Project Development Agreement 1 Owner: Fire Door Branch of Chongqing Maxim Security Door Group
Contractor:
In accordance with the Contract Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reach an agreement on the construction of this building project and conclude this contract.
I. Overview of the Project
1. Project address: Chongqing Olympic Garden
Project content: Installation and acceptance of fire doors in Chongqing Olympic Garden construction project and related contract agreements.
Second, the project contract period
Commencement date: 20xx65438+February 7th Completion date: May 30th, 20xx.
Third, the quality standard
This standard is based on the installation, debugging and standard implementation of fire doors of National Fire Bureau.
Four. Contract price
Total project cost (amount): RMB 4 million only.
Verb (abbreviation of verb) payment terms
1. After Party B enters the site, Party A shall pay Party B 30% of the project cost, 50% in the interim and 20% after completion, and Party A shall withhold 5% of the project cost as the security deposit, which will be paid one year later.
2. Party B must pay 20% of the project cost to Party A as the project transfer fee.
Six, the construction requirements
Clean up all the rubbish in the original site and transport it out. All fire doors have been installed and accepted.
Seven. Rights and obligations of both parties:
1. Party B shall not default on the wages of construction workers during the construction process, which has nothing to do with Party A's economic disputes and other disputes, and Party A shall not assume any responsibilities. Party B shall be responsible for all accidents and disability incidents during the construction, and Party A shall not bear any responsibility.
2. Fighting, drunkenness and theft are strictly prohibited in Party B's construction site. In case of such situation, Party B shall hand it over to the public security organ for handling and compensate all losses.
3. Party B must carry out the construction according to the contract requirements and ensure the construction quality and requirements. If Party A suffers from waste and loss of building materials, Party B will take double indemnity.
4. If Party B fails to carry out the construction according to the contract requirements, Party A has the right to refuse to pay the balance and clean up Party B, and the losses shall be borne by Party B. ..
Eight. If this contract is inconsistent with the original contract, the requirements of the original contract shall prevail.
Nine. This contract is made in duplicate, one for each party, and shall come into effect as of the date of signature by both parties.
Party A: Chongqing Maxim Security Door Group Fire Door Branch
Party B:
date month year
Chapter II of the Project Development Agreement Party A:
Party B: (Personal) ID number:
Xxxx (individual) (hereinafter referred to as Party B) is entrusted by _xxx (hereinafter referred to as Party A) to develop _ XXX information management database. Based on the principle of mutual cooperation and mutual benefit, both parties reached the following agreement through consultation:
I. Project name:
CICC project information management database
Second, the content and requirements:
1. development content: according to the requirements of party a, party b completed the development of xxx information management database within the specified time. The design requirements of the system are as follows:
2. Main functions: adding, modifying, querying, deleting, modifying and backing up the engineering database.
Design and test projects according to requirements. The specific work shall be arranged by Party A. ..
3. The operating environment of the system includes:
(1)windows operating system
(2)sql database system
4. Development time:
(1) Commencement date: the official commencement date of the project is the date of signature and seal by both parties;
(2) Completion period: within 30 working days from the official start of the project.
Three. Rights and obligations of both parties:
1. Party A:
(1) Party A has the right to urge Party B to complete the project development within the specified time. If there are any supplements or amendments, both parties shall negotiate separately. Without affecting the progress, Party B must meet the needs of Party A for small-scale changes; In case of major changes, Party A and Party B shall negotiate to extend the development cycle and increase the development cost.
(2) Party A has full ownership of xxx information management database system, including all rights such as the right to use and copyright;
(3) Party A shall pay the development expenses to Party B on time as agreed;
(4) Party A is responsible for keeping the contents of this agreement confidential;
(5) Party A has the responsibility to keep Party B's software development technology confidential and shall not disclose it to a third party without Party B's written permission.
(6) Party A has the responsibility to keep Party B's personal information confidential and shall not disclose it to a third party.
2. Party B:
(1) Party B is responsible for completing the project development within the specified time as required by Party A, and completing the contents that need to be developed;
(2) After the completion of the project development, during the maintenance service period provided by Party B to Party A, if the demand changes due to Party A's design changes, if the change scope is within the functional scope specified in this contract, Party B is obliged to modify the change content for Party A free of charge;
(3) Party B is responsible for keeping the contents of this agreement confidential;
(4) Party B has the responsibility to keep the interface specification with Party A confidential and shall not disclose it to a third party without the written permission of Party A;
(5) Party B has the responsibility to provide Party A with free maintenance service for 30 days after the project acceptance. This maintenance only refers to the modification of software bugs and small-scale functional changes;
(6) Party B is responsible for preparing the hardware equipment and development materials needed for software development.
Four. Fees and payment methods:
1. Cost: The total cost of this project is 8000 yuan.
2. Payment method:
1) Before the project development, Party A and Party B shall pay 3,000 yuan in advance;
2) Complete the test acceptance within 10 working days after the overall development of the project, and provide the acceptance report to Party B.. At the same time, Party B will deliver the relevant software design documents to Party A, and Party A will pay Party B a second development fee of RMB 3,000 within 3 working days.
3) After the system runs for one month, if everything is normal, Party A will pay Party B the remaining development expenses of 2,000 yuan.
3. Liability for breach of contract:
(1) Party A is responsible for paying Party B's expenses on schedule. If Party A fails to deliver the goods on time due to its own reasons, Party A will pay an additional 0.5% of the total cost of Party B as compensation for each day of delay;
(2) Party B has the responsibility to deliver the source code and design documents to Party A on schedule to realize all the functions in the project. If Party B fails to deliver the goods on time due to its own reasons, Party A will deduct 0.5% of Party B's total expenses as compensation for each day of delay. If Party B fails to deliver the goods on time due to Party A's reasons, Party B will not bear the losses caused thereby.
Verb (abbreviation of verb) Applicable law:
This Agreement shall be interpreted in accordance with the laws of People's Republic of China (PRC).
Arbitration of intransitive verbs
Any dispute arising from the performance of this agreement shall be settled by both parties in the principle of friendly consultation. If negotiation fails, either party may submit the dispute to the local arbitration commission for arbitration according to its arbitration rules. The arbitration decision is binding on both parties. During the dispute arbitration, Party A and Party B shall continue to perform their obligations and exercise their rights stipulated in this contract except for the disputed matters.
Seven. Contact persons and contact information designated by Party A and Party B.
Party A:
Contact person:
Contact telephone number:
Party B:
Contact person:
Contact telephone number:
If Party A and Party B change their contact persons, they shall notify each other in writing.
Eight. Others:
This contract is made in duplicate, each party holds one copy, and the signature and seal are valid.
Party A:
Signature (seal) of representative:
Date: XX _ _ _ _ _ _ _ _
Party B:
Signature (seal) of representative:
Date: XX _ _
Article 3 of the project development agreement: Party A (the entrusting party): _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _
Tel: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B (trustee): _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _
Phone number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A and Party B, in accordance with the relevant laws and regulations of the State and Shenzhen Special Economic Zone and on the principle of equality and mutual benefit, have reached the following agreement on the matter that Party A entrusts Party B to handle _ _ _ _ _ _ _ _ _ _ land development consultation, for both parties to jointly perform.
Article 1 Basic information of the project
1. Project name:
2. Project scale:
3. Parcel number:
4. Total area:
5. Planning scope: (see attached figure)
Article 2 Ways of cooperation
1. Party A provides the above development land and cooperates with Party B to develop and construct commercial real estate. Party B shall be responsible for the preliminary demonstration and relevant procedures of project development at this stage, and Party A shall pay corresponding service fees to Party B according to relevant regulations.
Article 3 Payment and payment methods
1. The consulting service fee for this project is RMB per square meter. If the project covers an area of _ _ _ _ _ square meters and the plot ratio is _ _ _ _ (subject to the actual approval), Party A shall pay Party B the entrustment fee of RMB _ _ _ _ _ _ _ _ (in words: fourteen million yuan only).
2. This project adopts installment payment, namely:
(1) Party A shall pay _ _ _ of the total price to Party B as a down payment, that is, RMB _ _ _ ten thousand yuan (in words: _ _ ten thousand yuan only) within _ _ working days from the date when both parties sign this contract; The deposit will offset the contract price payable in the second payment.
(2) Party A shall pay Party B _ _% of the total price, that is, RMB _ _ _ _ ten thousand yuan (in words: _ _ ten thousand yuan only), after Party B promotes the revision of the statutory plan (after arranging the revision scheme).
(3) After the project has passed the acceptance of Luohu Old Reconstruction Office and passed the preliminary examination, Party A shall pay _ _% of the total price to Party B within the next three working days, that is, RMB _ _ _ million (in words: one hundred thousand yuan only).
(4) After the project is approved by the Municipal Bureau of Urban Renewal or other relevant departments of the municipal government, Party A shall pay 40% of the total price to Party B, that is, RMB 5.6 million (in words: _ _ ten thousand Yuan only).
(5) After the project is approved by the municipal government, the balance will be paid off.
Article 4 Rights and obligations of both parties
I. Rights and obligations of Party A
1. Party A shall, within _ _ working days from the date when both parties sign the contract, promptly assist Party B to collect and prepare the materials required by the agency.
2. Party A shall pay the contract price to Party B at the time and amount stipulated in this contract.
3. Party A shall fully cooperate with and assist Party B to handle the formalities for the construction and approval of this project, and provide and sign (affix the official seal of Party A) the supporting documents and materials.
Two. Rights and obligations of Party B
1. Party B shall work in accordance with the relevant laws, regulations, design standards and technical specifications of the state and _ _ _.
2. Party B shall actively and seriously communicate with relevant government departments and technical design departments to complete the development procedures related to this project.
3. Have the obligation to report the progress of handling the entrusted matters at any time according to the requirements of Party A;
4. Party B shall go through the relevant legal procedures when handling the plot, and Party B shall be responsible for the relevant responsibilities arising from the inconsistent development procedures.
5. If Party A intends to cooperate with _ _ _ _ _ _ _ _
Article 5 confidentiality clause
1. Party A and Party B shall abide by the relevant national confidentiality regulations, properly keep the information provided by the other party, keep the secrets of the other party and protect the intellectual property rights of the other party.
2. Without the permission of the other party, neither party may transfer the other party's data or achievements to a third party or use them for other projects outside this contract. In case of the above situation, the disclosing party shall bear all consequences arising therefrom and pay% of the total contract price as liquidated damages.
Article 6 Term of Cooperation
1. The cooperation period of this project is _ _ _ years, counting from the date of signing the formal agreement. If the time limit can be extended for government reasons, a supplementary agreement can be signed at that time. The supplementary agreement has the same legal effect as this agreement.
Article 7 Liability for breach of contract
1. During the performance of this contract, if either party has other breach of contract, it shall be handled in accordance with the provisions of this contract. If there is no agreement, it shall be handled according to law.
2. If there is any dispute over the confirmation of the property right of the development plot provided by Party A; Or Party A, in violation of the relevant provisions of this Agreement, develops and develops land on its own or signs any contract or agreement with a third party such as transfer, renovation and cooperative lease, or sets any third party's rights and interests; Or Party A fails to provide Party B with the certification documents sealed by Party A in time, which makes it impossible for Party B to fulfill the formalities of applying for approval and construction of cooperative land development and realize the purpose of land development, Party B has the right to terminate this agreement and compensate Party B for its economic losses.
3. If Party B breaches the contract or fails to complete the approval and construction application procedures within the time limit stipulated by the government, Party A has the right to terminate the cooperation agreement with Party B, and Party B shall not pursue Party A's economic and legal responsibilities for any reason.
Article 8 Methods of settlement of contract disputes
During the performance of this contract, if there is any dispute between the two parties, it shall be settled through consultation. If negotiation fails, it shall be submitted to the people's court for adjudication.
Article 9 Supplementary Provisions
This Agreement is made in quadruplicate (two for each party) and shall come into force after being signed and sealed by both parties. If there are any outstanding matters, both parties shall settle them through consultation. If no agreement can be reached, it shall be settled by the local arbitration department.
Entrusting party (Party A)
legal representative
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Trustee (Party B)
legal representative
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 4 of the Project Development Agreement: Party A: _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and other relevant laws and regulations, Party A and Party B, on the basis of equality, voluntariness, fairness, honesty and credibility, have reached the following agreement through consultation:
Party B shall pay RMB _ _ _ _ _ _ _ _ (in figures) at the event site; Party A gives Party B the following items: _ _ _ _ _ _ _ _ _ _ _ All kinds of items: _ _ _ _ _ _ All kinds of items \ The business sharing ratio of both parties is: _ _ _ _ _ _ (Party A: Party B); If the performance is achieved within one year (after sharing): _ _ _ _ _ _ (in words), all the deposit will be returned; The validity period of this agreement is: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
The accession policy is as follows:
Remarks:
1. The donated items are only for the use of Party B's boss, and this amount shall not be used for customers, otherwise Party A has the right to terminate the cooperation and confiscate all the down payment;
2. The setting of the full refund amount is that Party A will give Party B a special reward, and this amount is the performance of sharing;
3. The amount of gifts, activities and full refund is valid for one year, and the sharing ratio remains unchanged during the contract period.
Party A:
Party B:
Signing time: year month day
Article 5 of the Project Development Agreement: Party A (Entrusting Party): xx
Legal Representative: xx
Telephone message:
Party B (Trustee): xx
Legal Representative: xx
Telephone message:
Party A and Party B, in accordance with the relevant laws and regulations of the State and Shenzhen Special Economic Zone, and in line with the principle of equality and mutual benefit, have reached the following agreement through consultation for both parties to perform jointly.
Article 1 Basic information of the project
1. Project name:
2. Project scale:
3. Parcel number:
4. Total area:
5. Planning scope: (see attached figure)
Article 2 Ways of cooperation
1. Party A provides the above development land and cooperates with Party B to develop and construct commercial real estate. Party B shall be responsible for the preliminary demonstration and relevant procedures of project development at this stage, and Party A shall pay corresponding service fees to Party B according to relevant regulations.
Article 3 Payment and payment methods
1. The consulting service fee for this project is RMB xx per square meter. If the project covers an area of xx㎡ and the plot ratio is X (subject to the actual approval), Party A shall pay Party B the entrustment fee of RMB XX million (in words: fourteen million yuan only).
2. This project adopts installment payment, namely:
(1) Within x working days from the date when both parties sign this contract, Party A shall pay x% of the total price to Party B as the down payment, that is, RMB ￥x million (in words: X million only); The deposit will offset the contract price payable in the second payment.
(2) After Party B promotes the revision of the statutory plan (after arranging the revision plan), Party A shall pay x% of the total price of Party B, that is, RMB X million Yuan (in words: X million Yuan only).
(3) After the project has passed the acceptance of Luohu Old Reconstruction Office and the preliminary examination, Party A shall pay x% of the total price to Party B within the next three working days, that is, RMB X million (in words: X hundred thousand Yuan only).
(4) After the project is approved by the Municipal Bureau of Urban Renewal or other relevant departments of the municipal government, Party A shall pay 40% of the total price to Party B, that is, RMB 5.6 million (in words: X million yuan only).
(5) After the project is approved by the municipal government, the balance will be paid off.
Article 4 Rights and obligations of both parties
I. Rights and obligations of Party A
1. Party A shall, within x working days from the date when both parties sign the contract, assist Party B to collect and prepare the information required by the agency in time.
2. Party A shall pay the contract price to Party B at the time and amount stipulated in this contract.
3. Party A shall fully cooperate with and assist Party B to handle the formalities for the construction and approval of this project, and provide and sign (affix the official seal of Party A) the supporting documents and materials.
Two. Rights and obligations of Party B
1. Party B shall work in accordance with relevant laws, regulations, design standards and technical specifications of the State and xx.
2. Party B shall actively and seriously communicate with relevant government departments and technical design departments to complete the development procedures related to this project.
3. Have the obligation to report the progress of handling the entrusted matters at any time according to the requirements of Party A;
4. Party B shall go through the relevant legal procedures when handling the plot, and Party B shall be responsible for the relevant responsibilities arising from the inconsistent development procedures.
5. If Party A intends to cooperate with xx enterprise in this project, the company to which Party B belongs will have priority.
Article 5 confidentiality clause
1. Party A and Party B shall abide by the relevant national confidentiality regulations, properly keep the information provided by the other party, keep the secrets of the other party and protect the intellectual property rights of the other party.
2. Without the permission of the other party, neither party may transfer the other party's data or achievements to a third party or use them for other projects outside this contract. In case of the above situation, the disclosing party shall bear all the consequences arising therefrom and pay a penalty of X% of the total contract price.
Article 6 Term of Cooperation
1. The cooperation period of this project is x years, counting from the date of signing the formal agreement of this project. If the time limit can be extended for government reasons, a supplementary agreement can be signed at that time. The supplementary agreement has the same legal effect as this agreement.
Article 7 Liability for breach of contract
1. During the performance of this contract, if either party has other breach of contract, it shall be handled in accordance with the provisions of this contract. If there is no agreement, it shall be handled according to law.
2. If there is any dispute over the confirmation of the property right of the development plot provided by Party A; Or Party A, in violation of the relevant provisions of this Agreement, develops and develops land on its own or signs any contract or agreement with a third party such as transfer, renovation and cooperative lease, or sets any third party's rights and interests; Or Party A fails to provide Party B with the certification documents sealed by Party A in time, which makes it impossible for Party B to fulfill the formalities of submitting for approval and construction for cooperative land development and realize the purpose of land development, Party B has the right to terminate this agreement and compensate Party B for its economic losses.
3. If Party B breaches the contract or fails to complete the approval and construction application procedures within the time limit stipulated by the government, Party A has the right to terminate the cooperation agreement with Party B, and Party B shall not pursue Party A's economic and legal responsibilities for any reason.
Article 8 Methods of settlement of contract disputes
During the performance of this contract, if there is any dispute between the two parties, it shall be settled through consultation. If negotiation fails, it shall be submitted to the people's court for ruling.
Article 9 Supplementary Provisions
This Agreement is made in quadruplicate (two for each party) and shall come into force after being signed and sealed by both parties. If there are any outstanding matters, both parties shall settle them through consultation. If no agreement can be reached, it shall be settled by the local arbitration department.
Entrusting party (Party A)
legal representative
XX, XX, 2008
Trustee (Party B)
legal representative
XX, XX, 2008
Article 6 of the transferor (Party A) of the Project Development Agreement: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Transferee (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A owns _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 1 Transfer of land use right and its project development right
(A) the status of land use rights
1. Location of the land: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. Land use area: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. The approved floor area ratio is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
4. Approved building area: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5. Land planning purposes: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
6. Land use years: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
7. Land status: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Land status
(ii) Status of the right to project development
1. Party A has received the approval letter for construction land, the planning permit for construction land and the planning permit for construction project;
2. With the approval of the municipal government, Party A has obtained the single development right on the land to be transferred and obtained the single development qualification certificate;
3. Party A has commissioned the design according to the planned use of the land, gone through the construction application procedures and paid the fees required for the construction application.
(iii) Status of other rights
1. Party A confirms that the land use right and project development right transferred by this agreement are legally owned by Party A, and there are no property rights defects such as mortgage, seizure and third party claiming rights;
2. Bear the creditor's rights and debts and all legal and economic responsibilities arising from the status quo of transfer payment. Party A confirms that all payables and expenses have been paid to obtain the land use right and project development right transferred by this agreement, and there is no dispute over creditor's rights and debts (including greening fees and compensation for demolition and resettlement, etc.). ).
Article 2 the transfer price of this agreement
1. Party A and Party B confirm that the transfer price of this agreement is based on the use area approved by Party A, and the transfer price is RMB _ _ _ _ _ _ _ _.
2. The above transfer price includes all the money and expenses paid and payable by Party A for obtaining the right to use the transferred land and the right to develop the project;
3. Party B is allowed to increase or decrease the construction area after the transferee, which has nothing to do with Party A and is not used as the basis for increasing or decreasing the transfer fee paid by Party B to Party A. ..
Article 3 Payment of Transfer Price
(1) Payment:
1. Within three working days from the effective date of this agreement, Party B shall pay _ _ _ _ _% of the transfer price of this agreement to Party A. ..
2. Party B shall pay _ _ _ _ _% of the transfer price of this agreement to Party A within three working days after Party A transfers the original data of land use right and project development right, including but not limited to land transfer contract, red line diagram, construction land approval, construction land planning permit, construction project planning permit, architectural design points, design drawings, single development right approval and qualification certificate;
3. Party B shall pay _ _ _ _ _ _% of the transfer price of this agreement to Party A within three working days after the planning and land department handles the land use right and project development right related to the transferred land in the name of Party B or its designee.
4. According to the needs of project development, Party B shall pay _ _ _% of the transfer price of this agreement to Party A within three working days after submitting the original planned office and shopping mall functions as commercial and residential functions.
5. Within thirty days after Party B is allowed to start construction, Party B shall pay the remaining transfer price of this agreement to Party A. ..
(II) The bank where Party A receives the transfer price of this Agreement is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(3) When Party A receives the payment from Party B, it shall issue an invoice to Party B or the unit or individual designated by Party B according to regulations.
Article 4 Delivery of materials and handling of land use right certificates
1. Within 10 working days after this contract comes into effect, Party A shall provide Party B with the original materials related to the land use right of the leased plot and the project development right, including but not limited to the land transfer contract, red line diagram, approval for construction land, planning permit for construction land, planning permit for construction project, architectural design points, design drawings, approval for individual development right, qualification certificate, etc.
If any party's contact information changes, it must notify the other party in writing within 3 working days after the change. Otherwise, letters and faxes sent through the above contact address, telephone number and fax will be deemed as delivered.
Article 14 Others
This agreement is made in quadruplicate, one for each party, and the other two are used to handle the formalities of change and transfer.
Party A (seal): _ _ _ _ _ _ _ _ _ Party B (seal): _ _ _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.