Reservoir Construction Contract 1 Party A:
Party B:
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on this construction project.
I. Overview of the Project:
Project name: fire pool;
Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Project area: the project construction area is 199.5 square meters;
Project cost: The total project cost is 520,000 yuan, in words: five hundred and twenty thousand yuan only.
Second, the contract period:
This project started in 20 _ _ _165438+1October 10, and was completed in 20 _ _ _1October 26 +65438. Total calendar days are 16 days.
Third, the way of contracting:
Contracting method: take the form of contracting for work and materials.
Fourth, quality standards.
(a) the overall reinforced concrete pouring, pool 30 cm above the ground, install stainless steel railings.
(two) the project quality standards according to the current national construction norms acceptance;
(3) The project warranty shall be implemented in accordance with relevant regulations, and the warranty shall be calculated from the date of signing the completion acceptance;
V. Payment method of project funds
(1) Party B completes 50% of the engineering quantity, and Party A pays 30% of the total cost to Party B;
(2) Within seven days after the project completion acceptance, Party A shall pay 90% of the total settlement price;
(3) The remaining 65,438+00% of the project payment shall be settled in one lump sum within one year from the date of completion acceptance.
Scope of responsibility of intransitive verbs
(1) Party A's responsibilities:
1, responsible for solving construction water, electricity and roads;
2. Organize the project completion acceptance in time;
3. Handle the completion acceptance within the time limit stipulated in this contract, and pay the project payment to Party B..
(II) Party B's responsibilities:
1. Ensure the construction quality according to the construction safety specifications, carefully construct, complete and deliver on time, and Party B shall be responsible for any construction quality and safety accidents during the construction;
2. Party B has the obligation to repair the damage and deformation of Party A's adjacent facilities during the construction period;
3, responsible for cleaning up the construction waste in time, after the project construction, responsible for cleaning up the construction waste.
Seven. any other business
(1) Matters not covered in this contract shall be studied and supplemented by both parties and have the same legal effect as this contract.
(2) Any dispute arising from the execution of the contract shall be settled through friendly negotiation. If negotiation fails, it may be submitted to the relevant arbitration institution for adjudication.
(III) This contract is made in duplicate, with each party holding 1 copy.
Party A (seal): person in charge:
Party B (seal): person in charge:
date month year
Reservoir Construction Contract 2 Party A:
Party B:
Party A entrusts Party B to be responsible for the blasting design and construction of the stone works in the water pool of the capital construction site. Both parties reached the following agreement through consultation:
I. Project Location:
Two. Engineering quantity: about m3
Three. Project cost: RMB.
4. Payment method: When Party B's equipment enters the site to start drilling, Party A will pay Party B 50% of the project cost, and the balance will be paid in one lump sum after the project is completed.
Verb (abbreviation of verb) Responsibilities of both parties:
(1) Party A's responsibilities:
1. Be responsible for removing the original turquoise and eluvial soil in the pool to facilitate Party B's drilling operation.
2. Send someone to assist Party B in blasting safety alert.
(II) Party B's responsibilities:
1. Responsible for handling blasting construction procedures with relevant government departments.
2. Be responsible for the safety of the whole blasting process, and ensure that the blasting will not affect and destroy the structure of Party A's # residential building.
3. The homework personnel show certificates.
4. Strengthen security alert.
Liability for breach of contract of intransitive verbs:
1. Party B completes the blasting construction as required by Party A..
2. Party A shall settle the project payment on time, and shall not default on the project payment under any excuse.
Seven. Matters not covered in this contract shall be settled by both parties through consultation.
Eight. This contract is made in quadruplicate, with each party holding two copies.
Party A: Party B:
Representative of Party A: Representative of Party B:
Reservoir Construction Contract 3 Employer:
Contractor:
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and the specific conditions of this project, the following agreement is reached:
1. Project content
Party B shall complete the construction of fire pool, water pump house, fence and building protection foundation.
2. Contract method and contract price
Contracting method: contracting for labor and materials, and fixed comprehensive unit price.
Contract Price: The total price is RMB 198 100 Yuan (in words: one hundred and ninety-eight thousand one hundred Yuan only). The comprehensive unit price is fixed, and the quantities are settled according to the actual quantities recognized by the contractor and the employer. Repairing the ground, punching the wall, iron gate, pump house equipment and underground pipeline are not included in the total price, and will be settled according to the actual quantities after completion.
The comprehensive unit price is shown in the following table: Bill of Quantities Quotation Table.
Bill of quantities quotation sheet
3. Quality requirements: qualified
The technical standards and specifications quoted or involved in this contract shall be the latest valid version still in use in People's Republic of China (PRC) when this contract is signed.
4. Payment method:
Appropriation method: 20% of the contract price shall be paid when the contractor's construction personnel and facilities enter the site; When 50% of the project construction is completed, 25% of the contract price shall be paid; Once the project is completed and accepted, it will be paid at one time.
5, time limit for a project:
5. 1 Planned commencement date: 20 _ _ _ _ _; Planned completion date: year month day.
5.2 Party B shall enter the site for construction according to the time required by Party A. Party B guarantees to complete the project on schedule. In case of delay due to Party A's reasons, on the day of the incident, Party B's on-site project manager will apply and the work will be postponed after being confirmed by Party A's on-site representative.
6. Inspection standard, method, place and time limit: After the construction is completed, Party A and Party B shall organize the acceptance and notify Party B in writing within three days after the acceptance. If Party B fails to receive the notification of acceptance result from Party A within three days after acceptance, the project will be deemed as qualified.
7. Work of both parties:
7. 1 Party A's work
7. 1. 1 Supervise and inspect the construction process of Party B. ..
7. 1.2 Organize relevant personnel to accept the project.
7. 1.3 Pay the project payment according to the contract.
7. 1.4 Provide water and electricity supply to ensure that there are no obstacles that hinder the smooth progress of construction on the construction site.
8.2 Work of Party B
8.2. 1 Party B shall carry out the construction in strict accordance with Party A's requirements. Obey the command of Party A and management.
Responsible for the project, project progress, technical quality, safe construction, inspection and acceptance, warranty and other matters.
8.2.2 Do a good job in site safety management according to the requirements of construction safety specifications, and set up site lighting and maintenance facilities as needed to prevent industrial accidents and ensure the safety of life and property of site personnel. In case of an accident, it shall be handled actively and reported to Party A and relevant departments immediately, and the losses caused thereby shall be borne by Party B. ..
8.2.3 Do a good job of finished product protection before project delivery.
9. Warranty period:
The warranty period is one year after the acceptance of this project.
10. Liability for breach of contract:
10. 1 If Party A fails to perform its obligations as agreed in the contract, it shall compensate for the economic losses caused to Party B; If the construction period is delayed due to Party A's responsibility, the construction period will be postponed, and the expenses arising therefrom shall be borne by Party A. ..
10.2 party b's liability for breach of contract
If Party B fails to complete the project within the time limit stipulated in the contract or fails to pass the acceptance, it shall be liable for breach of contract. If the construction period is delayed due to Party B's reasons, the construction period will not be postponed.
1 1. Handling of breach of contract: if one party breaches the contract, the other party may terminate or terminate the contract, and the breaching party shall bear corresponding responsibilities.
12. Dispute settlement: In case of any dispute during the performance of the contract, both parties shall settle it through negotiation in a timely manner on the principle of fairness and reasonableness. If negotiation fails, it may apply to Shouguang Arbitration Commission for arbitration or bring a lawsuit to the people's court in the place where the contract is performed.
13. Entry into force and termination of the contract: This contract shall come into force as of the date of signature by both parties. The contract price shall be terminated after payment.
14. supplementary agreement: for matters not covered in this contract, both parties can sign a supplementary agreement, which has the same legal effect as this contract.
15. Number of copies:
This contract is made in triplicate, one for each party and one for the manager.
Party A:
Party B:
date month year
Reservoir Construction Contract 4 Party A:
Party B:
Based on the principles of equality, mutual benefit, fairness and voluntariness, Party A and Party B have reached the following terms through friendly negotiation for common compliance.
I. Overview of the Project
1. Project name: waterproofing of clean water pool and water leakage treatment of coal conveying pit in Siyang Zhiying Thermal Power Plant.
2. Project location: Siyang County Economic Development Zone.
3. Project content:
3. 1( 1) wall plugging is based on engineering glue, cement, hole plugging and joint sealing.
(2) Permeable cement-based crystalline surface.
(3)JS-2 type twice.
3.2 The waterproof surface on the inside of the clear water pool is * * * square meters, including the bottom, east, west, south and north.
3.3 600 yuan for waterproof treatment of coal pit leakage.
4. The unit price of clear water pool waterproofing in this contract project is 30 yuan /m2, and the cost of clear water pool waterproofing project is RMB (in words), so there is no need to adjust the price.
5. The total project cost of this contract is RMB (in words) (including tax).
2. Quality requirements and acceptance criteria
(1) conforms to the Quality Acceptance Standard for Underground Waterproofing Engineering (GB50208-2022).
(2) Full-water test, the pool is filled with water for 72 hours without water leakage.
3. Time limit for a project requirements
Waterproofing of clean water tank: February 2, 65438+20 _ _ _—February 7, 65438+20 _ _ _ (completion); Treatment of coal bunker water leakage: 20x65438+February 8-20x65438+February 9 (completion).
Four. Payment method (bank transfer)
After the project is completed and accepted, 50% of the project payment shall be paid within 7 days. After 2 months, the remaining project funds will be settled without quality problems, and the contract will automatically become invalid.
Party A: Party B: (signature) (seal) ID number: authorized representative:
Date: Bank: Account Number: Date:
Reservoir Construction Contract 5 Party A:
Party B:
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and the specific conditions of this project, the following agreement is reached:
/
2. Contract method and contract price
Contract method: total price (including tax).
Contract Price: The total price is RMB (in words: ten thousand yuan only).
3. Quality requirements
According to the design drawings provided by Party A, the construction can reach the national acceptance standard. The technical standards and specifications quoted or involved in this contract are the latest valid version still in use in People's Republic of China (PRC) when this contract is signed.
4. Payment method: 95% of the total price shall be paid after the project is completed, and 5% of the quality deposit shall be paid one year later.
5, time limit for a project
5. 1 calendar days.
5.2 Party B shall enter the site for construction according to the time required by Party A. Party B guarantees to complete the project on schedule. In case of delay due to Party A's reasons, on the day of the incident, Party B's on-site project manager will apply, and the construction period will be postponed after being confirmed by Party A's on-site representative.
6. Inspection standard, method, place and time limit
After the construction of fire pool is completed, Party A and Party B shall organize acceptance according to relevant national standards. If it does not meet the specifications and design requirements, Party A shall notify Party B in writing to rework within three days after acceptance. If Party B fails to receive the notification of acceptance result from Party A within three days after acceptance, the project will be deemed as qualified.
7. Work of both parties
7. 1 Party A's work
7. 1. 1 Supervise and manage the construction process of Party B. ..
7. 1.2 Organize relevant personnel to accept the project.
7. 1.3 Pay the project payment according to the contract.
7. 1.4 Provide water and electricity (expenses shall be borne by Party B).
7.2 Work of Party B
7.2. 1 Party B shall carry out the construction in strict accordance with the drawings and design requirements provided by Party A and obey the supervision. Responsible for the project progress, technical quality, safe construction, inspection and acceptance, supervision data inspection, warranty and other matters.
7.2.2 In accordance with the requirements of construction safety specifications, do a good job in site safety management to ensure the safety of site personnel and property. In case of any safety accident, it shall be actively handled and immediately reported to Party A and relevant departments, and bear all responsibilities and losses caused thereby.
7.2.3 Do a good job of finished product protection before project delivery.
8. Liability for breach of contract
8. 1 If Party A fails to perform its obligations as agreed in the contract, causing economic losses to Party B, it shall compensate 5% of the total contract price as liquidated damages; If the construction period is delayed due to Party A's responsibility, the construction period will be postponed, and the expenses arising therefrom shall be borne by Party A. ..
8.2 If Party B fails to complete the project within the time limit stipulated in the contract or fails to pass the acceptance, it shall be liable for breach of contract and compensate Party A for 5% of the total contract price as liquidated damages. If the construction period is delayed due to Party B's reasons, the construction period will not be postponed and the corresponding economic losses will be borne.
9. Dispute settlement
In case of any dispute during the performance of this contract, both parties shall settle it through consultation in a timely manner on the principle of fairness and reasonableness. If negotiation fails, a lawsuit may be brought to the people's court at the place where the contract is performed.
12. Supplementary clauses
This contract shall come into effect as of the date of signature by both parties. The contract price shall be terminated after payment.
This contract is made in duplicate, with the same legal effect, and each party holds one copy.
For matters not covered in this contract, both parties may sign a supplementary agreement, which has the same legal effect as this contract.
Employer: (Seal) Contractor: (Seal)
Representative: (signature or seal) Representative: (signature or seal)
Year, month, sun, moon, sun.