Demonstration seedling planting contract 1
Party A:
Party B:
In order to * * * complete the greening landscape project of the new campus of the Party School of Pingxiang Municipal Committee quickly, on time and with high quality, and reach the acceptance standard, and at the same time, for the friendship between the two parties, no dispute occurs, the following agreement is reached:
1, construction site:
2, the construction unit:
3. Project contracting method: contracting for work and materials (lump sum).
4. Contract quantities: The unfinished greening quantities of the new campus shall be subject to the design drawings of the third edition in June 2000, including the newly-added seedlings (page 3 of Annex I, which shall be recognized and signed by both parties). The number of seedlings is for reference only, and the actual amount is subject to the quality standards required by the design. If there are any trees provided by Party A, the price of seedlings in the list determined on page (2) of Annex II shall be deducted).
5. Party A shall fulfill its obligations: Party A has enough water to supply and place the nursery stock site 24 hours a day, and use electricity for overtime. After Party A has no objection to the acceptance of Party B's seedlings, Party A shall pay the money according to the agreed time (except holidays).
6. Party B shall fulfill its obligations: Party B shall pay attention to cleanliness and civilized construction. Seedling size is designated by Party A, and the quality shall not be changed at will. Only after the change is approved by Party A can the seedlings be changed. The seedlings shall not be sick, and the red flowers and green leaves shall be guaranteed.
7. General contracting cost: The total cost is RMB five hundred and twenty thousand Yuan only. (excluding tax).
8. Payment method: 60% of the project progress. After the seedlings enter the first car, they will be paid in installments from the second car (60% of the cost). 90% of the total project cost shall be paid within 65,438+05 days after the project completion acceptance, and the remaining 65,438+00% deposit shall be paid within 65,438+05 days after the one-year acceptance of seedling maintenance.
9. Other unfinished matters shall be settled through negotiation.
10. This contract is made in duplicate, with each party holding one copy and abiding by it together!
Signature (seal) of Party A's representative: signature (seal) of Party A and Party B's representatives:
date month year
Model seedling planting contract II
Party A: Party B:
Party A and Party B negotiate on the principle of equality, mutual benefit and cooperation, and Party A contracts the project to Party B for planting by means of materials and living, and reaches the following contract terms.
I. Name and content of the project
1. Project name:
2. Construction content:
Second, the construction time:
From year month day to year month day. This time includes a one-year curing period.
Third, the way of contracting.
This project is organized by Party B in the form of maintaining and managing contractors and material packages.
Fourth, the scope of planting
1. Plant corresponding seedlings at the place designated by Party A;
2. Replace and replant the seedlings that died and grew poorly during the maintenance period.
Five, planting requirements (variety and price)
Six, quality standards and quality assurance
1. According to Party A's existing greening surface, Party B will organize personnel to dig pits, fertilize and plant, so as to ensure that the seedlings grow well and are free from pests and diseases.
2. During the construction period, the greening materials used by Party B shall conform to the varieties, specifications and grades specified by Party A. ..
3. Project warranty period: one year after Party B's project is completed and accepted. Party B shall be responsible for the maintenance and management of green seedlings for one year, and ensure the survival rate reaches 100%.
Seven. terms of payment
After the project is completed and accepted by Party A, Party A shall pay% of the total project price within one week, that is, RMB (in words): the balance shall be paid within one week after the warranty period expires and Party A passes the acceptance. ..
Eight. Responsibilities of Party A and Party B
1. Party A is responsible for providing water source for seedling irrigation and coordinating the construction environment;
2. Party A will send on-site representative (name: Tel:) to conduct quality supervision. If the site representative thinks that there may be problems with the project quality, he has the right to ask Party B to stop work and listen to the handling opinions. Beyond the number of projects and changes in the number of projects, Party B's visa is required for approval;
3. Party B is responsible for making a good construction organization plan, informing Party A of the construction progress and changes of engineering quantity in time, and completing the project tasks with good quality and quantity as scheduled according to the overall arrangement of Party A;
4. Party B is responsible for dispatching the project manager (name: telephone:) to be fully responsible for the project implementation;
5. Party B is responsible for the personal safety of construction personnel, and any accident has nothing to do with Party A..
Nine. responsibility for breach of contract
If one party breaches the contract, the other party may terminate the contract and charge the other party a penalty of% of the contract amount; If the project is not completed on schedule, a penalty of% of the contract amount will be charged for each day of delay. In case of force majeure, the construction period will be postponed.
Ten, engineering subcontracting
Party B shall not subcontract its contracted projects to others, nor shall it dismember all its contracted projects and subcontract them to others in the name of subcontracting. If it is necessary to transfer (subcontract) under special circumstances, the written consent of Party A must be obtained.
XI。 force majeure
Force majeure includes explosions, fires and agreed natural disasters caused by war, turmoil, falling objects in the air or other responsibilities not attributable to Party A and Party B. ..
Twelve. Dispute mediation
In case of any dispute arising from the performance of this contract, both parties agree to submit it to Guiyang Arbitration Commission for arbitration.
Thirteen. This contract is made in duplicate, one for each party. This contract shall come into effect after being signed and sealed by both parties.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Model seedling planting contract 3
Employer (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
according to
The rights, obligations and economic responsibilities in the construction process shall be agreed by both parties through consultation and this contract shall be signed.
Article 1: General situation of contracted projects
I. Project name:
Second, the project site selection:
Third, the way of contracting: contracting, contracting materials, contracting survival, contracting time, ensuring quality and safety.
4. Planting varieties and unit price: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Verb (abbreviation of verb) project cost: The total project cost of this contract is RMB day.
6. Duration of the project: the project starts at and ends at. (In case of force majeure and natural disasters, or Party A's reasons, which affect the construction, the construction period can be extended after Party A's visa. If the construction period is delayed due to Party B, Party B shall pay Party A a penalty of RMB 65,438+RMB 0,000 for each day of delay. Party A can deduct it from Party B's project payment)
Article 2: Representatives of Party A and Party B
Name of legal representative of Method A:
ID number:
Name of Legal Representative of Party B:
ID number:
Article 3: Rights, obligations and responsibilities of both parties during the construction period.
3. 1 Party A:
1. Provide Party B with the temporary site needed for construction.
Second, provide water and electricity to ensure the normal construction.
Third, provide relevant information such as engineering geology and underground pipe network lines on the construction site, and coordinate and deal with unforeseen problems in construction.
3.2 Party B:
First, the construction (seedling planting project) must be organized according to the contract requirements. Includes seedling raising, packaging, transportation, digging, soil replacement, miscellaneous fertilizer purchase, planting, greening, earthwork leveling and replacement, soil filling, muck transportation, cleaning, watering, pest control, weeding, pruning, fertilization, replacement of dead seedlings and maintenance.
Second, the project is responsible for maintenance for one month. Ensure that the survival rate of seedlings reaches 90%. Party B shall submit to Party A the maintenance plan of greening project for next month.
Three. When Party B fails to complete all the work as agreed in the contract, it shall bear the direct economic losses caused thereby.
Four. During the seedling planting project and maintenance, all personnel in the unit should be educated to take care of flowers and trees. In case of man-made injury, Party B shall bear the economic responsibility for the loss of seedlings.
5. In the process of construction, Party B must obey the supervision, inspection and quality management of Party A. If rework is caused by quality problems, all expenses shall be borne by Party B.:
6. Party B shall carefully organize during the construction to ensure safety. In case of any accident, the consequences shall be borne by Party B.. Party B shall ensure that the construction site is clean and clean up the garbage in time.
7. Party B shall maintain the seedlings for months after planting, and the expenses incurred during the maintenance period shall be borne by Party B. ..
3.3 When either party requests to change the design, it must be agreed by both parties before the construction can be organized according to the modified design, and the corresponding investment can be adjusted and a supplementary agreement can be signed.
Article 4: Project Quality Inspection and Acceptance
1. After planting is completed, Party B shall conduct self-inspection and notify Party A for joint acceptance. After the acceptance, Party A shall sign the acceptance record. After the maintenance period expires, Party A re-accepts, and the survival rate of seedlings reaches 90%. If the contract requirements cannot be met, Party B shall be responsible for replanting or Party A shall deduct the expenses according to the unit price of seedlings.
2. After the maintenance period expires, Party A shall organize the acceptance on the same day. If Party A fails to receive the goods on time and causes losses to Party B, Party A shall bear all the responsibilities.
Third, the scope of project quality warranty: quality warranty is the maintenance and management of the project; Including the maintenance and management of green seedlings, flowers, lawns and garden sketches. The specific quality warranty contents are as follows: according to the planting list of design drawings, do a good job in greening, pruning, weeding, watering, pest control and other maintenance and management.
Article 5: Settlement of project funds:
1. After signing this contract, Party A shall pay% of the total project investment in advance, RMB * *.
2. After the project maintenance expires, Party A shall pay off all the balance, namely RMB * * *.
Article 6: Supplementary provisions
1. This contract is made in duplicate, with each party holding one copy.
2. This contract shall come into effect as of the date of signing, and shall become invalid after all the projects are completed and accepted and the balance payment is settled.
Three. For matters not covered in this agreement, both parties shall sign a supplementary agreement through consultation. The contents of the supplementary agreement shall not conflict with the contents of this agreement; The supplementary agreement has the same legal effect as this agreement.
Four. Dispute settlement: All disputes related to this contract shall be settled by both parties through consultation. If negotiation fails, you can apply to Changzhou arbitration institution for arbitration, and the arbitration result is final.
Article 7: Breach of Contract
If Party A and Party B fail to perform their respective obligations according to the contents of this agreement, resulting in the inability to perform the contract, they shall bear corresponding liabilities for breach of contract, including paying 5% of liquidated damages, compensating the other party for the direct economic losses caused by its breach of contract, and continuing to perform the contract unless both parties agree to terminate the contract.
Date of signing this contract: year month day.
Party A: (Seal) Address of Party B (Seal):
Legal Representative: Legal Representative: Authorized Agent: Authorized Agent: Tel: Tel:
Three related articles about the model contract of seedling planting;
★ Seedling planting contract
★ Seedling planting contract
★ Three samples of landscaping contract.
★ 3 samples of greening labor contract
★ 3 The latest green planting contract terms
★ The latest three modes of individual farmland contract.
★ Three samples of greening construction contract.
★ Simple afforestation contract mode
★ 3 copies of the lease contract for nursery land.
★ 3 model essays on contracted greening projects.