party B (Contractor)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction project contracting and signed this contract for mutual compliance.
I. Project name:
Second, the project site selection:
Three. Project content: civil engineering, water and electricity, etc.
Fourth, the construction period:
Verb (abbreviation of verb) Engineering quality requirements: qualified.
6. The general contracting of the project is about 1 ten thousand yuan.
7. Project contracting method and charging standard: quantity contracting, (how much is a square meter)? Or calculate the direct fee plus %25 management fee according to the national quota? Eight. Appropriation and settlement method of the project price: after 65,438+05% of the total cost is paid for the foundation completion, 65,438+00% of the total cost will be paid for each floor, and the remaining 65,438+00% will be paid in one lump sum with the tax invoice after the project acceptance. After three years, 5% will be kept as the project quality deposit, and if there is no project quality problem, it will be paid to Party B in one lump sum.
Nine, this project by Party B according to the construction progress of the supply of materials, its specifications, models, etc. It can only be used after Party A's verification and visa.
X inspection and acceptance: party a of this contract requires party b to accept four aspects of inspection before settlement:
1. Safety in production: Party B shall strengthen safety education, conscientiously implement safety technical specifications, strictly abide by the safety system, and implement safety measures to ensure construction safety.
2. Project quality: adhere to the project quality standards, and carefully organize the construction in strict accordance with the design drawings, construction acceptance specifications, construction organization design, construction technical scheme and other related requirements to ensure the project quality meets the agreed requirements.
3. Civilized construction: strengthen the management of the construction site, strictly implement the management regulations of the competent construction department, environmental protection, fire protection, health and other relevant departments on the construction site, and achieve civilized construction.
XI。 Party A's responsibilities:
1. Organize relevant personnel to educate Party B's construction personnel on safety, quality, civilized construction and comprehensive management, and do a good job in daily supervision.
2. Organize and be responsible for the disclosure of construction technology and measures to Party B's construction personnel.
3. Be responsible for guiding and supervising the safety, engineering quality and civilized construction of Party B's construction personnel, and make timely acceptance according to regulations.
4. Pay the project payment to Party B in full and on time according to the contract.
Twelve. Party B's responsibilities:
1, according to Party A's disclosure requirements, and in strict accordance with national operation specifications and construction acceptance specifications, carefully organize the construction.
2, according to the requirements of Party A's time limit for a project plan, carefully prepare the construction operation plan, and complete the monthly time limit for a project plan issued by Party A on time every month.
3. Pay the contract fee for each type of work in full and on time as agreed in the contract.
4, strictly implement the provisions of the safety agreement, the implementation of the construction site safety measures, to do a good job of foundation.
(1) Party B shall provide Party A with valid certificates such as Business License of Enterprise as a Legal Person and Certificate of Enterprise Qualification Grade.
(2) Party B's production and operation personnel entering the construction area of Party A shall show their identity certificates, operation certificates for special types of work and other valid certificates.
6. Party B shall strengthen the management of laborers and consciously abide by various management regulations.
Thirteen. When signing this contract, Party A and Party B must also sign the following contract annexes. The following annexes have the same legal effect as this contract.
1, safety production agreement;
2, public security, safety, fire prevention and other agreements.
14. Party A and Party B may separately agree on matters such as materials, equipment, tools and technology.
Fifteen. Liability for breach of contract:
1. In any of the following circumstances, Party A shall be liable for breach of contract:
(1) If Party A fails to verify Party B's engineering quantity as agreed, or fails to pay the labor operation project funds as agreed, or fails to pay the final payment of the labor operation project funds as agreed, it shall pay Party B the interest on overdue labor operation project funds according to the loan interest rate of Party B's bank for the same period, and pay Party B a penalty of 5 ‰ per day according to the arrears;
(2) When Party A fails to perform or fails to perform its obligations as agreed in the contract, it shall pay 5 ‰ of the liquidated damages to Party B, compensate Party B for the economic losses caused by its breach of contract, and postpone Party B's delayed working hours. ..
