In our daily life, agreements are used in many places, and signing agreements can bind both parties to fulfill their responsibilities. Let's refer to how the agreement is written. The following is a sample (3 selected articles) of the simple intermediary project introduction fee agreement I collected for you, for reference only, and I hope it will help you.
Agency project introduction fee agreement 1 Party A (introducer):
Party B (product engineering service provider):
Project Name: Building Fire Protection Project
Through negotiation, Party A and Party B have reached the following agreement on the above items:
1. For this project, if Party A imports Party B's equipment and orders from Party B's company, Party B will withdraw an introduction fee of 5% (after tax) of the contract amount from Party A..
2. Specific royalty method: Party B shall pay the same proportion to Party A after receiving the order payment. When Party B receives 95% of the contract amount, it will pay all the introduction fees to Party A. ..
3, this project if you don't use the equipment of Party B's company, not from Party B.
Company orders, this agreement will be automatically terminated:
4. This agreement is only for the above-mentioned _ Dingcheng project, and other agreements are valid.
5. Liability for breach of contract: Party B shall contact relevant companies through Party A's introduction, and give up Party A's breach of contract, and shall pay 200% of the above equal remuneration as liquidated damages.
6. This agreement is made in duplicate, each party holds one copy, which has legal effect.
7. Solution by agreement: In case of any dispute, both parties shall submit it to the Haizhu District Court of Guangzhou for trial.
Party A:
Party B:
Signature time: year month day.
Intermediary project introduction fee agreement 2 Party A:
Party B:
Based on the principles of equality, mutual benefit, coordination and cooperation, honesty and friendship, Party A and Party B have reached the following conditions and commitments on the earthwork leveling project of Pengjiawan Phase II project in Guiyang through consultation, and signed this agreement:
I. Obligations and responsibilities of Party A
1. On the basis of fully understanding the earthwork leveling project contract and project of Pengjiawan Phase II project in Guiyang, provide Party B with real information and assist Party B to sign the earthwork leveling project contract of Pengjiawan Phase II project in Guiyang.
2. Ensure the authenticity of the project and coordinate China Tunnel South Construction Co., Ltd. Guizhou Branch to sign the project construction contract with Party B. ..
Two. Obligations and responsibilities of Party B
1. Party B actively cooperates with Party A to track the owner's project progress.
2. According to Party A's understanding of the earthwork contracting of Pengjiawan Phase II project in Guiyang and its trust and confidence in obtaining the construction contracting right, Party A has the responsibility to provide true and effective information, construction funds and construction strength, labor remuneration and payment methods. Party A is designated as the sole coordinator, and a third party (referring to another contact) cannot be designated as the coordinator.
Third, pay remuneration.
1. After Party A assists Party B in obtaining the construction contracting right of earthwork leveling project of Pengjiawan Phase II project in Guiyang, Party B shall pay Party A% of the total project amount as labor remuneration.
2. Within three days after the signing of the construction contract of this project, the remuneration received by Party A shall be paid by Party B to Party A in one lump sum.
Fourth, the liability for breach of contract
(I) Party A's liability for breach of contract
1. After the signing of this contract, Party A shall not accept any third-party service (construction team) to carry out this project without Party B's breach of contract.
2. After the signing of this agreement, if Party A entrusts this project to other construction teams, it will be regarded as Party A's breach of contract and compensate Party B for liquidated damages of 50,000 yuan.
If Party B refuses to cooperate with Party A, Party A has the right to seek other cooperators.
(II) Party B's liability for breach of contract
1. After the signing of this contract, if Party B completes the transaction with the intermediary (including directly or indirectly), it shall be deemed that Party A has completed the work, and Party B shall pay the labor remuneration agreed in Article 3, paragraph 1 of this contract to Party A, and Party A has the right to recover the labor remuneration indefinitely and bring a lawsuit to the court.
2. After the signing of this agreement, if Party B contacts a third party (another contact person) on this project, it will be regarded as Party B's breach of contract, and Party A will be compensated with a penalty of 500,000 yuan.
Verb (abbreviation for verb) is confidential.
In this service project, Party A and Party B have a permanent obligation to keep confidential any business secrets and personal privacy of the other party, and shall not disclose or use them without authorization. This contract is made in triplicate, one for each party and witness. If Party B has no opinion on the agreement and contract proposed by Party A, it will take effect from the date of signature by both parties.
Party B:
Party A:
Witness:
date month year
Intermediary project introduction fee agreement 3 Party A:
Party B:
Based on the principles of equality, mutual benefit, coordination and cooperation, honesty and friendship, Party A and Party B have reached the following conditions and commitments on the _ _ _ _ project through consultation, and signed this agreement:
I. Obligations and responsibilities of Party A
1. Party A shall provide the known engineering information of this project and assist Party B to sign the construction contract of this project and provide services.
2. Ensure the authenticity of the items and materials provided by Party A. ..
Two. Obligations and responsibilities of Party B
1. Party B actively cooperates with Party A to track the owner's project progress.
2. Actively provide Party A with its own real information and ability, labor remuneration and payment methods, and designate Party A as the sole coordinator, not the third party.
3. Party B helps Party B to obtain the project under the terms of the contract agreed between Party A and the owner (or under the condition that Party A introduces Party B and the owner to reach an agreement on the terms of the contract directly). Party B must recognize all the agreed terms of the contract, and shall not make other unreasonable demands on the way, and Party B shall bear all the losses caused thereby.
Third, pay remuneration.
1. After Party A helps Party B obtain the project contracting right, Party B shall pay Party A% of the total project settlement price as labor remuneration. After the signing of this project, the remuneration received by Party A will be paid in _ _ installments, with _ _% for the first project payment, _ _% for the second project payment and _ _% for the third project payment. If Party B fails to pay the remuneration, Party A has the right to ask the owner or subordinate unit to deduct it.
Fourth, the liability for breach of contract
(I) Party A's liability for breach of contract
1. Before and after the signing of this contract, Party A shall not introduce this project to any third party without Party B's breach of contract.
2. After the signing of this agreement, if Party A sends another construction team to carry out this project, it will be regarded as Party A's breach of contract and compensate Party B for the liquidated damages of RMB.
3. If Party B refuses to cooperate with Party A, Party A has the right to find other cooperators.
(I) Party B's liability for breach of contract
1. If Party B completes the transaction (including direct or indirect) with the owner or other intermediary before the signing of this contract, it shall be deemed that Party A has completed the work, and Party B shall pay Party A the labor remuneration agreed in Article 3, paragraph 1, of this contract. Party A has the right to recover the remuneration indefinitely and bring a lawsuit to the court.
2. After signing the contract of this project, Party B shall immediately organize funds and human resources to actively carry out the work, and shall not subcontract or excuse not to start the work. If Party B breaches the contract, Party B shall bear all losses and compensate Party A for the liquidated damages of RMB.
Verb (abbreviation for verb) is confidential.
In this service project, Party A and Party B have the obligation to keep any business secrets and personal privacy of the other party confidential forever, and shall not disclose or use them without the permission of the other party, and the responsible party shall bear all legal responsibilities for any adverse consequences caused thereby.
This contract is made in triplicate, one for each witness. This contract will take effect as soon as it is signed.
Party A:
Party B:
Witness: Year Month Day
;