Party A: (hereinafter referred to as Party A) _ _ _ _ _ _ _ _ _ _ _ _
Party B: (hereinafter referred to as Party B) _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A employs Party B to decorate Party A's location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
The duration of the project is _ _ _ _ _ _ _ days, and the commencement date is _ _ _ _ _ _ _ _ _.
Contract Price: The project cost of this contract is (in words) _ _ _ _ _ _ _ _ _ _. (See attached table: budget table for details) Both parties shall abide by the following terms:
Article 1: Construction Preparation
1. Party B shall design and provide the decoration drawings in duplicate, one for Party A and one for Party B (see the decoration effect diagram for details).
2. Party A entrusts Party B to design the construction drawing in duplicate, one for Party A and one for Party B (see the decoration construction drawing for details).
Article 2: Obligations of Party B
1. During the construction period, Party B will hand over two keys of the outhouse to the contractor for safekeeping. After the project is completed and accepted, Party B is responsible for providing new locks, and both parties are responsible for site installation and delivery.
2. Party A shall provide water and electricity supply during the construction period.
3. Party A is responsible for coordinating the relationship between the construction team and the neighborhood.
3. Party B shall not dismantle the indoor load-bearing structure.
4. Party A shall have the right to participate in the supervision of project quality and construction progress, and supervise the material entry and completion acceptance.
Article 3: Decoration Items and Prices
1, water and electricity installation:
(1) Waterway: Party B is responsible for decorating and installing two bathrooms, kitchen, living room and gas pipeline. (transformation of hot and cold water)
(2) Circuit: including four bedrooms and two bathrooms, kitchen, living room, additional indoor switches, sockets and lamps specified by Party A..
(3) Heating: including installing four bedrooms, two bathrooms, kitchen and living room.
Price: The total cost of water, electricity and heating installation is RMB _ _ _ _ _ _ _ _.
2. Floor and wall tiles
(1) The living room, dining room, bathroom, kitchen, balcony, corridor and four rooms on the first floor have a unit price of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(2) Walls: two bathrooms, kitchens, bay windows of four rooms, kitchen and bathroom door and window covers, right-angle joints for pasting walls, etc. The unit price is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
(3) baseboard: dining room, living room, corridor, bedroom, etc. The unit price is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
(4) Others: When water and electricity pipeline joints and bottom boxes encountered in tiling need to be drilled and slotted, no cost will be incurred; (including labor, cement mortar, auxiliary materials, excluding main material bricks).
3. Bedroom bay window: sauna boards are used for the master bedroom balcony and the reception room balcony, and artificial stones are used for the study and children's room. * * * RMB _ _ _ _ _ _ (including labor cost, sauna board, artificial stone, pine board, styrofoam, pneumatic nail row, steel nail row, white latex Dulux paint (Hangang), installation cost and material cost).
4. Ceiling of the living room: * * * * RMB _ _ _ _ _ _ _ _; RMB: _ _ _ _ _ Yuan only (including labor costs, sand, stone, gypsum board, light steel keel and Taishan brand gypsum board).
5. Corridor to ceiling: * * RMB _ _ _ _ _ _ _; RMB: _ _ _ _ _ _ (including labor costs, sand, stone, gypsum board, light steel keel, Taishan brand gypsum board, and opposite-sex ecological board).
6. Balcony ceiling: sauna board, * * RMB _ _ _ _ _ _ _; RMB: _ _ _ _ _ _ _ Yuan only (including labor costs, sand, stone, gypsum board, light steel keel, Taishan brand gypsum board, and opposite-sex ecological board).
7. porch ceiling and dining room ceiling: * * * * RMB _ _ _ _ _ _ _ _; RMB: _ _ _ _ _ _ (including labor costs, sand, stone, Taishan brand gypsum board, and heterosexual ecological board).
8. Two bathroom ceilings and kitchen ceilings: * * yuan; RMB: _ _ _ _ _ _ Yuan only (including labor cost, aluminum gusset plate, Xintai Art and integrated ceiling).
9. Woodworking: desk+bookcase, * * * is RMB _ _ _ _ _ _ _ _; RMB: _ _ _ _ _ Yuan only (including labor costs, pine boards and eco-boards).
10, carpentry: shoe cabinet, _ _ _ _ _ yuan/m2, * * * is _ _ _ _ _ _ _ _ _ _ _ _; RMB: _ _ _ _ _ _ _ Yuan only (including labor costs, Olympic pine boards and eco-boards).
1 1. Woodworking: cabinets, hanging cabinets, storage cabinets, cabinets _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. RMB: _ _ _ _ _ _ _ (including labor costs, cabinets: Peng Hong eco-board, plastic door panels/color boards, countertops, stone materials, excluding wall tiles and floor tiles).
/
13, carpentry: wardrobe, * * * is RMB _ _ _ _ _ _ _; RMB: _ _ _ _ _ _ (including labor costs, Hongyuan/Xinjinqiu eco-board, painted/baked door panels).
14. Woodworking: wine cabinet, * * * is RMB _ _ _ _ _ _ _ _; RMB: _ _ _ _ _ _ (including labor costs, pine boards, ecological boards and wall paintings).
15, woodworking: OK, * * * is RMB _ _ _ _ _; RMB: _ _ _ _ _ Yuan only (including labor and timber).
15, living room pass: * * * RMB _ _ _ _ _ _ _; RMB: _ _ _ _ _ Yuan only (including labor cost, pine board and paint).
16, Chutong: * * yuan; RMB: _ _ _ _ _ Yuan only (including labor cost, pine board and paint).
Article 4: Tools and facilities
1. Party B shall prepare professional tools and personnel by itself. During the renovation, Party B's personnel shall abide by the residential property management, and shall not occupy Party A's house life and daily life, and pay attention to personal safety. If personal and property losses are caused by Party B's own faults or mistakes, Party B shall bear them.
2. Before renovation, Party B shall confirm the status of existing renovation facilities in advance; Before the materials are used, ensure that there are no quality problems in the materials, otherwise, Party B shall bear all responsibilities and be responsible for compensating the new defects and quality problems found in the acceptance process.
3. Party B must carry out decoration according to standard flow and procedure, and shall not cut corners, defile or destroy any facilities (including floors and walls) and surrounding environment in Party A's house. If irreparable damage is caused, Party B shall bear all expenses for compensation and repair.
Article 5: Method of Payment
1. After this contract comes into effect, Party A shall directly pay the project payment to Party B according to the following agreement:
Remarks:
(1) More than half of the project progress means that the ceiling in the house is completely completed.
(2) Other payment methods: _ _ _ _ _ _ _ _ _ _ _.
After the acceptance of the project, Party B shall propose the project settlement to Party A and send relevant materials to Party A. If Party A has no objection within _ _ _ _ _ days after receiving the materials, it shall be deemed as agreement, and both parties shall fill in the project settlement form.
Article 6: Liability for breach of contract
1. If either party fails to perform the contract or violates national laws, regulations and relevant policies, the responsible party shall bear the responsibility and compensate the other party for its economic losses in full.
2. If the performance of the contract cannot be continued due to one party's reasons, that party shall promptly notify the other party to handle the termination procedures of the contract, and the responsible party shall compensate the other party for all economic losses.
3. If the quality of the project fails to meet the quality standards agreed by both parties due to Party B, Party B shall be responsible for the repair and the construction period will not be postponed.
4. If the construction period is delayed due to Party B's reasons, Party B shall pay the other party _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 7: Settlement of Contract Disputes
Disputes arising from the performance of this contract shall be settled by both parties through consultation; Can also be mediated by the relevant departments; If negotiation or mediation fails, it shall be settled in the following second way:
(1) submitted to the Arbitration Commission of Erdos City, Inner Mongolia for arbitration.
(two) to bring a lawsuit to the people's court according to law.
Article 8: Modification and Termination of the Contract
1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.
2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.
Article 9: Entry into force of the contract
1. This contract and its annexes shall be sealed by both parties and come into force after being signed.
2. The supplementary contract has the same legal effect as this contract.
3. This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Contract and Materials renovation contract Template Second Customer (Party A) _ _ _ _ _ _ _ _ _ _ _
Organizer (Party B) _ _ _ _ _ _ _ _ _ _ _
Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.
Article 1: Project Overview
1. Project address: _ _ _ _ _ _ _ _.
2. Room specification: room type: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3. Construction content: See the annex to this contract for details.
(a) the home decoration construction content list and construction drawings.
4. Entrusting method: turnkey project of contracting and materials.
5. Commencement date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2: Project Price
Project price (amount in words _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _). ), see the annex to this contract for details.
(2) Budget table of home decoration engineering materials.
Article 3: Quality Requirements
1. The varieties, specifications and names of the main materials used in the project shall be approved by both parties.
2. The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.
3. During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.
4. All materials and equipment purchased by Party A shall be borne by Party A; Party B shall be responsible for the quality of the project.
Article 4: Supply of Materials
1. Party B shall clearly price the materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.
2. If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..
Article 5: Method of Payment
1. Once the contract is signed, Party A shall pay RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The remaining _ _ _% shall be settled by Party A after the project is completed and accepted. (Note: Construction costs include labor costs)
Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.
Article 6: Construction Period
1. If the completion is delayed due to Party B's reasons, Party A will be fined _ _ _% of the working expenses as liquidated damages every day until the working expenses are deducted. If the construction period is delayed due to Party A's reasons, Party B shall be paid _ _ _% of the labor cost of the decoration project price as the lost time fee for each day of delay.
2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.
3. During the construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.
Article 7: Other matters
1. Party A's responsibilities
1. The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided; otherwise, Party A shall provide the house plan and water, electricity and gas circuit diagram and make on-site disclosure to Party B. ..
2. The second decoration project, all or part of the empty house, remove obstacles that affect the construction. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..
2. Party B's responsibilities
1. Assign a staff member as the representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.
2, responsible for the safety of the construction site, beware of fire, show certificates, civilized construction, to prevent the construction caused by pipeline blockage, water leakage, power failure, damage and other accidents affect others. If it happens, it must be repaired or compensated as soon as possible.
Article 8: Liability for breach of contract
After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay _ _ _% of the total contract amount to the other party as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.
Article 9: Settlement of disputes
In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.
Article 10: Modification and Termination of the Contract
1. After this contract comes into effect after being signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, pay liquidated damages at% of the total contract price, and go through the termination procedures.
2. In the process of construction, if either party proposes to terminate the contract, it shall submit it to the other party in written form. After both parties agree to go through liquidation procedures and conclude an agreement to terminate the contract, the contract shall be deemed to be terminated.
Article 11: Entry into force of the contract
1. This contract shall come into effect after being sealed by both parties.
This contract is made in duplicate, one for each party.
Party A _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Renovation contract Template for Contracting and Materials: Party A (Owner): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Party B (contractor): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
1. Party B shall decorate the house for Party A. The area is _ _ _ _ _ square meters and the address is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. All materials of this renovation contract are provided by Party B, and can only be used after Party A's acceptance. If it does not meet the requirements of Party A, it must be stopped immediately and the materials must be replaced until Party A is satisfied.
2. The total renovation cost is RMB _ _ _ _ _ _ _ _ ten thousand Yuan, in words: _ _ _ _ _ _ _. After the project is completed and accepted, 99.5% of the remaining price shall be paid. Party A found no quality problems after using it for three months, and paid off 0.5% of the remaining amount. Party B must carry out the construction according to Party A's requirements to ensure the quality and quantity. If quality problems are found, all consequences shall be borne by Party B. ..
Three. This agreement is made in triplicate, one for each party and one for the witness. It will take effect after being signed by both parties.
Party A: _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Entrusting party for contracting renovation contract templates and materials (hereinafter referred to as Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Contractor (hereinafter referred to as Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, combined with the construction characteristics of decoration engineering, the two parties reached the following agreement on the principles of equality, mutual trust, mutual benefit, voluntariness and consultation:
1. Party A has signed a set of _ _ _ _ _ _ _ _ _ _ contracts.
2. Contracting method: contracting for work and materials. The materials are purchased by Party B according to the contract, and can only be used after being inspected by Party A before use.
Three. Contract contents: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Four. Construction period: from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If the project is not completed on schedule, RMB will be deducted every day. After the construction period exceeds _ _ _ _ _, Party B will compensate Party A according to _ _ _% of the total project cost every day.
Verb (abbreviation of verb) Total project cost: _ _ _ _ _ _ Yuan only (RMB: _ _ _ _ _ _).
Construction requirements of intransitive verbs: Party B shall carry out the construction according to the renderings. If Party A changes during the construction, Party B shall carry out the construction according to Party A's requirements.
7. Party B shall purchase materials according to the list of materials. If Party A designates purchasing materials, the part exceeding the budget will make up the difference. If materials are selected to reduce the budget price, Party B shall deduct it from Party A. ..
Eight. Obligations of Party A
One day before the commencement of construction, Party A shall create conditions for Party B to enter the site for construction (including clearing other sundries, if any, which shall be cleared by Party A), and shall not affect Party B's construction. Party A shall provide water and electricity for construction.
Nine. Obligations of Party B
During the construction, strictly implement the safety construction operation specifications, pay attention to fire prevention, construction specifications and quality standards, and complete the project on time with good quality and quantity. In case of accidents of construction personnel during the construction period, Party B shall bear all the responsibilities.
Ten, the project payment method
1. Since the signing of this contract, Party A has paid Party B _ _ _ _ _ _ _ yuan in advance.
2. For the second payment, Party A shall pay Party B _ _ _ _ _ _ _ _ _ yuan after the carpentry is completed and the paint enters the site.
3. After the project is completed and accepted, Party A shall pay 8,000 yuan in one lump sum within seven days without default.
X quality assurance: party b shall guarantee the decoration quality for one year, except for human reasons.
XI。 Solutions to contract disputes
Disputes arising from the performance of this contract shall be settled by both parties through consultation, and may also be mediated by relevant departments. If negotiation or mediation fails, a lawsuit shall be brought to the people's court according to law.
Thirteen. responsibility for breach of contract
Party A and Party B shall abide by the terms of the contract, and the liquidated damages shall be paid to the other party at 20% of the total cost, and other losses shall be calculated in real terms.
14. This contract is made in duplicate, one for each party, with the same legal effect from the date of signing.
Party A: _ _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _