Carpenter Cleaning Subcontract 1 Party A:
Party B: ID number:
According to the Contract Law of People's Republic of China (PRC), Party A contracts Party B to manufacture, install and dismantle the formwork through internal labor settlement through negotiation between Party A and Party B.. In order to strengthen project management, this contract is signed through consultation in accordance with the requirements of standardization, high speed, high quality and safety.
I. Project name:
Second, the project site selection:
3. Contracting methods: contract clearing, contract quota acquisition, contract quality, contract safety, contract progress (contract duration) and contract civilized construction.
Iv. contents of the project:
1, horizontal and vertical transportation of floor and floor formwork, supporting materials and fasteners; And the horizontal elevation (inside and outside) of formwork installation in structural layer (construction setting-out is available except axis). Multi-layer roof support strip.
2, according to the design drawings or template sample diagram processing template, before installing the wall, column, beam, site casting template is clean, protect the template when pouring concrete. According to the construction drawings and acceptance specifications for template installation. After the installation, the garbage in the formwork shall be cleaned and the concrete expansion caused by formwork erection shall be eliminated. Scratch and repair the main structure, etc. Template every two layers brush isolation agent.
3. The formwork shall be dismantled, cleaned, corrected, material specifications and models, transported to the designated place, stacked, and nails on the laminated board and wood square pulled out. Support and removal of concrete guide wall formwork, installation and removal of sporadic component formwork (including all small formwork and constructional column formwork, etc.). ), design disclosure, leaving holes according to the drawings, and plugging holes for installation (including sewer holes and flue holes, etc. ); Placement of embedded iron parts (including fabrication and installation of all prefabricated templates and reserved boxes; Manufacturing of reverse screw, etc. Manufacture and placement of stair tread protection template);
5。 Including tie rods, nails, iron wires, step-by-step tightening and other auxiliary materials.
6. The design institute and the construction unit change the project and increase or decrease the engineering quantity.
Five, the project quality:
Six, time limit for a project:
Seven. Artificial price and settlement method:
1, artificial price:
2. Settlement method: calculate the area according to 04 quota area calculation rules;
3. Payment method: the balance shall be settled within 90 days after the completion and acceptance of this project.
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of signing:
Carpenter Cleaning Subcontract 2 Party A (hereinafter referred to as Party A)
Party B (hereinafter referred to as Party B):
Through negotiation between Party A and Party B, Party A is willing to contract out the construction task of Xianghe Garden 13# building to Party B to complete the construction task. According to the provisions of relevant laws and regulations, Party A and Party B sign the labor service contract on the basis of equality, voluntariness and mutual benefit, and the contents are as follows.
I. Work content
1. Party B is responsible for all the main work contents of the carpentry formwork of this project, including all formwork fabrication in the design drawings and the change order of the engineering contact list, the dismantling of the tower crane foundation formwork, the erection and dismantling of the internal model steel pipe, the installation of water stop, formwork coating agent and adhesive tape.
2. All carpentry work in13 # building (special attention: formwork blasting, chipping of dislocated concrete surface, concrete cleaning and utilization of formwork blasting).
Second, gadgets
1, (including chainsaws, hand saws, electric drills, nails, iron wires, step-by-step tightening, tungsten lamps, cocks, hammers, drills, release agents, adhesive tapes, etc.). ).
1, three-level distribution (secondary distribution box to tool line)
2. The contract price is calculated according to the construction area.
3, including labor insurance benefits, labor supplies, raincoats, rain boots, heatstroke prevention drinks, antifreeze and heating.
4, including non-productive employment, meetings, study, quality and safety training, visiting relatives and other employment, temporary power and water cuts, intermittent short-term shutdown of workers, lost time and personal income tax.
5, including personnel organization and employment, job transfer between construction sites, secondary porters, and materials to be unloaded.
6. There is no extra-long material and secondary handling fee in this project.
7, must according to the project department weekly, monthly parts and total construction progress plan, to ensure that there is enough labor to complete the construction plan in time.
8. If Party A needs to hire workers, the wages of the workers shall be RMB per hour.
Third, the job requirements
1. According to the plan of the project department, it will be signed and approved by the monitor, and a fine will be imposed for each day of delay 1000 yuan/day.
2. After the ZuoYeDui comes into play, the team leader (the signatory of the contract) should always be on the scene, and the foreman 1 person should be on the scene for at least 28 days every month, and the penalty will be 100 yuan/day for each absent day.
3, demolition materials neatly stacked, nails removed, completes the civilized construction.
4. Do a good job in dormitory hygiene, prohibit gambling, theft, fighting and other illegal acts, prohibit bringing family members into the construction site, prohibit cooking without permission, and prohibit disorderly wiring. Party A shall pay a fine of 3,000 yuan/time for any fight, theft or fire of Party B's personnel in the construction site or dormitory area, whether right or wrong.
5. It is forbidden to urinate anywhere on the construction site.
6, the construction site each team requires uniform clothing, must wear a helmet.
7, according to the requirements of specification construction, strict quality control, put an end to quality accidents.
8, quality accident a penalty of 500-5000 yuan.
Fourth, fire management.
1, the fire control system must be implemented in the team, and every employee must be educated on fire control.
2. Strictly implement hot work declaration procedures. Fireworks are strictly prohibited in woodworking workshop to ensure fire safety.
3, strengthen the use of flammable and explosive materials management and work.
4, fire equipment shall not be used for other purposes.
Verb (abbreviation of verb) material management
1, the team must collect and use the materials well, and must not waste them at will.
2. The cost overrun of materials shall be borne by Party B. ..
3. Turnover materials such as boards and steel pipes are not allowed to be cut or damaged at will, and those who happen will be punished by one penalty and ten penalties according to the actual quantity.
4. Party B must do a good job in cleaning the construction site, otherwise Party A has the right to assign other personnel to manage and clean it. The cost of each job is the agreed unit price 1. Party B will be deducted by 5 times. ..
Terms of payment for intransitive verbs
1、 0。 00, 80% of the completed workload will be paid within one week after the completion of the seventh floor, 9 0% of the completed workload will be paid within one week after the structural acceptance, and the rest will be paid in one lump sum within one month after the intermediate acceptance of the structure. Party B must ensure that the wages of the workers in this shift are settled monthly.
7. Risk amount of prepayment guarantee.
The deposit for the project is 80,000 yuan (including 30% for quality, 30% for safety and 40% for civilized construction). If it does not meet the terms of the contract, it will be fined according to the relevant system.
Eight. Party B's responsibilities
1. Party B must appoint a shift safety officer to be responsible for the production, public security and security work of the safety team, do a good job of safety education before shift every day, and make records, and submit it to the project department for inspection before closing the account at the end of each month, otherwise the account will not be closed.
2. The team must sign a labor contract with the workers and submit one point to the project department, including a copy of the ID card.
2. During the construction period, the team leader must be in place every day, arrange the work of team members under special circumstances, and ask for leave from the construction personnel of the project department. The team leader must attend the weekly meeting of the project department. If he does not attend the weekly meeting without reason, he will be fined 500 times.
3, turnover materials obey the unified arrangement of the project department.
Nine. responsibility for breach of contract
1. During the construction period, Party B failed to complete the quality, safety, schedule, cost and other contents as agreed, or failed to complete the plan issued by Party A due to its own reasons, or the quality of the project was poor, resulting in frequent safety accidents and chaotic team management. Party A has the right to order to leave the site and settle .70% of the actual engineering quantity, and the losses shall be borne by Party B. If Party B fails to carry out the construction as agreed, Party A has the right to set up another team to enter the site, and the work unit price is 1 as agreed. 5 times, and deducted from Party B's project payment accordingly.
2. Party B's construction personnel do not obey the unified command of the project department and violate the rules. Depending on the seriousness of the case, they will be fined 50-500 yuan. If the circumstances are serious, be expelled from the court.
Ten, labor protection, accident liability handling costs
1. It is not allowed to force workers to do jobs without security. If found, the relevant responsible person shall be investigated and dismissed.
2. The general responsibility for accident handling and the expenses for handling minor injuries shall be borne by the team in the hospital, and the responsibility shall be defined and the responsible person shall be investigated.
XI。 Supplementary content
Matters not covered shall be settled through consultation. This agreement and the letter of commitment have legal responsibilities at the same time.
This contract is made in triplicate, two for Party A, one for Party B and one for Project Department. After being signed by both parties, it will take effect on the day after the risk premium is paid, and the settlement price will automatically become invalid.
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _
Signing place: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of signing:
Carpenter Cleaning Subcontract 3: (hereinafter referred to as Party A)
Labor Contractor: (hereinafter referred to as Party B)
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, this contract is concluded on matters related to the woodworking labor contracting of the workshop in Building No.8 and the expert buildings No.2 and No.3 of Sichuan Kexin Lighting Co., Ltd. through consultation.
1, the object of the labor contract and the content of providing labor services
Project Name: No.8 Building of xxx Co., Ltd. and No.2 and No.3 Workshop of Expert Building Project Location: Ziyang Chengnan Industrial Park Project Contracting Scope: Woodworking Sub-project.
2. Term of the contract
From the date of signature and seal by both parties, the term of the contract is years and the total calendar working days are days.
3, quality standards
According to the current national code for construction and acceptance of building and installation engineering and the quality evaluation standard of building and installation engineering, ① the axis position deviation of cast-in-place foundation shall not exceed15 mm; ; Axis position deviation of walls, columns and beams shall not exceed 8 mm; Shear wall axis position deviation is less than 5 mm. (2) The vertical deviation between layers of cast-in-place structure shall not exceed 8 mm; The vertical deviation of overall height shall not exceed 30mm；; Height elevation deviation shall not exceed10mm; ; The total height elevation deviation shall not exceed 30mm. (3) The deviation of section size of cast-in-place structure shall not exceed-5 mm+8 mm; The surface flatness (length 2m) deviation of cast-in-place structure shall not exceed 8mm；; (4) The deviation of the center position of embedded facilities is not more than 65438+/-00 mm; ; The deviation of the center position of the reserved hole shall not exceed 65438±05mm.
4. Party A's obligations
4. 1 Party A shall deliver to Party B the construction site with the conditions for the commencement of the labor service operation of this contract project, and meet the energy supply required for completing the labor service operation of this contract.
4.2 Party A shall provide Party B with corresponding leveling points and pile location distribution, and provide some temporary facilities such as water and electricity for production and living.
4.3 Responsible for engineering survey and positioning, settlement observation, technical disclosure, organization of the blue prints.the design, and unified arrangement of technical files.
4.4 Coordinate and solve the temporary facilities for production and living, water and electricity for work and the construction site that Party B does not use independently.
4.5 Pay labor remuneration to Party B as agreed in this Contract;
4.6 Responsible for contacting the owner, supervision, design and relevant departments, and coordinating the working relationship on site.
4.7 If the project is shut down due to Party A's reasons, Party A shall take full responsibility for the losses caused thereby.
5. Party B's obligations
5. 1 Be responsible to Party A for the engineering quality within the scope of the labor service contract, and organize skilled workers with corresponding qualification certificates to take up their posts; Without the authorization or permission of Party A, it is not allowed to establish working contact with the owner and relevant engineering departments without authorization; Consciously abide by national laws and regulations and relevant rules and regulations;
5.2 Party B shall, according to the requirements of the general schedule of construction organization design, submit the construction plan for the next month and the quantities completed this month five days before the end of each month, and submit the ten-day and weekly construction plans required by Party A, as well as the labor arrangement plans corresponding to the completion of the construction plans in the above stages and periods, which shall be strictly implemented after being approved by Party A;
5.3 Carefully organize the construction in strict accordance with the design drawings, construction acceptance specifications, relevant technical requirements and construction organization design to ensure that the project quality reaches the agreed standards; Scientifically arrange the operation plan and invest enough manpower and material resources to ensure the construction period; Strengthen safety education, conscientiously implement safety technical specifications, strictly abide by the safety system, and implement safety measures to ensure construction safety; Strengthen site management, strictly implement the management regulations of the competent construction department and relevant departments of environmental protection, fire protection and health on the construction site, and achieve civilized construction; Bear the losses caused by its own responsibility, such as quality modification, rework, delay in construction period, messy site and various fines;
5.4 Consciously accept the management, supervision and inspection of Party A and relevant departments; Accept Party A's inspection of the storage and use of its equipment and materials and the valid certificates and certificates of its operators at any time; Coordinate with other units on site and take the overall situation into consideration;
5.5 Stack materials, machines and tools according to Party A's unified planning, set up signs according to Party A's standardized site requirements, manage the living quarters well, and do a good job in public security in their own responsibility areas;
5.6 Do a good job in protecting the finished products of buildings, structures, underground pipelines and completed projects around the construction site. If the damage is caused by Party B's responsibility, Party B shall bear all economic losses and various fines caused thereby;
5.7 Keep and reasonably use the machines, tools, turnover materials and other facilities provided or leased by Party A to Party B; (The material compensation standard depends on the actual situation)
5.8 Party B shall obey the instructions of the owner and engineer conveyed by Party A and relevant units.
5.9 Unless otherwise agreed in this contract, Party B shall be responsible for the implementation and completion of its operations, and Party B shall undertake and perform all obligations and work procedures related to labor operations agreed in the general (subcontracting) contract.
5. 10 During the construction of this project, if the quality of the project is reworked or repaired due to Party B's reasons, Party B shall take full responsibility for the losses such as material cost and time delay.
5. 1 1 Party B must clean up the site after work. If it is not completed within the time limit of Party A, Party A shall designate personnel to clean it up, and Party B shall be responsible for the economic and construction period losses caused thereby.
5. 12 Party B must complete the contract within a limited time limit, which is not affected by the busy farming season. Over the agreed time, according to the daily 500 yuan fine.
6, safety construction and inspection
6. 1 party b shall abide by the management regulations on production safety in engineering construction, carry out the construction in strict accordance with the safety standard JGJ59-99, and accept the supervision and inspection of industry safety inspectors at any time, and take necessary safety protection measures to eliminate potential accidents. Personal injury caused in the construction of the project is less than 20xx yuan, which shall be borne by Party B, and the above shall be borne by Party A. ..
6.2 Party A shall conduct safety education for its employees on the construction site and be responsible for their safety. Party A shall not require Party B to carry out construction in violation of safety management regulations. In case of safety accidents caused by Party A, Party A shall bear corresponding responsibilities and expenses.
7. Safety protection
7. 1 All safety protection articles (such as safety helmet, safety belt and other protective articles) used by Party B at the construction site shall be borne by Party B. ..
7.2 If safety protection measures need to be taken in the construction site, they shall be implemented after being approved by Party A, and the cost of protection measures shall be borne by Party A.. ..
8, accident treatment
8. 1 In case of serious casualties and other safety accidents, Party B shall immediately report to relevant departments and Party A in accordance with relevant regulations, and handle them according to relevant national laws and administrative regulations.
8.2 In case of any dispute between Party B and Party A on the responsibility for the accident, it shall be handled according to relevant regulations.
9. Insurance
9. 1 The materials and equipment to be installed that are transported to the construction site for labor construction shall be handled or insured by Party A, and Party B does not need to pay the insurance premium; Party B shall be responsible for its own materials.
9.2 When an insurance accident occurs, Party B and Party A have the responsibility to take necessary measures to prevent or reduce losses.
10, labor remuneration (excluding tax)
Template installation: according to the template development area of 29 yuan/m2; Unless otherwise agreed in the supplementary contract under special circumstances.
1 1, quantity confirmed.
The construction area is calculated according to the construction drawing and the completion drawing; Calculation of sporadic quantity.
12, payment of labor remuneration
After the first floor of this project is completed, Party A shall pay Party B 60% of the completed project quantity, 95% of the total project quantity after capping, and the remaining 5% shall be paid within one month after the project completion acceptance settlement.
13. Payment method: cash payment.
14, liability for breach of contract
14. 1 In any of the following circumstances, Party A shall be liable for breach of contract:
(1) Party A violates Articles 1 1 and 13 of the Contract and fails to pay Party B the labor remuneration on time.
(2) Other circumstances in which Party A fails to perform or fails to perform its contractual obligations as agreed.
