Engineering construction contract 1
Party A: _ _ _ _ _ _ _
Party B: _ _ _ _ _ _
Based on the principle of "mutual benefit and common development", Party A and Party B have reached the following agreement on _ _ _ _ _ _ _ _.
I. Contents of cooperation
1. Party A shall formulate the terminal sales policy according to the overall business philosophy of the company, and Party B shall be responsible for the introduction and sales of "_ _ _ _ _ _ _ _ _ _" dedicated terminals.
2. Party B recovers the input cost by sharing the business with Party A. ..
Two. Rights and obligations of Party A
(I) Rights of Party A
1. According to the market development needs of _ _ _ _ _ _ _ _ _ _ _, Party A has the right to jointly select _ _ _ _ _ _ _ _ _ _ _ _ dedicated terminal model * * with Party B;
2. Party A shall formulate the sales policy of the ordering terminal;
3. Party A has the right to supervise Party B to improve the after-sales service system, including:
(1) Provide terminal backup machine;
(2) Set up at least one after-sales service station in _ _ _ _ _ _ _ _ _ _;
(3) It is required to formulate a detailed after-sales service process and deal with terminal after-sales problems in strict accordance with the relevant three-guarantee regulations of products;
(4) If it is confirmed by the after-sales service maintenance station that the mobile phone is out of order, and within the time limit for providing replacement service, Party B must provide replacement service for users.
4. Party A has the right to require Party B to improve its terminal sales system, including:
(1) Vehicle requirements: there must be at least _ _ _ _ _ self-owned trucks and at least _ _ _ _ _ delivery personnel;
(2) Terminal management: there should be a complete terminal purchase, sales and warehousing management system and management system, and corresponding post responsible personnel should be equipped;
(3) Financial management: it has a sound financial accounting system and management system, and is equipped with corresponding financial personnel;
(4) Business liaison personnel: equipped with relevant business liaison personnel for developing users, daily business negotiations, source contact, market sales monitoring, etc. ;
5. For the centralized procurement terminal ordered by Party B for a non-telecom company, Party A has the right to require the manufacturer to provide direct proof, otherwise it will not be scanned.
(II) Obligations of Party A
1. For Party B's scanning terminal, Party A has the obligation to formulate a terminal sales policy in line with market development in accordance with the general idea of socialized operation of cda mobile services;
2. For the mobile terminals ordered through negotiation between Party A and Party B, Party A has the obligation to apply to the system for inputting the terminal serial number;
3. According to the needs of market development, Party A has the obligation to instruct Party B to purchase terminal models;
4. In the process of Party B's improvement of after-sales service and terminal sales system, Party A has the obligation to provide some guidance to assist in the implementation;
5. If the telecom terminal companies in each union city fail to settle accounts for Party B within the time limit, Party A has the obligation to assist Party B to urge the telecom terminal companies in each union city to pay terminal subsidies;
Three. Rights and obligations of Party B
(I) Rights of Party B
1. According to the needs of market development, Party B has the right to report the model of purchasing terminal by itself;
2. During the terminal ordering process, Party B has the right to select the terminal model on the premise of meeting the shortlisting conditions;
3. After negotiation between Party A and Party B, Party B has the right to require Party A to input the terminal serial number into the system and formulate relevant sales policies for the purchased terminals;
4. Party A has not made specific provisions on penetrating the terminal sales channels through its own capabilities, and Party B has the right to choose the penetration target;
5. In the process of improving the after-sales service and terminal sales system, Party B has the right to put forward personalized construction plans on the premise of meeting the relevant requirements of telecom companies;
6. Party B has the right to ask Party A to assist Party B to ask the telecom terminal company in a certain city to pay the terminal subsidy until Party B receives the corresponding payment.
(II) Obligations of Party B
1. According to the market development, Party B has the obligation to make partial or full orders according to the terminal ordering demand put forward by Party A;
2. Party B has the obligation to improve its after-sales service and terminal sales system according to Party A's requirements;
3. During the macro-control of Tianyi terminal market by Party A according to the actual market development, Party B has the obligation to operate Tianyi terminal business according to Party A's requirements;
4. In the process of terminal procurement, delivery and sales, Party B has the obligation to conduct standardized operations according to Party A's requirements.
Fourth, tariff standards.
1, SMS fee: _ _ _ yuan (each);
2. Function fee: _ _ _ 1 month (there is no limit to the traffic fee in the autonomous region, and the traffic fee outside the region and the excess part are charged according to the standard tariff);
3. Monthly tariff package for Internet service: _ _ _ _ _ _ people per month, unlimited traffic in the area, _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
4. If other services are opened, they will be charged according to the current tariff standard.
Verb (abbreviation for verb) sharing method
1. Party B will recover the input cost through cooperation and sharing with Party A;
2. Divide functions, SMS and other expenses.
3. The share ratio is: 50% for Party A and 50% for Party B..
Settlement period of intransitive verbs
1. Party A shall make timely settlement in strict accordance with the time stipulated in the contract;
2. Provide the business bill of last month before _ _ _ _ every month, and both parties will make reconciliation;
3. After the bill is checked correctly, Party B will issue an invoice equal to the bill amount and send it to Party A on _ _ _ _ _ _;
4. According to the invoice issued by Party B, Party A shall remit the settlement amount of last month to Party B's settlement account before _ _ every month.
Seven. Party B's settlement
Account Company Name: _ _ _ _ _ _ _ _ _ _ Company Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Eight. responsibility for breach of contract
1. If Party A and Party B or one of them cannot perform or fully perform the relevant obligations under this Agreement due to force majeure, the liability for breach of contract may be partially or completely exempted as appropriate. However, in case of force majeure, one party or both parties shall notify the other party of the situation within _ _ _ days after the occurrence or elimination of force majeure, and provide supporting documents from relevant units. After the influence of force majeure is eliminated, one or both parties shall continue to perform the contract. If the impact of the force majeure event exceeds three months, both parties shall renegotiate the performance of the contract.
2. If the performance of the agreement is affected by force majeure, the performance period of the agreement shall be extended by the time equivalent to the time affected by force majeure;
3. The expenses caused by the time of force majeure shall be borne by both parties.
Nine. Settlement of Disputes Any dispute arising from the performance of this Agreement may be settled by both parties through consultation. If negotiation fails, Hohhot Arbitration Commission shall conduct arbitration according to the arbitration rules. The arbitral award is final and binding on both parties.
X. Term of Contract This agreement shall come into effect as of the date when the representatives of both parties sign and seal it, and the contract shall be valid for _ _ _ _. After the expiration of the contract, if both parties have no objection, the validity period will be automatically postponed; If either party has any objection, it shall notify the other party in writing one month before the expiration of this agreement, and the agreement will be automatically terminated or a new agreement will be signed through negotiation with the written objection as a sign.
Party A: _ _ _ _ _ _ _
Signature of legal representative (or authorized representative): _ _ _ _ _ _ _
Seal: _ _ _ _ _ _ _
Date of signature: _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _
Signature of legal representative (or authorized representative): _ _ _ _ _ _ _
Seal: _ _ _ _ _ _
Date of signature: _ _ _ _ _
Engineering construction contract 2
Employer (hereinafter referred to as Party A): Contractor (hereinafter referred to as Party B):
In order to ensure the necessity, in accordance with the provisions of the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, both parties reach an agreement on the organization and construction of this construction project, and hereby conclude this agreement.
I. Project name: _ _ _ _.
II. Project Location: _ _ _ _.
Third, the scope of construction and technical requirements:
See the construction drawings and bill of quantities for details.
Fourth, the project cost:
The budget price of this project is _ _ ten thousand yuan only (see the project budget book for details).
Verb (abbreviation of verb) signing method:
Contracting projects and materials.
Settlement method of intransitive verbs:
When the project is settled, a qualified intermediary agency is entrusted for settlement audit, and the downward floating rate is, and the engineering quantity is calculated according to the actual situation. According to the construction drawings and actual engineering quantity calculation, the information price, labor insurance fee, quota application and charging standard shall be implemented according to the project budget standard.
Seven. Payment terms:
After the project is completed and accepted, 90% of the total project cost will be paid after the final accounts are audited, and the remaining 10% will be used as the warranty payment, which will be paid within one month after the warranty period expires.
Eight, the project duration:
The total calendar days of the construction period is days, from year month day to year month day. If the construction period is delayed due to the rainy season and Party A's reasons, the construction period can be postponed accordingly after Party B's written application and Party A's confirmation ... If Party B fails to complete the project according to the agreed date, 300 yuan will be deducted for every five days of delay.
Nine, construction requirements:
1. Party B must carry out the construction in strict accordance with Party A's technical requirements and approved quantities, ensure the quality and quantity are completed on time, and the project quality standard must be above the standard.
2. Party B shall consciously raise the awareness of production safety and take on-site safety protection measures to ensure construction safety. All safety responsibilities and measures in the construction process shall be borne by Party B. ..
X. other matters:
1. Party B must have the corresponding construction qualification, and can sign the construction agreement only after being confirmed by Party A. ..
2. Party B must coordinate and solve the disputes and related matters in the construction of this project.
3. After the completion of this project, Party B shall submit a written application to Party A, which can only be accepted after being approved by Party A..
4. During the acceptance period, if Party B fails to carry out the construction according to the drawings, Party B shall make rectification within 15 days, otherwise Party A will not pay the project payment.
5. The quality warranty period of this project is one month, counting from the date of project completion acceptance. All warranty expenses arising from quality problems during the warranty period shall be borne by Party B. If Party B fails to enter the site for maintenance within 3 days after Party A's written notice, it shall be deemed as giving up the warranty money, and Party A will entrust others for maintenance.
XI。 One copy of this agreement shall be held by Party B and shall come into effect as of the date of signature and seal by both parties.
Attachment: Construction Drawings and Project Budget
Party A (seal): Party B (seal):
Legal representative (signature): Legal representative (signature):
Date of signing: Date of signing:
Engineering construction contract 3
Employer: _ _ Co., Ltd. (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
According to the Construction Law of People's Republic of China (PRC), the Economic Contract Law of the People's Republic of China and the specific conditions of this project, Party A and Party B sign this contract through consultation, and both parties shall abide by it.
1. Project name and address: Office of the Ombudsman of Shaanxi Ministry of Finance (Cai Zhong Building)
Second, the scope and content of the project: the roof is 4mmSBS waterproof, and the original protective layer is removed to make a new protective layer.
Third, the way of contracting: contracting for labor and materials
Four. Material: product name, specification and grade.
5. Project cost: RMB per square meter (including auxiliary materials and labor costs), which will be settled according to the actual area after completion. The construction area is square meters, and the total project cost is RMB Yuan only.
Duration of the intransitive verb item: _ _ _ _ _ _ _ _ _ _ _ _ _ _
Completion date (postponed due to rain)
Seven. Settlement method: The materials and personnel enter the site and are confirmed to meet the contract requirements by Party A. After the completion experience is qualified, the total project payment will be paid, and the rest will be paid in one lump sum one year later.
Eight. Responsibilities of Party A and Party B:
Party A shall provide Party B with written materials related to the design drawings of this waterproof project, and Party B shall carry out the construction according to the design standards and construction technology with the commencement notice issued by Party A. ..
2. Before the construction within the scope of this contract, Party A and Party B shall inspect and test the quality and site construction conditions of the previous procedure, and Party A shall be responsible for solving the situation that affects the waterproof construction of the previous procedure.
3. Party A shall create conditions for Party B's warehouse, and Party B shall respect Party A's jurisdiction and relevant rules and regulations, accept Party A's supervision and management, and ensure civilized and safe construction.
4. Party B shall provide Party A with relevant copies of the construction as required, and report the progress and quality of the project to Party A in time. Party A shall timely check and accept the progress and quality of Party B. ..
The warranty period of this project is three years. In case of leakage caused by Party B's construction or materials during the warranty period, Party B will immediately organize construction personnel to rush to the site for maintenance within the specified time after receiving the notice, and do their best to do a good job of service during the warranty period without any remuneration. Party B shall not be responsible for the damage to the waterproof layer caused by Party A's improper use or natural disasters.
Nine. Other agreements:
In case of special-shaped waterproof projects such as expansion joints and settlement during construction, the construction shall be carried out according to the national building waterproof standards, and the price shall be determined by both parties through consultation.
2. Party B shall complete the construction task as scheduled. During the construction period, due to the influence of climate and the limitation of on-site construction conditions, Party A and Party B shall coordinate in time, and the contract period shall be postponed accordingly. If Party A fails to pay according to the contract, thus affecting the construction period, Party A shall bear the responsibility.
3. During the construction period, Party B's personnel shall unconditionally obey Party A's safety management, but Party B shall improve the safety awareness of construction personnel by itself. If Party A's safety facilities are not suitable during the construction, and Party B does not raise any objection, the economic losses caused by the construction shall be borne by Party B. ..
4. During the construction period, Party A may conduct random inspection of materials, and the inspection fees of authoritative organizations shall be borne by Party A. ..
5. For matters not covered, Party A and Party B may negotiate at any time and sign a supplementary agreement as an annex to this contract.
6. This contract is made in duplicate, with each party holding one copy. This contract is valid for a long time from the date of signing.
Party A: Beijing Guojia Deyu Technology Construction Co., Ltd.
Party B:
Legal representative or client:
Address: _ _ _ Building
Address:
Tel: _ _
Engineering construction contract 4
Employer: _ _ _ _ _ _ _ University (hereinafter referred to as Party A).
Contractor: _ _ _ _ _ _ _ Construction Company (hereinafter referred to as Party B).
Party A entrusts Party B to build a five-story teaching building for teaching and office. In accordance with the Contract Law of People's Republic of China (PRC), the Regulations on Construction and Installation Engineering Contracts and relevant regulations, and in combination with the specific conditions of this project, this contract is signed by both parties through consultation for their compliance.
Article 1 General situation of the project
Project name: _ _ _ _ Building.
Project Location: RoadNo. _ _ _ _ _ _ _ _ _ _ _ _ _
Building area: _ _ _ _ square meters
Project cost: _ _ _ ten thousand yuan.
Article 2 Project design.
Drawing construction, its quality standards must meet the requirements of the Municipal Construction Committee on construction acceptance.
Article 3 The project duration is:
From _ _ _ _ _ _ _ _ to _ _ _ _ _ _ _ _.
Article 4 The project settlement and payment methods are as follows:
Within five days after the contract comes into effect, Party A shall pay Party B _ _ _ _ _ _ _ _ _ _ _ _ ten thousand yuan in advance according to 30% of the project cost, and then allocate funds according to the project progress. After the project is completed and accepted, Party A shall pay 99% of the total project payment to Party B within one month, that is, the maximum amount is _ _ _ _ _ _ _ _ _ five thousand yuan. The remaining 1%, that is, _ _ _ _ _ _ _ thousand yuan, is used as the quality guarantee fund for the one-year warranty period. After the warranty period expires, Party A shall pay Party B within ten days.
Article 5 Project acceptance:
After the completion of Party B's project, the municipal quality supervision department is responsible for the acceptance and delivery to Party A after it is qualified.
Article 6 Liability for breach of contract:
Party B shall be responsible for the losses caused by engineering quality problems; If Party B fails to complete the project on schedule, Party B will be fined 1% of the project cost for each day exceeding; If the construction period is delayed due to Party A's late payment of the balance, Party A will be fined 1% of the project cost; Party A shall be responsible for losses caused by continuous water and power cuts for more than eight hours.
Article 7 Other clauses:
Party A shall submit the construction drawings to Party B ten days before the project starts; Party A is responsible for the "three links" (road link, electricity link and water link) required for construction; Party B is responsible for the "three major materials" (steel, wood, cement) and other materials required for construction; In case of work-related injuries during construction, Party B shall be responsible, and Party A shall not be held responsible.
Article 8 This contract is made in duplicate, with each party holding one copy.
A copy, sent to the securities regulatory office. This contract shall come into effect as of the date when both parties affix their seals (_ _ _ _ _ _ _ _ _ _ _ _).
Employer: _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ University (official seal) _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ (signature and seal)
Address: Road number. _ _ _ _ _ _ _
Contractor: _ _ _ _ _ _ _ _ _ _ _
Construction Company (Official Seal) _ _ _ _ _ _ _
Legal Representative: (Signature) _ _ _ _
Signing time: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Engineering construction contract 5
Party A: _ _ _ _ _ _ Co., Ltd.
Party B: _ _ _ _ _ _ _ Company
Based on the principle of equality and mutual benefit, Party A and Party B reached the following supplementary agreement through friendly consultation on matters related to the project construction:
First, the project cost
1, the civil engineering cost is charged according to the second-class project, and the settlement cost of civil engineering of both parties is _ _ _ _% of the total price.
2. The installation cost shall be charged according to the three types of projects, and the total price shall be settled by Party A and Party B after falling by _ _ _%.
3. The calculation of material price is divided into two stages: the calculation of civil structures and embedded materials for installation (from the underground structure to the capping of the main body) and the calculation of materials for construction and water and electricity installation (from one month before the capping of the main body to _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _), and the calculation is confirmed by stages, that is, both parties confirm it every month.
4. If the difference between the information price and the market price of engineering materials and equipment is within the range of plus or minus _ _ _ _ _ _ ten thousand yuan (referring to the difference between the total value of single materials in this contract, the same below), and if the difference between the information price and the market price is outside the range of plus or minus _ _ _ _ _ _ _ _ ten thousand yuan, Party B shall submit a written report to Party A for confirmation according to the actual market wholesale price of engineering materials, and carry out project settlement according to the prices confirmed by both parties.
5. Party B agrees not to charge the following fees: measures to rob work, measures to ensure project quality, measures to disturb people, measures for insufficient space and general technical measures for construction safety (if included in the quota project, it will not be deducted separately, but will not be added); On-site civilized construction measures shall be negotiated separately by both parties.
6. For the project subcontracted by Party A, Party B's project department will charge the total subcontracting cooperation fee and management fee at _ _ _% of the total subcontracting project price (excluding the main equipment fee), and Party A will deduct it from the project funds of various professional projects and pay it to Party B's Huanqing Garden Project Department.
7. The calculation basis of the project cost is the relevant provisions of this agreement, the construction drawings and minutes of blue prints.the design review designed by Shenzhen Design and Research Institute of the Ministry of Machinery Industry, the design changes confirmed by Party A's engineering department, design institute and supervision company, and the economic visa on the construction site confirmed by Party A and supervision company.
8. Design changes and economic visas shall be measured and priced according to the principles agreed in the relevant provisions of this agreement. Unless Party A agrees, Party B shall not refuse the construction, nor shall it be priced separately according to the total price as required.
2. Party A shall provide engineering materials, equipment and Party A's subcontracted projects.
1. The materials supplied by Party A are: steel bars and commercial concrete.
2. The equipment provided by Party A includes elevators, generators, high and low voltage distribution cabinets and water pumps.
3. The professional projects subcontracted by Party A include: aluminum alloy door and window security engineering, fire door security engineering (including entrance door), secondary interior and exterior decoration and installation engineering of podium, elevator security engineering, fire fighting engineering, gas engineering, air conditioning engineering, high and low voltage power distribution engineering, cable TV, telephone engineering, monitoring intercom system engineering, automatic meter reading and electricity meter system engineering.
Third, the project payment
1._ _ _ _ years ago, the payment and settlement of the pile foundation project.
2. Settlement of pile foundation works constructed after _ _ _ years: After the pile foundation construction is completed and passed the quality inspection, Party B will prepare all the engineering materials and settlement book, and Party A will complete the audit within _ _ _ _ days after receiving the complete engineering materials. After Party B confirms the audit result of Party A, Party A will pay the final payment of the project in three equal installments within three months (that is, one third of the final payment each time).
3. Within _ _ _ _ _ days after the completion of the basement project, Party B shall submit the settlement data to Party A for review, and Party A shall complete the review within _ _ _ _ _ _ _ _ _.
4. For the superstructure project, Party A shall pay _ _ _% of the project payment for each completed _ _ _ _ floor according to the structure construction progress, and the masonry project shall be divided into three sections according to the difference of the total masonry quantity, and pay _ _ _% of the project payment for each time. The decoration of the main building and the installation of water and electricity are regarded as a construction stage of each single project on the _ _ _ _ _ floor, and _ _ _% of the project payment is paid after the completion of the image progress of each stage. After the completion of the construction progress in the above stages, Party B shall submit an image progress report to Party A.. Party A shall complete the audit according to the requirements stipulated in the contract within _ _ _ _ _ _ _ years.
5. Within _ _ _ _ _ days after the project completion acceptance, the project payment shall be paid to _ _% according to the tentative cost of the project contract, and the balance of the project settlement shall be paid in three installments (excluding _ _ _% warranty money) within _ _ _ _ days after the project settlement is passed. When the settlement time exceeds _ _ _ _ months, Party A shall pay _ _ _ _ _ _% of the total project price within _ _ _ _ _ days from the date of project completion and receipt of documents.
Four. All construction permits and other procedures for construction application, approval, inspection, quality supervision, quality inspection and safety inspection that need Party B's assistance in this contract project shall be completed and handed over to Party A within _ _ _ _ days after Party A provides relevant procedures.
Verb (abbreviation of verb) Matters not covered in this agreement shall be negotiated by both parties separately.
6. This agreement is an integral annex to the construction application contract. If the construction application contract is inconsistent with this supplementary agreement, this agreement shall prevail.
Seven. This Supplementary Agreement shall come into effect on the date when Party A and Party B sign and seal, the project department is formally established and Party B completes the construction permit on schedule.
Party A: _ _ _ _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ _ _ _ _ _
Five related articles on engineering construction contract template:
★ Five construction contracts
★ Engineering construction contract (5 references)
★ Five templates commonly used in construction contracts
★ Five construction agreements
★ Five copies of the construction contract template of the engineering department.
★ The latest version of the engineering construction contract template
Taken the latest template 202 1
★ Model construction contract of construction project (five copies)
★ Five common templates for 2022 construction contracts
★ 5 engineering contract samples.