2. In any of the following circumstances, Party B shall be liable for breach of contract:
(1) If the completion of the project is delayed due to Party B's own reasons, Party B shall pay liquidated damages of RMB to Party A for each day of delay;
(2) When the quality of the project constructed by Party B does not meet the quality requirements agreed in the contract, but can meet the minimum standards stipulated by the state, Party B shall pay Party A a penalty of 5,000 yuan.
(3) When Party B fails to perform or fails to perform its obligations as agreed in the contract, it shall pay Party A RMB as liquidated damages, and Party B shall also compensate Party A for the economic losses caused by its breach of contract, and the delayed working hours of Party B shall not be postponed.
3. When one party breaches the contract and the other party requests the breaching party to continue to perform the contract, the breaching party shall continue to perform the contract after assuming the above liabilities for breach of contract.
16. Party A appoints Comrade as the on-site person in charge of this project, and Party B appoints Comrade as the on-site person in charge, and both parties are responsible for fulfilling the provisions of this contract.
Seventeen. Controversy:
Any dispute between Party A and Party B during the performance of this contract can be settled through negotiation. If negotiation fails, a lawsuit can be brought to the court where the project is located.
18. This contract shall come into effect as of the date of signing, and shall become invalid after all project operation contents are completed and accepted and the project price is settled.
19. For matters not covered in this contract, Party A and Party B may sign a supplementary agreement through consultation. The original of this contract is in triplicate, with each party holding one copy.
Three copies, Party A holds two copies and Party B holds one copy.
Party A (Contract Seal) Party B: (Contract Seal)
Legal representative:
Authorized Agent: Authorized Agent:
Address: Address:
Tel: Tel:
Bank of deposit: Bank of deposit:
Account number: Account number:
Year, month and day symbol
Part III of the Project Agreement Party A: Gong Xin Primary School in Wantun Town.
Party B: Gong Xin Primary School Public Rental Housing Contractor.
Because there is no dormitory in our school, teachers are not at school after school, weekends, winter and summer vacations. In order to strengthen the safety production management of the construction site of the project under construction and ensure the smooth progress of the construction project. In order to promote safe production and civilized construction and ensure the safety of teachers and students in our school, Party B shall strictly abide by the provisions of this agreement through consultation between Party A and Party B to ensure the safety of teachers and students in our school during the construction period.
First, the safety management of the school project under construction:
1. When the school is not in normal class, the school construction personnel will open the door by themselves and must lock it after opening the door. If it is not locked, Party B shall be responsible for all safety accidents that occur after students and social workers enter the campus.
2. If Party B locks the iron gate when entering or leaving, and students and social workers enter the campus in other ways, Party B will not bear any responsibility for safety accidents.
3. During the construction period, Party B has the right to prevent students and social workers from entering the fence, not to mention the building under construction. If students and social workers enter the building, Party B shall be responsible for the safety accidents.
4. During the construction period, Party B shall pay attention to the safety of construction, electricity consumption and falling objects. Non-construction personnel shall not be allowed to enter, otherwise Party B shall be responsible for the safety accident.
Second, others:
Matters not covered in this agreement can also be settled by both parties through consultation.
1. This agreement shall come into force as of the date of signature and seal. After the completion of the project, this agreement will be automatically terminated after it is accepted by the higher authorities.
2. This Agreement is made in duplicate, with each party holding one copy.
3. Xiao Jinben is the school security guard, who is responsible for opening and closing the school gate.
Party A: Gong Xin Primary School in Wantun Town.
Party B:
date month year
Article 4 of the Project Agreement Party A (the Employer): Contact person:
Party B (Contractor): Contact information:
Party A will contract the renovation project to Party B _ _ _ _ _ _ _ _ Party B.
The renovation period given by Party A to Party B is 20xx. In the absence of special circumstances, neither party can delay the time. Who is responsible for major problems?
Party A's work: provide Party B with necessary conditions such as water and electricity needed for construction, and explain matters needing attention in use. Party B shall be responsible for providing the drawings, and the designer shall make disclosure, and the construction shall be carried out according to the drawings. Without special circumstances, Party A shall not make any changes on its own.
The contracting method is Party B's cleaning work (water, electricity, bricklayer, carpenter and painter only).
Material supply agreement: All materials for this project shall be provided by Party A and transported to the site. (Including paint brushes, rollers, etc. )
The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Party B must assist Party A in handling the acceptance formalities. If there is any quality problem or specification difference in the materials and equipment supplied by Party A, Party B shall promptly raise it with Party A; if Party A still says that it will be used, Party A shall bear the responsibility for the engineering losses. After the materials supplied by Party A arrive at the site, they shall be accepted by both parties, and Party B shall be responsible for organizing the construction. Party B shall be responsible for compensation for material losses caused by improper construction technology.
In order to ensure the normal progress of the project, Party B must submit the material purchase list of the next process to Party A at least three days in advance. Party A shall provide information required by Party B on time. Party A shall bear the consequences of project delay caused by Party A's delay in providing materials. ..
5. Complete the quantity of water, electricity, masonry, carpentry and painting according to the drawings and agreements. If there is any change, it shall be decided by both parties through consultation. See the back for detailed bill of quantities.
6. Payment method: The total project contract amount is RMB _ _ _ _ _ _ _ _ _.
7. Responsibility of Party B: Party B shall ensure the quality and quantity and complete the project on time. If Party B has decoration quality problems, Party A has the right to refuse to pay the project payment.
8. I hope both parties will abide by the above agreement. Matters not covered herein shall be discussed separately by both parties.
9. This contract is made in duplicate, one for each party, with the same legal effect.
Signature of Party A: Contact person:
Signature of Party B: Contact person:
Date, year and month
Article 5 _ _ _ _ _ _ _ _ _ (hereinafter referred to as the "Client") of the Project Agreement and _ _ _ _ _ _ _ _ (hereinafter referred to as the "Engineering Consulting Unit") entered into this Agreement through negotiation.
1. The customer entrusts the engineering consulting unit to provide _ _ _ _ _ (indicate the entrusted service content) consulting services, and has accepted the documents such as the proposal and quotation put forward by the engineering consulting unit to perform the services.
2. The terms in this agreement are synonymous with the terms in the service agreement and related annexes.
Three. The following documents are an integral part of this agreement:
(1) Power of attorney or letter of acceptance;
② General terms and conditions of engineering consulting service agreement;
③ Special conditions of engineering consulting service agreement;
(4) Accessories, namely
Annex a scope of entrusted engineering consulting services;
Annex B Services provided by customers for employees, equipment, facilities and other personnel;
Appendix c remuneration and payment;
⑤ * * Supplementary and modified documents signed during the implementation.
Four. In view of all the money paid by the customer to the engineering consulting unit according to the following provisions, the engineering consulting unit promises to undertake consulting services within the agreed scope in Annex A according to the provisions of this Agreement.
5. In view of the fact that the engineering consulting unit performs consulting services in accordance with the above provisions, the customer promises to pay the amount specified in this agreement to the engineering consulting unit in accordance with the time limit, method and currency specified in this agreement as a reward for performing services.
6. All disputes arising from or related to this Agreement shall be settled through friendly negotiation. If negotiation fails, the case shall be submitted to South China International Economic and Trade Arbitration Commission for arbitration. The arbitral award is final and binding on both parties.
Seven. This agreement is made in duplicate, with the same legal effect, and each party holds one copy. Each party holds one copy.
This agreement shall come into effect after being signed by the representatives of both parties and stamped with the official seal of the unit.
Client: (Signature) Engineering Consulting Unit: (Signature)
Legal representative: (signature) Legal representative: (signature)
Address: Address:
Authorized representative (signature): Authorized representative (signature):
Bank of deposit: Bank of deposit:
Account number: Account number:
Post: post:
Tel: Tel:
Chuan Zhen: Chuan Zhen:
Electrical sub-box: electrical sub-box:
Signed on the day of the month.
Article 6 of the Project Agreement Party A: _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Through consultation, Party A and Party B have reached the following agreement on compensation for capital removal of construction projects:
1. After settlement by both parties, it is confirmed that Party A owes Party B RMB _ _ _ _ _ _ _ _.
Second, the guarantee clause:
1. Party A guarantees that the above-mentioned buildings with deducted project funds have not been sealed up, mortgaged or sold for other reasons;
2. Party A guarantees that after the signing of this agreement, the house after deducting the project payment will not be sealed up or mortgaged due to Party A's reasons, so that Party B's rights cannot be realized;
3. Party A guarantees that there is no dispute over the property right of the house after deducting the project payment, and can apply for the property right certificate at this stage;
4. Party A promises not to sell the house for which the project payment has been paid without written notice from Party B; (Party A guarantees that Party B fully enjoys the ownership of the mortgaged house and the right to freely buy, sell, lease, transfer and mortgage).
5. Party A guarantees to complete the property right certificate of the building and pay the project payment within 30 days from the date of signing this agreement.
Three. After the signing of this agreement, Party B has the ownership of the above-mentioned buildings (including but not limited to self-use, lease, transfer, mortgage, etc.). ).
Four. After the signing of this agreement, Party B has the right to go through the registration formalities of house property right immediately. If it fails to go through the registration formalities temporarily, Party B has the right to change its name for free. Party B may notify Party A in writing, sign a house purchase contract with a third party, and go through the formalities of house property registration.
Verb (abbreviation of verb) Property management fee:
1. If Party B or the owner moves in within 12 months after the signing of this agreement, the property management fee shall be paid according to the actual moving-in time;
2. After the signing of this agreement, if Party B or the owner stays for more than 12 months, he shall pay the property management fee according to relevant regulations.
6. Taxes, transaction fees, etc.
1. Party A must cooperate with Party B or the third party designated by Party B at any time to go through the formalities of purchasing the house, including but not limited to signing the commercial house purchase contract, issuing invoices, providing relevant information, and handling the real estate ownership certificate;
2. Party A and Party B shall bear the taxes and transaction fees for handling the real estate license respectively according to regulations.
Seven, construction sales
1. When Party B uses the house for his own use, Party A shall cooperate with Party B to handle the house ownership certificate;
2. From the date of signing this agreement, Party B may entrust Party A or a third party to sell the house for which the project payment has been paid. If Party A is entrusted to sell, a separate agreement shall be signed;
3. From the date of signing this agreement, Party B may sell the house for which the project payment has been paid by itself;
4. No matter how Party B handles the house, Party A shall cooperate with relevant procedures. Party A shall go through all corresponding procedures (including but not limited to pre-purchase registration, real estate ownership certificate, etc.). ) According to the requirements of Party B or the property owner.
Eight. responsibility for breach of contract
If the house from which the project payment has been deducted is sealed up, mortgaged or sold due to Party A's reasons, or the property right certificate cannot be handled on schedule, Party B has the right to require Party A to pay 10% of the house price as liquidated damages, and provide other housing compensation or compensate for all losses.
IX. This contract shall be valid until all buildings with deducted project funds have completed the Property Ownership Certificate.
X. Matters not covered in this contract shall be settled by both parties through consultation. If negotiation fails, either party may bring a lawsuit to the people's court with jurisdiction.
XI。 This agreement shall come into force after being signed and sealed by all parties. This agreement is made in quadruplicate, with each party holding two copies.
Party A (seal): _ _ _ _ _ _ _ _ _ _ _ _
Authorized representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (seal): _ _ _ _ _ _ _ _ _ _ _ _
Authorized representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _