Contractor (hereinafter referred to as Party B): xxxxxx
In accordance with the relevant provisions of the Contract Law of People's Republic of China (PRC) and the Construction Law of People's Republic of China (PRC), and in combination with the specific conditions of this project, the two parties reached the following agreement through consultation on the principle of friendship, honesty and voluntariness:
Article 1 General situation of the project
1. Project name:
2. Project location:
Article 2 Scope of Contract
Renovation and installation of fire hydrant system, alarm system and automatic sprinkler system. If the extra workload increases or decreases, both parties shall settle it through consultation.
Article 3 Method of project contracting
The contractor, the contractor, the contractor, the contractor and the contractor have passed the fire control acceptance, provided that Party A provides the corresponding project application and acceptance materials.
Article 4 Term of Contract
Start date:
Date of completion:
Article 5 Project cost, payment method and price adjustment
The project contracting fee is RMB _ _ _ _ _ _ _ (in figures) (in words).
Payment method: After signing the contract, when Party B enters the site, Party A shall pay 40% of the total price as the entry fee for the preliminary fire control construction audit and construction; Party A shall pay 80% of the total price as the cost of later construction and materials, pay 98% of the total price after obtaining the fire acceptance letter, and reserve 2% of the total price as the quality guarantee, with a warranty period of one year. After the warranty period expires, Party A shall return the warranty money.
Article 6 Engineering Quality and Acceptance Criteria
1. This project has been accepted by Party A, Party B and the government fire department according to the construction drawing, design description, design changes and relevant national (industry) standards and specifications.
2. All kinds of raw materials and equipment that Party B enters the site must meet the acceptance criteria, and unqualified materials and equipment shall not be used and installed in the site.
3. The project quality must conform to the Unified Standard for Acceptance of Construction Quality of Building Engineering (GB50300-20xx). Code for construction and acceptance of automatic fire alarm system (GB 50 166- 19xx) and Code for construction and acceptance of automatic sprinkler system (version 20xx) (GB 5026 1-65438). 5023 1- 19xx。 Code for acceptance of construction quality of building electrical engineering (GB50303-20xx. ). Technical Standard for Installation and Construction of Indoor Fire Hydrant Water Supply and Fire Extinguishing System (J5 12-20xx) and other relevant national and industrial standards and specifications.
Article 7 Safe construction
1. Party B must comply with the current national and local relevant specifications and requirements, and at the same time, Party A must implement the safety and civilized management measures for construction projects. ..
2. In the process of construction, Party B shall bear all responsibilities and losses for quality accidents, safety accidents or fire accidents caused by Party B's violation of relevant safety operation regulations or fire regulations.
Article 8 Rights and obligations of both parties
1. Party A is responsible for providing Party B with the construction site and conditions to coordinate construction water and electricity consumption.
2. Party B must provide Party A with relevant documents and materials such as construction organization design and quality assurance service measures, and shall not conceal them for any reason.
3. Party B shall be responsible for the design, construction, installation and pressure test of the fire protection project, and submit it to Party A for acceptance.
4. Party B must carry out the construction and installation according to the written confirmation of Party A or the construction drawings provided by Party A and the installation scheme and method confirmed by Party A, and shall not change it without authorization. If there is any change, the written notice of change shall prevail.
5. The changes proposed by Party B must be confirmed by Party A in writing before the construction can be organized, otherwise the consequences will be at your own risk and the economic losses caused to Party A will be compensated. ..
6. Party B must carry out the construction according to the fire protection design, construction and acceptance specifications and industry standards, and report to Party A in time if any violation or defect is found.
7. Party B shall carry out process inspection and final inspection on concealed works such as fire-fighting electrical lines and fire-fighting water supply pipes in combination with main working procedures such as construction, installation, commissioning and acceptance, and make quality records in stages. Party B shall be responsible for the whole fire control system before the installation and construction of the fire control project is completed but fails to pass the fire control acceptance. After the acceptance of fire protection, Party B must actively provide Party A with installation and commissioning records, opening reports, concealed works records, fire protection engineering manuals and other documents, conscientiously perform the handover procedures, and take the initiative to do a good job in the later maintenance of the project.
Article 9 Design changes
1. The design drawings, descriptions and relevant technical data approved by Party A are effective basis for construction, and neither Party A nor Party B may change them without authorization.
2. Major changes in construction drawings must be approved by Party A. Design change orders can only be implemented after Party A's visa is valid. The number of copies of the change order and modified drawings is the same as that of the construction drawing, which serves as a supplementary document to the contract.
3. When the revised drawings are changed due to design errors, the contract costs will be adjusted after both parties determine the increase or decrease of costs.
4. On the premise of ensuring the engineering quality and not lowering the design standard, Party B puts forward reasonable suggestions to modify the design, which will be implemented on the premise of meeting the requirements of fire protection design and construction specifications.
5. If it is really necessary to make changes during the construction, it shall be agreed by Party A, and Party A shall make changes in written form. Therefore, the increased expenses have actually been recorded in the final accounts.
6. In the process of construction, when one of the following circumstances occurs, Party B must immediately notify Party A in writing and ask for confirmation:
(1) When the design drawings and description documents are inconsistent with the conditions of the project site;
(2) The design drawings and documents are unclear or have errors and omissions, and the drawings are inconsistent with the description;
(3) Unexpected special difficulties occurred in the construction conditions not specified in the design drawings and description documents.
Article 10 Liability for breach of contract and claim
1. If Party A fails to make payment as agreed in this Contract without justifiable reasons and fails to make payment within ten days after receiving Party B's written dunning notice, Party A shall pay Party B a penalty of 2‰ of the payable amount from the date when the dunning expires.
2. Before the project fails to pass the acceptance, if Party A uses it without authorization and causes damage, Party A shall bear the corresponding responsibilities in addition to the quality reasons of the project itself.
3. If the project is not completed within the time agreed in the contract, Party B shall pay Party A a penalty of two thousandths of the total project cost for each day of delay.
4. Due to the quality of materials and equipment provided by Party B and the construction quality of Party B, Party B shall bear all losses caused by quality accidents, safety accidents or fire accidents during the use of this project.
5. Party B shall deliver the completion materials and other materials related to the project to Party A within seven days after the completion of the project, otherwise, Party B shall pay Party A a penalty of two thousandths of the total project cost for each day overdue.
Article 11 Good faith agreement
Party A's responsibilities:
1. Party A has the responsibility to introduce to Party B the regulations of this unit on clean and cooperative management.
2. Party A has the responsibility to educate the personnel of this unit on the provisions on clean and cooperative management.
3. Party A's personnel shall strictly abide by the regulations of the unit on clean and cooperative management, and shall not accept entertainment banquets from Party B, or accept any kind, cash or gift certificates.
4. When Party A discovers any form of bribery of Party A's personnel during the project construction, it shall take timely measures to stop it and notify Party B's unit leaders in time.
5. If Party A's personnel violate the management regulations on honest cooperation, Party A will give administrative and economic penalties according to the seriousness and influence.
6. Party A shall promptly investigate the behavior of Party B's personnel in violation of the provisions on sincere cooperation, and deal with it seriously according to the investigation.
Party B's responsibilities:
Party B shall ensure that the relevant personnel of Party B understand and abide by the relevant regulations on the cooperation and management of clean government in Party A's unit.
Representative of Party A (signature):
Person in charge of Party B (signature):
Fire Engineering Cooperation Agreement 2 Employer (Party A):
Contractor (Party B):
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Fire Protection Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credit, both parties reach an agreement on the construction of this construction project and conclude this contract.
I. Overview of the Project
1, project name:
2. Project location:
3. Project content: automatic fire alarm system, automatic sprinkler system, fire pump room,
Fire truck, fire hydrant, smoke control, fire shutter and other systems.
Second, the scope of contracting.
1. Contracting method: contracting engineering and materials, packaging inspection and data.
Third, the safe construction
Party B shall carry out the construction in strict accordance with the safety construction specifications, and all safety accidents caused by Party B during the construction shall be borne by Party B. ..
Fourth, the completion acceptance
Party A is responsible for the inspection procedure of the whole project, and Party B shall cooperate with Party A to submit complete completion data and fire inspection report issued by the fire inspection company.
Verb (abbreviation for verb) Contract amount
1. Based on the principle of good faith and friendly cooperation, Party A and Party B * * * negotiate on the following matters.
For matters related to fire fighting engineering, the total project amount is RMB.
2. Party A is responsible for coordinating the cooperation between Party B and various construction units.
Other agreements of intransitive verbs
1. Party B shall carry out the construction in strict accordance with the requirements of construction drawings and specifications, and obey the unified, coordinated and supervised management of Party A..
2. Party B shall cooperate with Party A to sort out the project completion data in time.
Seven, cooperation management fees include the following cooperation fees:
Provide vertical transportation, scaffolding, water and electricity construction debugging, and repair holes after equipment installation.
Eight, Party B must be equipped with qualified librarians, responsible for the collection and collation of information on the construction site, and must ensure that the information is true, complete and synchronized.
If Party A falsifies the sampling data and the project is not synchronized, Party B will be financially punished, and the data of the whole project will be filed by a special person. The minutes of the blue prints.the design of construction, design changes, technical approval forms and on-site visa units shall be made in quadruplicate, two for Party A, one for the supervisor and one for the contractor. For the project subcontracted by Party A, the subcontractor shall sort out the information and provide it to Party B. Within 20 days after the project is completed and accepted, Party B shall be responsible for handing over a complete set of engineering technical information to Party A. Otherwise, Party A will punish Party B. ..
Nine. terms of payment
1. The pricing method of this project adopts list quotation, based on the drawings and quantities provided by Party A to Party B, and audited by relevant departments. The pricing standard shall be settled with reference to the 2008 edition of Comprehensive Pricing Specification for Construction Engineering Quantity in Henan Province and Nanyang Engineering Cost Information in the current quarter, and the total project price shall be settled with the actual engineering quantity.
2. This project does not include the second handling fee of materials, the increase fee for long-distance construction, the increase fee for shortening the construction period, and the construction measures fee in winter and rainy season. The general contracting management fee and cooperation fee shall be coordinated by Party A and borne by subcontractors. If the coordination fails, Party A shall bear it. In case of any change in national, provincial and municipal laws, regulations, norms and policies during the performance of this contract, the new laws, regulations and regulations shall prevail.
3. The labor cost of fire building installation is increased by 65,438+00% per working day in 69 yuan and included in the final accounts.
4. This contract is fully underwritten by Party B with a 3% discount. After the project construction is completed, Party A will pay 0.80% of the total project cost to Party B after Party B submits the complete completion data and the fire detection report issued by the fire detection company. Party A shall pay 17% of the total project cost to Party B after passing the fire control acceptance, and the remaining 3% shall be used as the project quality deposit, which will be 10 years after the warranty period expires.
X. 1. The quality and brand of raw materials shall be recognized by Party A, and Party B shall be responsible for purchasing.
2. The materials purchased by Party B must meet the requirements of drawings and standards, and all kinds of certificates and quality inspection reports are complete, which can only be used after being accepted by Party A and the supervision engineer. The necessary sampling expenses shall be provided by Party B and the material supplier. Whether or not Party A conducts random inspection, Party B and the material supplier shall bear the civil liabilities arising from the material quality problems.
3. Materials that have not been accepted by Party A and the supervision engineer must be shipped out of the construction site within three days from the date of receiving the notice from Party A or the supervision engineer. Party A and the supervision engineer have the right to deal with the overdue period, and the losses caused thereby and the cleaning expenses of Party A shall be borne by Party B. ..
XI。 Engineering warranty: warranty period 1 year.
12. In the process of construction, if the work is stopped for more than 3 days due to Party A's reasons, the workers shall be paid wages and certain economic losses.
Thirteen. Party B appoints Comrade _ as the on-site representative to perform this contract.
14. This contract is made in quadruplicate, with Party A and Party B holding two copies respectively, and shall come into effect as of the date of signature and seal by both parties.
15. Matters not covered in this contract shall be discussed separately by both parties. The supplementary agreement, after being signed and sealed by both parties, has the same legal effect as this contract.
Employer: Contractor:
Representative: representative:
Fire Engineering Cooperation Agreement 3 Party A (the Employer):
Party B (contractor):
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Regulations on Contract of Construction and Installation Projects, the Regulations on Fire Punishment in Guizhou Province and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility, this contract is concluded through friendly negotiation.
I. Overview of the Project
Project name:
Project location:
Project content: Equipment procurement and installation of automatic fire alarm system, automatic sprinkler system, indoor fire hydrant system and smoke control system.
Second, the scope of project contracting
Scope of contract: According to the contents shown in the automatic fire alarm design construction drawing, spray design construction drawing and HVAC design drawing provided by Party A:
1. Equipment procurement and installation of all indoor automatic fire alarm systems;
2, all indoor automatic sprinkler system equipment procurement and installation (including spray pump control box);
3, all indoor fire hydrant system equipment procurement and installation (including fire pump control box);
4, all indoor smoke control system equipment procurement and installation (including fan control box);
5. Party A shall be responsible for the installation of power inlet lines of fire pumps, spray pumps and fans, and Party B shall be responsible for the power piping, wiring and debugging from fan control box to fan and from water pump control box to water pump.
6. Equipment procurement and installation of the water inlet of underground fire pool.
7, emergency lighting system, fire doors, gas fire extinguishing system equipment procurement and installation.
Contracting method: this project adopts the general contracting method of materials (materials must be approved by Party A); The construction content outside the scope of this contract shall be calculated separately by visa.
Third, the term of the contract.
Start date: year month day.
Completion date: year month day.
Total days of contract term: days.
Fourth, quality standards.
Engineering quality standard: qualified according to the design and national standard "Code for Fire Protection Design of Buildings".
Verb (abbreviation of verb) settlement method
The project price is settled by pre-settlement.
Payment of the contract price of intransitive verbs
1. After the contract price is stipulated in the agreement, neither party may change it without authorization. Both parties have agreed on the scope of risks included in the contract price and the calculation method of risk expenses. Within the agreed scope of risks, the contract price will not be adjusted. The contract price adjustment method beyond the risk scope shall be agreed separately and strictly implemented according to the payment method of Party A in this contract.
2. Payment method: After Party B enters the site for construction, Party A shall report the project progress of the current month on 25th of each month, and Party A shall pay 80% of the progress payment to Party B before 10 of the following month. After the project is completed, the progress payment paid by Party A to Party B shall reach 90% of the total project contract amount. After the fire protection certificate of this project is obtained and handed over to Party A, 97% of the total contract price of the project shall be paid within one week, and 3% of the project payment shall be reserved as the quality guarantee. The warranty period is one year. If there is no quality problem after the expiration, Party A will pay the balance within one week. If the payment is not made within the time limit, it shall be treated as breach of contract.
Seven. Responsibility of both parties
1. Party A's responsibilities:
① Party A shall make clear to Party B the contents, details and engineering requirements of this project.
(2) Party A must provide detailed fire protection design drawings to Party B, and Party B shall carry out the construction according to the drawings after confirming the correctness.
(3) Coordinate the relationship between the construction teams and the stacking place of the equipment used in the installation project.
(4) Provide necessary water, electricity and lighting.
⑤ If the acceptance of the project is delayed or unqualified due to Party A's reasons, Party A shall not delay the payment to Party B for any reason.
2. Party B's responsibilities:
① Install and debug in strict accordance with the requirements of Party A, fire department and relevant national codes. Party B is responsible for organizing the overall acceptance of this fire fighting project.
(2) During the construction period, Party B shall strictly carry out workers' safety education, strictly implement the production management on the construction site, and achieve civilized and safe construction. During the construction period, Party B shall obey the management of Party A and shall not damage the production equipment on site.
(3) Ensure that the materials and equipment used meet the fire control quality standards, and have production licenses, inspection reports, production certificates and other related documents. The construction can only be started after the materials used are approved by Party A and the supervisor.
Eight, the construction organization progress, suspension of construction and time delay responsibility
1. Party B must organize the construction according to the progress plan confirmed by the engineer of Party A, and accept the engineer's inspection and supervision of the progress. When the actual progress of the project is inconsistent with the confirmed progress plan, Party B shall propose improvement measures according to the requirements of the engineer and implement them after being confirmed by the engineer. If the actual progress is inconsistent with the plan due to Party B's reasons, Party B has no right to propose additional contract price for improvement measures.
2. Party B shall start construction according to the commencement date agreed in this agreement. If Party B fails to start the construction on time, it shall submit the reasons and requirements for delaying the construction to the Engineer in writing not later than 7 days before the commencement date agreed in this agreement. If the engineer fails to reply within 48 hours after urging the application for delayed commencement, it shall be deemed that he agrees with Party B's request, and the construction period shall be postponed accordingly. If the engineer does not agree to the extension request or Party B fails to put forward the extension request within the specified time, the construction period will not be extended.
3. If the commencement date agreed in this agreement cannot be started due to Party A's reasons, Party A's engineer shall notify Party B in writing to postpone the commencement date. Party A shall compensate Party B for the losses caused by the delayed commencement of construction, and postpone the construction period accordingly.
4. When the engineer thinks it is really necessary to suspend the construction, he shall request Party B to suspend the construction in writing, and put forward written opinions within 48 hours after the request is made. Party B shall stop the construction as required by the engineer and properly protect the completed project. After Party B implements the engineer's handling opinions, it may put forward a request for returning to work in written form, and the engineer shall give a reply within 48 hours. If the engineer fails to put forward the handling opinions within the specified time, or fails to reply within 48 hours after receiving Party B's request to resume work, Party B may resume work by itself.
5. If the construction period is delayed due to the following reasons and confirmed by the engineer, the construction period will be postponed accordingly:
(1) Party A fails to provide the drawings and commencement conditions as agreed;
(2) Party A fails to pay the project advance payment and progress payment according to the agreed date, which makes the construction unable to proceed normally;
(3) The engineer failed to provide the required instructions and approvals as agreed in the contract, which made the project unable to proceed normally;
(4) Design change and increase of engineering quantity;
⑤ Within one week, the water, electricity and gas cut-off caused by reasons other than Party B have accumulated for more than 8 hours;
⑥ Force majeure;
⑦ Other circumstances in which the engineer agrees to postpone the construction period.
Nine, project completion acceptance
1. Party B must complete the project according to the completion date agreed in the agreement or the extended period agreed by the engineer.
2. If the project cannot be completed according to the completion date agreed in the agreement or the extended time limit agreed by the engineer due to Party B, Party B shall be liable for breach of contract.
3. If Party A needs to complete the project ahead of schedule during the construction, both parties shall negotiate and sign an early completion agreement, which is an integral part of the contract documents. The early completion agreement shall include the measures taken by Party B to ensure the quality and safety of the project, the conditions provided by Party A for early completion and the additional contract price required for early completion.
4. The project quality should meet the quality standards agreed in the agreement, and the evaluation of quality standards should be based on the quality inspection and evaluation standards of the country or industry.
5. If both parties dispute the quality of the project, it shall be appraised by an engineering quality inspection agency agreed by both parties, and the expenses and losses arising therefrom shall be borne by the responsible party. Both parties have responsibilities, which shall be borne by both parties according to their respective responsibilities.
6. If the project is completed and accepted, Party B shall provide Party A with complete completion data and completion acceptance report in accordance with relevant national regulations on project completion acceptance.
7. Party A shall organize relevant units to carry out acceptance within 28 days after receiving the completion acceptance report, and give approval or propose amendments within 14 days after the completion acceptance. Party B shall revise as required, and bear the expenses caused by its own reasons.
8. If Party A fails to organize the acceptance within 28 days after receiving the completion acceptance report sent by Party B, or fails to propose amendments within 14 days after acceptance, the completion acceptance report shall be deemed to have been approved.
9. Party A shall not use any project that has not been completed and accepted or is unqualified. When Party A forcibly uses it, Party A shall be responsible for the quality problems and other problems arising therefrom.
10. Party B shall be fully responsible for relevant matters and provide the acceptance permit of the fire department.
X. Quality assurance
1. Party B shall, in accordance with laws, administrative regulations or relevant national regulations on project quality warranty, undertake the quality warranty responsibility for the project delivered to Party A for use during the quality warranty period, and deduct 3% of the total price as the quality deposit at the last payment. The warranty period is one year from the date of obtaining the fire permit.
2, the implementation of quality warranty work. Before the project is completed and accepted, Party B shall sign a quality guarantee with Party A as an annex to this contract.
XI。 responsibility for breach of contract
1, Party A's liability for breach of contract. When the following happens:
After Party B enters the site, the construction period is delayed due to Party A's mistakes in the construction process, and all losses shall be borne by Party A. ..
2. Party B violates this contract. When the following happens:
(1) Party B fails to complete the project according to the completion date agreed in the agreement or the extended time limit agreed by the engineer.
② The project quality fails to meet the quality standards agreed in this agreement due to Party B's reasons.
③ Other circumstances in which Party B fails to perform its contractual obligations or fails to perform its obligations as agreed in the contract.
(4) Modify the drawings without Party A's consent, and do not construct according to the drawings.
Party B shall bear the liability for breach of contract and compensate Party A for the losses caused by its breach of contract.
3. After the breaching party breaches the contract, when the observant party requests the breaching party to continue to perform the contract, the breaching party shall continue to perform the contract after assuming the above liabilities for breach of contract.
Twelve. Entry into force of contract
Date of conclusion of the contract: year month day.
Contract signing place:
Both parties agree that:
This contract is made in quadruplicate, with Party A and Party B holding two copies respectively. For matters not covered in this contract, both parties can sign a supplementary agreement through consultation, which has the same legal effect as this contract.
This contract shall be terminated after Party A and Party B have fulfilled all their obligations under this contract, paid the completion settlement price and Party B delivered the completed project to Party A..
After the termination of the rights and obligations under this contract, both parties shall abide by the principle of good faith and perform the obligations of notification, assistance and confidentiality.
Party A: (official seal)
Party A: (official seal)
Fire Project Cooperation Agreement 4 Party A:
Party B:
Based on the principle of equality and mutual benefit, Party A and Party B have reached the following contract terms for this project and weak current fire protection installation project:
I. General situation of the project: fire protection weak current system safety.
Project name:
Second, the team will carry out the construction according to the construction drawings provided by Party A, and the team will ensure the cleaning work.
Three. Duration: subject to the total duration of the project department and implemented according to the construction progress plan issued by the project department.
Fourth, the quality grade: qualified.
Verb (abbreviation of verb) Total contract price: 365,438+0 yuan per point.
Terms of payment for intransitive verbs:
1. Party B shall carry out the construction in strict accordance with the requirements of the construction drawings and construction specifications provided by Party A as stipulated in the contract to ensure the construction quality. If the construction quality does not meet the contract requirements or there are quality problems, Party B must rework unconditionally, and all expenses shall be borne by Party B. ..
2. If Party A fails to pay the project payment (progress payment) as agreed in the contract, and both parties fail to reach an agreement on deferred payment, Party B may stop the construction, and Party A shall bear the liability for breach of contract.
Seven, safe production and civilized construction
1. When entering the workshop, Party B's construction personnel shall abide by laws and regulations and strictly implement the policy of "safety first, prevention first". Abide by the safety operation rules, make good use of the "three treasures", do a good job in the protective measures of "four mouths" and "five emergencies", and often educate workers to prevent accidents. Party B shall be responsible for the management and compensation of accidents and losses caused by violation of safety operation regulations.
Eight. Responsibilities of Party A and Party B
Party A:
1, provide construction drawings and related technical documents, and make technical disclosure.
2. Party A shall provide the main materials and auxiliary materials in time, and shall not provide jobs. If the materials are delayed, Party A will give corresponding subsidies.
Party B:
1. Party B must wear safety helmet when going to work, and shall not wear slippers or go to work barefoot.
Don't fight and make trouble in the construction site, or you will be fined. If the circumstances are serious, Party A has the right to send it to the public security department for handling.
Party A: (signature)
Party B: (signature)
Fire Project Cooperation Agreement 5 Party A (labor contract issuer):
Party B (Labor Contractor):
In the spirit of friendly cooperation and in accordance with the Civil Law and other relevant laws, Party A and Party B sign the following contract on the basis of equality and fairness:
I. Overview of the Project
Project address:
Project name:
Project content:
Second, the contract price
1. Indoor fire hydrant system is only calculated according to the number of boxes, excluding other installation costs such as pipes and fittings. The specific unit price is as follows:
Box specification: 1600x700x240, unit price: RMB/piece.
2. The indoor automatic sprinkler system is only calculated according to the number of nozzles, excluding other installation costs such as pipes and fittings. The specific unit price is as follows:
Nozzle type: downward spraying, unit price: xx yuan/piece.
3. The fire alarm system is calculated according to the number of probes, and the installation cost of weak wire tube (yuan/m). The specific unit price is as follows:
Unit price of probe: RMB/set
4. The outdoor fire water supply system is only calculated according to the length of the pipeline (from the fire pool water supply supervisor to the outdoor municipal water supply pipeline, about xx meters), excluding other installation costs such as accessories. * * * xx yuan, excluding the cost of earthwork excavation.
5. Sporadic expenses such as opening holes in black boxes, blocking holes, and opening holes in walls. The specific unit price is as follows: fee content: opening DN 150 holes, unit price: xx yuan/piece.
6. Due to changes in design, requirements of the owner and the supervisor, and other visa contents, after the visa form is finally reviewed, Party A shall pay xxx to Party B separately according to the fixed labor cost.
7. The fire pump house includes 2 main fire pumps, 2 pressure stabilizing pumps, 1 pneumatic tank and 1 wet alarm valve * * *.
8. The debugging fee of fire protection system is only the debugging fee of alarm system, with a subtotal of xx yuan. The debugging fee of fire hydrant and automatic sprinkler system is not counted separately.
Three. terms of payment
1. Within 1 week after Party B enters the site for construction, Party A shall pay Party B the monthly living expenses in RMB.
2. After Party B installs the fire sprinkler branch pipe and weak current branch pipe (including threading), Party A shall pay 85% of the project payment to Party B within 1 week; Pay off the balance within one month after the fire department has passed the acceptance.
Four, materials and construction site
1. Party B shall make a list of engineering materials, and Party A shall select brands for Party B to buy, and Party B shall be responsible for the construction, with more refunds and less supplements. Party B's construction tools and pressure testing tools shall be provided by Party B. ..
2. Party B shall provide Party A with a list of materials to be purchased two days in advance, and Party A shall timely purchase materials for the use of the construction team within two days, and both parties shall bear the responsibilities and economic losses of the other party for delaying the construction period.
3. Before Party B enters the site, Party A shall provide the construction surface and residence. If renting a house outside, Party A pays the rent and Party B pays the utilities.
Verb (abbreviation of verb) contract dispute
1. In case of any dispute, Party A and Party B shall settle it through negotiation first.
2. If negotiation fails, a lawsuit can be brought to the court where the dispute is located.
3. This contract is made in duplicate, with each party holding one copy.
Representative of Party A (signature):
Person in charge of Party B (signature):