(3) Party A fails to verify the workload completed by Party B as agreed, or fails to pay labor remuneration or labor remuneration as agreed.
14.2 In case of any of the following circumstances, Party B shall be liable for breach of contract:
(1) If the construction quality of Party B does not meet the quality standards agreed in Party A's contract, Party B shall pay Party A a penalty of 5,000 yuan.
(2) When Party B fails to perform or fails to perform other obligations under this contract, it shall pay a penalty of 5,000 yuan to Party A and compensate Party A for the economic losses caused by its breach of contract, and the delayed working hours of Party B shall not be postponed.
(3) If Party B's construction quality and safe and civilized construction fail to meet the minimum standards stipulated by the state, Party B shall pay a penalty of 5,000 yuan to Party A and compensate Party A for the economic losses caused by its breach of contract, and the working hours delayed by Party B shall not be postponed.
15, controversial
In case of any dispute between Party A and Party B during the performance of this contract, they may settle it by themselves or ask the relevant competent department for mediation. If mediation fails, a lawsuit may be brought to the people's court where the project is located.
16, the contract is terminated
If Party B stops work for no reason, wrangling or other factors lead to the delay of the construction period, Party A has the right to notify Party B to leave unconditionally, and Party A will not pay any money and expenses or settle accounts, and demand Party B to compensate all economic losses caused by the stoppage. This contract will automatically terminate and become invalid, and Party A will not refund the performance bond to Party B..
17, the contract is terminated
After both parties have fulfilled all their obligations under this contract, Party B shall deliver the labor operation results to Party A, and this contract shall be terminated after Party A's acceptance and payment of labor remuneration.
18, number of contract copies
This contract is made in duplicate, with the same legal effect, and each party holds one copy.
19, the contract comes into effect.
Contract signing time: Contract signing place:
This contract shall come into effect after being signed and sealed by both parties.
Party A:
Party B:
date month year
Carpenter Cleaning Subcontract 4 Entrusting Party (Party A):
Organizer (Party B):
After friendly negotiation between Party A and Party B, Party A decided to entrust the carpentry part of the room decoration to Party B.. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.
Article 1: Project Overview
1, project address:
2. Living room specifications: The room has two rooms and two halls, with a total construction area of 78 square meters.
3. Construction content: interior decoration woodworking part, including (two wardrobes, two desks with bookshelves and chairs, shoe cabinet screen, wine cabinet, bar, porch door cover, kitchen door cover, living room balcony door cover, washing machine cabinet, kitchen hanging cabinet, living room, dining room and aisle ceiling).
4. Entrusting method: The contract work does not include materials.
5. Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2: Project Price
Project Price (amount in words)
Article 3: Quality Requirements
1. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.
2. After the construction materials are inspected by Party B, Party B shall be responsible for the construction quality, and shall not change the construction personnel at will.
3. Party B shall fully consider the overall use of the project during the construction process. If other decoration parts need to be modified or redone, Party B shall rework them in time without compensation, and the cost of reworked materials shall be shared equally by both parties.
4. If the construction affects the use or is obviously unsightly, Party B shall rework it in time and bear the cost of reworked materials, and the construction period will remain unchanged.
5. If the construction does not affect the use, but it is slightly unsightly, Party B shall be responsible for the remedy or compensation, and the construction period will remain unchanged.
Article 4: Supply of Materials
1. If the decoration materials provided by Party A do not meet the quality requirements or have different specifications, Party B shall not use them and notify Party A to replace them in time. If it has been used, all losses caused to the project shall be borne by Party B. ..
2. The materials that Party A is responsible for purchasing and supplying shall be supplied to the site on time. Delayed arrival will postpone the construction period. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.
Article 5: Method of Payment
1. When the construction period is over half (_ _ _ _ _ _ _), Party A shall pay the first project payment. After the woodworking project is completed, Party A will pay the second project payment. The rest will be settled after Party A completes all interior decoration works. ..
2. Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction.
Article 6: Construction Period
1. If the completion is delayed due to Party B's reasons, Party A will pay a fine of 100 yuan per day as liquidated damages until the work expenses are deducted.
2, in the construction, due to engineering quality problems, the two sides disagree and cause work stoppage, which should be punished as delayed work or delayed construction period. Both parties should actively coordinate and deal with the dispute as soon as possible, so as to continue the construction.
Article 7: Other matters
1. Party A's responsibilities: Party A provides the floor plan of the house, supplies materials on time, and makes on-site disclosure to Party B. ..
2. Party B's responsibility: be responsible for the safety, fire prevention, work with certificates and civilized construction on the construction site, and prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.
Article 8: Modification and Termination of the Contract
1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing and go through the termination procedures.
2. The party that terminates the contract without authorization shall pay 5% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.
Article 9: Entry into force of the contract
1. This contract shall come into effect after being sealed or signed by both parties.
2. This contract is made in duplicate, with each party holding one copy.
Party A:
Signature:
Date of signing:
Party B:
Signature:
Date of signing:
Woodworking Cleaning Subcontract 5 Project Contractor: (hereinafter referred to as Party A)
Labor Subcontractor: (hereinafter referred to as Party B)
In accordance with the National Law of People's Republic of China (PRC), Construction Law of People's Republic of China (PRC), Regulations on Safety Production Management of Construction Projects, Regulations on Quality Management of Construction Projects in Guizhou Province and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credit, both parties have reached an agreement on the subcontracting of woodworking services, and both parties shall abide by this contract.
1, project overview
2. Project Name: Longli County Low-rent Housing Phase IV
3. Project Location: Huannan Road, Longli County
4. Engineering structure forms: frame structure and brick-concrete structure.
First, the contract method and unit price
1. Valuation is based on the construction area: every square meter of the frame needs assistance in joint sticking, formwork removal, site cleaning, nails and wires.
1. 1 Installation and removal of foundation plate:
2. The unit price has included all the expenses of carpentry work required by the labor subcontractor for implementing and completing the project construction drawing agreed in this contract.
3. Payment of price: 80% of the workload is completed from the completion of the second floor of the main structure, 80% of the monthly progress thereafter, and the balance is paid within 40 days of completion acceptance.
Second, the scope of contracting: labor organizations, professional woodworkers.
Third, schedule management.
1, the team must ensure that there are enough high-quality skilled workers to enter the site for construction, and on the premise of ensuring quality and safety in production, ensure that the weekly and monthly plans and overall progress tasks specified by Party A are completed as scheduled.
2. If the team does not obey the management due to insufficient labor force or low quality of employees, which affects the construction of other processes or delays the construction period for many times, the project department will have the right to take measures to organize human assault until the team is ordered to leave within a time limit, and the expenses incurred will be deducted twice from the settlement and ordered to leave.
3. The team must implement the construction progress arranged by the project department, and refuse to implement it for various reasons, and will be fined RMB.
Fourth, quality management.
1, this project is a high-quality project, and the quality acceptance shall be subject to the acceptance results of the project department and the construction unit, and shall be included in the settlement basis.
2, quality standards, partial project must be approved by Party A and supervision at a time.
3, in strict accordance with the figure construction and acceptance specifications, if unauthorized decision-making, resulting in quality rework accidents, will be held accountable and bear all the expenses arising therefrom.
4, project acceptance, not close cooperation, one-time acceptance is unqualified, not timely rectification, will be punished according to the management regulations of the project department.
Verb (abbreviation of verb) safety production management
1, fill in the roster and a copy of ID card according to the form specified by the company, and report to the project department for the record. If the number of personnel increases or decreases, the adjustment shall be reported in time. If the accident happens to someone other than the on-the-job staff, the consequences will be borne by the team.
2. The team strictly abides by the laws and regulations of the state and local governments. If there are illegal employees in the labor organization, once they are found out, the team will hold them accountable. It is forbidden to enter the construction site without a helmet, go to work shirtless, wear slippers to work and other uncivilized behaviors. Once found, 50 yuan/person will be fined every time, which will be deducted from the project payment of each team.
3. According to the accident analysis, depending on improper construction or command error, Party B shall be responsible for illegal operation.
6. The above agreement shall come into effect after being signed and sealed by both parties and shall be protected by law.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _