Classic design contract format template 1
Project name:
Engineering number:
Date of signing the contract: year month day.
Entrusting unit: (official seal) Design unit: (official seal)
Legal representative:
Contact person: contact person:
Address: Address:
Tel: Tel:
Full name of unit: full name of unit:
Account number: Account number:
Bank of deposit: Bank of deposit:
Article 1 This contract is formulated in accordance with the relevant provisions of the Economic Contract Law of the People's Republic of China.
Article 1 Name of the entrusting party: (hereinafter referred to as Party A)
Name of Contractor: (hereinafter referred to as Party B)
Article 2 Design basis:
Article 3 Projects designed by Party A on behalf of Party B:
Design scale:
Charge standard:%
Investment:
Estimated design fee: Yuan (calculated according to the actual amount at the time of settlement).
Prepaid design fee: yuan
Article 4 Party A shall provide Party B with the basic data and technical requirements required by the design, and the final submission time shall start from the engineering design date.
Article 5 The charging standard of this project shall be implemented in accordance with the Charging Standard for Engineering Survey and Design revised by the State Planning Commission and the Ministry of Construction in 2002 (matters not covered shall be supplemented separately).
Article 6 After the contract comes into effect, if Party A fails to perform the contract, it has no right to demand the refund of the advance payment, and the amount of the designed works shall be settled in proportion to the total amount of works. When Party B fails to perform the contract, it shall refund the deposit.
After all the information is complete, the engineering design is completed. When Party B provides Party A with a complete set of design documents, Party A shall settle all design fees to Party B. ..
Article 7 The respective responsibilities of both parties are:
(1) Client
1。 Provide the contractor with relevant design data required for the design work, and be responsible for the reliability of the provided data.
2。 Designers shall be responsible for providing necessary working conditions when they go to the site for investigation, work or cooperate with construction.
3。 According to the relevant regulations of the state, the remittance procedures for prepaid design fees should be completed within five days after the arrival of the prepayment form.
4。 Maintain the integrity of the contractor's design and design results; Without authorization, it shall not be modified, copied or transferred to a third party for reuse.
(ii) Contractor
1。 According to the schedule and number of copies stipulated in the contract, submit the design documents and drawing sets that meet the design standards and technical specifications stipulated by the state.
2。 After the scheme design is reviewed by the superior competent department, the contractor is responsible for a small number of modifications within the scope of the original scheme, without additional charges and without signing an agreement. For major modifications and changes beyond the scope of the original plan, both parties shall agree on expenses separately.
3。 Responsible for the technical disclosure of design projects; Cooperate with the construction and solve the related design problems in the construction process.
Article 9 Except for irresistible factors of human resources, if a party violates the provisions of the contract and causes losses, it shall bear the liability for breach of contract according to law.
(3) Entrusting party
1。 Due to the change of construction plan, unclear information provided, failure to submit basic design data or working conditions on time and other reasons. , design rework, shutdown, slowdown or design modification shall pay extra fees according to the actual workload consumed by the contractor. The design progress and the increased payment amount shall be added to the original agreement for future reference after being determined by both parties through consultation.
2。 If it is necessary to stop the design midway, it shall notify the contractor in writing, and the fees paid to the contractor have no right to demand a refund. The required fees shall be paid according to the workload already carried out by the contractor and the losses caused by stopping the design midway.
3。 If the payment is made beyond the date stipulated in the contract, 0.5 ‰ of the payable amount shall be paid as overdue penalty every day. After the liquidated damages are paid to the contractor's bank account, they shall be settled through the contractor's charge notice, with the amount corresponding to the liquidated damages.
4。 The contractor shall submit the preliminary planning scheme, and the entrusting party shall put forward the modification opinions in time within ten days. If the scheme is determined after the deadline, the result will be formally obtained and submitted.
(4) the contractor
1。 If the design quality is poor, resulting in rework or failure to submit design documents and drawings on time, thus delaying the construction period and causing losses, both parties shall be responsible for continuing to improve and complete the design, and shall negotiate to reduce the amount of design fee according to the value of the lost part according to the size of the losses, and make up for it in the original agreement for future reference.
Article 10 This contract shall come into effect immediately from the date of signing, and it shall be automatically terminated after the settlement of engineering design.
Article 11 Once this contract is established according to law, it is legally binding. Both parties must fully perform their obligations under the contract, and neither party may change or terminate the contract without authorization. Matters not covered in this contract shall be settled by both parties through consultation in accordance with the national contract law.
Article 12 This contract is made in duplicate, with each party holding one copy.
One for Party A and one for Party B. ..
Classic design contract format template 2
Employer (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ _ Title: _ _ _ _ _ _ _
Design unit (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Legal Representative: _ _ _ _ _ _ _ Title: _ _ _ _ _ _ _
In order to clarify the responsibilities, divide the work and cooperate, and * * and * * complete the design tasks of the construction project, this contract is hereby signed by both parties through full consultation according to the planned tasks approved by _ _ _ _ _ _, for * * * to abide by jointly.
first
Party A entrusts Party B to undertake the design project of _ _ _ _ _ _ _ _ _.
Article 2 Obligations of Party A
1。 Party A shall: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A must guarantee the quality of the above materials and shall not change them at will.
2。 Timely handle the examination and approval of design documents in each design stage.
3。 Before the project starts, Party A shall organize relevant construction units, and Party B shall make design technical disclosure; After the project is completed, Party A shall notify Party B to participate in the completion acceptance.
4。 When the designers enter the construction site, Party A shall provide necessary working conditions and living convenience. In the process of design and construction, due to special technical needs, trial production tests shall be carried out, and the required expenses and travel expenses for cooperation with Party A in other places shall be borne by Party A. ..
5。 Party A must maintain Party B's design documents and shall not modify them without authorization. Without the consent of Party B, Party A shall not copy, reuse or expand the construction scope without authorization. Party A has the obligation to protect Party B's design copyright and shall not transfer it to a third party for reuse.
Article 3 Obligations of Party B
1。 Party B must deliver the preliminary design documents to Party A _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Deliver the construction drawing design documents to Party A before _ _ _ _ _ _ _ _ _ _ _ _. Among them, preliminary design documents, technical design documents and construction drawing design documents. If Party A needs to add extra copies of documents and models, it will be charged separately.
Before _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(For large-scale construction and installation projects, Party A and Party B can design by stages according to specific conditions. After the design conditions are met, both parties shall sign a stage design contract, specifying the name and date of the design materials that Party A should submit in each stage, and the date when Party B delivers the design documents, which shall be taken as an annex to this contract. See Annex (2) for details.
2。 Party B must put forward the survey technical requirements and design according to the approved design task book or the approval documents of the previous stage design, as well as the relevant design technical agreement documents, design standards, technical specifications, regulations and quotas, and submit the design documents that meet the quality.
3。 After the preliminary design is reviewed by the superior competent department, Party B is responsible for making necessary modifications within the scope of the original task book.
4。 The design unit shall cooperate with the construction project undertaking the design task, make technical disclosure before construction, solve relevant design problems during construction, be responsible for design change and budget revision, and participate in the acceptance of concealed works and the completion acceptance of the project.
Article 4 Modification and Termination of Design
1。 If Party A requests to modify the project design for any reason, with the consent of Party B, Party A shall rework and modify the working day according to Party B's actual situation. And pay an additional design fee of RMB _ _ _ _ _ _ _ _ _.
2。 If there are major changes in the original task book, and the design is redesigned or modified, the written opinions of the design examination and approval authority or the design task book examination and approval authority shall be required, and the two parties shall sign a new contract through consultation. The paid design fee shall be calculated according to the method specified in the preceding article.
3。 When Party A requests to stop the design midway for any reason, it shall notify Party B in writing in time, and the paid design fee will not be refunded, and the design fee will be increased and settled according to the actual number of days of employment at this stage, and the contract relationship will be terminated.
Article 5 Quantity and delivery method of design fees
Within _ _ _ _ _ days after the design contract comes into effect, Party A shall pay Party B a deposit equivalent to 20% of the design fee, which shall be used as the design fee after the design contract is performed. Party A shall pay Party B% of the design fee within _ _ days after Party B submits the preliminary design scheme to Party A; Within _ _ _ _ days after Party B submits the construction drawing documents to Party A, Party A shall pay all the design fees to Party B (for large-scale projects with long design cycle, the design fees at the construction drawing stage can be allocated separately after the design of individual projects is completed).
Article 6 Reward and Liability for Breach of Contract
1。 Within a reasonable project investment control number, if Party B adopts advanced technology or reasonable suggestions to save project investment, Party B will be rewarded with _ _ _% of the saved investment.
2。 Because Party A fails to provide relevant design data on time and accurately, which leads to Party B's failure to carry out design or cause design rework, Party B may postpone the delivery date of design documents, and Party A shall also calculate and pay an additional design fee of _ _ _ _ _ _ yuan per day according to the actual lost working days of Party B. ..
3。 If Party A fails to pay the deposit and design fee to Party B within the time stipulated in the contract, Party A shall pay liquidated damages to Party B according to the bank's regulations on deferred payment.
4。 If the delivery time of design documents is delayed due to Party B's reasons, Party B shall pay a penalty equivalent to _ _% of the design fee to Party A for every _ _ days of delay (which Party A may deduct from the design fee).
5。 If rework is caused by poor quality of Party B's design, Party B shall continue to improve the design task and reduce or exempt the design fee according to the losses and waste caused. For major quality accidents caused by Party B's design mistakes, Party B shall not only exempt the design fee for the lost part, but also pay compensation equivalent to the design fee for the direct loss part.
Article 7 Other agreements
_____________________________________________________________
This contract shall come into effect after being signed by both parties on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ The supplementary agreement has the same effect as this contract, but it shall not conflict with the contents of this contract.
In case of any dispute during the execution of this contract, both parties shall settle it through consultation in time. If negotiation fails, if both parties belong to the same department, mediation shall be conducted by the superior competent department; If mediation fails, you can choose: (1) apply to an arbitration institution for arbitration, and (2) bring a lawsuit directly to the people's court.
The original of this contract is in duplicate, one for each party; A copy of this contract exists in the form of _ _ _ _ _ _ _ _ _
Employer (Party A): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Design unit (Party B): _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Representative: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Classic design contract format template 3
According to the Economic Contract Law of the People's Republic of China and the relevant regulations of the decoration industry, this contract is signed by both parties through consultation, and both parties shall perform it jointly.
First project
Party A entrusts Party B to undertake the following engineering design tasks:
Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2 Design Fees and Payment Methods
(1) The design fee of this project shall be implemented according to the national and current market charging standards. Party A and Party B agree that the design fee is RMB per square meter (interior construction area), and the estimated total cost is RMB, with the amount in words.
(II) Mode of payment
Through negotiation, Party A and Party B adopt the following payment methods (the unselected methods are crossed out).
1, both parties will decide separately.
2. Proceed as follows.
(1) Home measurement, price: RMB.
(2) Deposit: RMB.
(3) Print out the plan, plan: copies, price: RMB/copy.
(4) Plane elevation and profile, price: RMB.
(5) Construction drawing of hydropower station, price: RMB.
(6) renderings, price: RMB/piece.
Article 3 Agreement on Design Content and Completion Date
(1) The design drawings provided by Party B shall have detailed design descriptions.
(2) Front plan view
(3) side.
(4) Hydropower construction drawings
(5) Party A and Party B agree to complete the plan within days from the effective date of this contract; Complete a full set of construction drawings within one day after the scheme is passed.
Article 4 Responsibilities of both parties
(I) Party A's responsibilities
1. Submit the data required for the design to Party B as scheduled, and ensure the quality of the submitted data meets the engineering design requirements.
2. Pay the down payment and engineering design fee to Party B according to the agreed date and quantity.
3. If the processing and ordering of the building materials and equipment of this project need the cooperation of Party B's designers, the required expenses shall be borne by Party A. ..
(II) Party B's responsibilities
1. Party A shall pay the design documents stipulated in this contract on time and ensure that the quality of the design documents meets the requirements of relevant national laws and regulations, as well as the construction and use requirements of Party A. ..
2. Be responsible for the design disclosure of the engineering design projects listed in this contract before commencement. Responsible for solving technical problems related to design in the process of project construction in time. Participate in the project completion acceptance as required.
Article 5 Liability for breach of contract
(1) If the design documents cannot be submitted within the time stipulated in this contract due to Party B's reasons, Party B shall compensate Party A for economic losses, with the compensation amount of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(II) When Party A suffers serious economic losses due to Party B's design mistakes, Party B has the responsibility to continue to take remedial measures in the design, and compensate part of the economic losses actually suffered by Party A as appropriate, and the total amount of compensation shall not exceed the total design fee of this part of the project.
(3) When Party A fails to perform the contract, Party B will not refund the deposit and pay the design fee according to the actual work done by Party B. When Party B fails to perform the contract, it shall double the deposit of Party A and return all the design fees except the received deposit.
Article 6 Entry into force, suspension and termination of contracts
(1) This contract shall come into effect after being signed by Party A and stamped with Party B's official seal. The effective date of the contract is the date when the last party of Party A and Party B signs (or seals). ..
(II) When Party A and Party B need to change or terminate this design contract for any reason, they shall notify each other in writing one week in advance, reach an agreement on matters not covered in this contract, and form a written agreement to be executed as an annex to this contract. This contract is still valid until an agreement is reached.
(3) If the design work needs to be stopped halfway due to Party A's reasons, the paid deposit will not be refunded.
(4) This contract shall be terminated as of the date when Party B provides Party A with all the engineering design documents stipulated in this contract, and Party A pays all the design fees according to this contract, unless otherwise agreed in this contract.
Article 7 Methods of settlement of contract disputes
In case of any dispute during the performance of this contract, if both parties cannot reach an agreement through negotiation, the following option shall be adopted for settlement:
1. Apply to the Consumer Council for mediation;
2. Apply for arbitration to the Economic Contract Arbitration Commission of the Administration for Industry and Commerce with jurisdiction;
3, to the people's court with jurisdiction;
4. Other solutions: _ _ _ _ _ _ _ _ _ _ _
Article 8 Contract Text
1 This contract shall come into effect after being signed (sealed) by both parties.
After the signing of this contract, the project shall not be subcontracted.
This contract is made in duplicate, one for each party.
4. The contract will be automatically terminated after the performance.
This contract is subject to the principle of voluntary authentication by the parties, and the contract text can be submitted to the local administration for industry and commerce for contract authentication to protect the legitimate rights and interests of both parties to the contract.
Party A: Party B:
Signature: signature:
Signing address: Signing address:
Date of signing: Date of signing:
Classic Design Contract Format Template 4
Party A: _ _ _ _ _ _ _ _ _ Decoration & Design Engineering Co., Ltd.
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Through equal consultation, Party A and Party B hereby conclude this agreement for mutual compliance.
1. Party A hereby entrusts Party B to undertake the design contract for the interior design of the office building of customer _ _ _ _ _ _ _ _ _ _ _ _ Group Co., Ltd. located in Zhuji City, Zhejiang Province.
2. Party B is willing to accept and undertake all the work of this design. During the cooperation of this contract, Party B shall not illegally steal, use or disclose Party A's business secrets, nor shall it provide convenience for the third party to illegally steal, use or disclose business secrets.
3. All responsibilities arising from Party B's design shall be directly borne by Party B. ..
Four. Detailed rules of design entrustment fee
1. Through friendly negotiation between both parties, Party A is willing to use _ _ _ _ _% of the total contract price as Party B's design fee (including the blueprint for land cover construction). Party B's design must meet the customer's confirmation, and the materials shall indicate the model, specification and quality grade of the materials used.
2. Party A and Party B shall jointly bear _ _ _ _ _ _ _ _ various expenses.
3. The taxes payable under this contract shall be borne by Party A. ..
Verb (abbreviation of verb) liability for breach of contract
Both parties must strictly abide by this agreement, and if there is any violation, they shall compensate the observant party for the corresponding losses.
Intransitive verb others
The entrusted matters of Party A and Party B are limited to this project. If there are other matters, an entrustment agreement shall be signed separately. Note that the annex to this contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of signature: _ _ _ _ _ _ _ _ _ _ _ _ _ _
Classic design contract format template 5
Party A:
Party B:
In accordance with the Building Law of People's Republic of China (PRC), the Economic Contract Law of the People's Republic of China and relevant national regulations, and in combination with the actual installation of this building, the following agreement is reached through consultation between both parties, and please * * * abide by it.
Article 1 General situation of construction and installation facilities
(1) Building name:
(2) Installation scope:
(3) Commencement date: year month day.
Completion date: year month day.
Article 2 This Agreement, together with the following documents, constitutes a contract document:
(1) * * Project benefit agreement agreed by both parties;
(2) Special contract terms;
(3) General contract terms in current national standard contract documents;
(4) Letter of acceptance;
(5) Letter of Tender and its attachments;
(6) Technical standards and requirements;
(7) drawings;
(8) The priced bill of quantities;
(9) Other contract documents.
The above documents complement each other and explain each other. If there is any ambiguity or inconsistency, the order agreed in the contract shall prevail.
Article 3 Quality:
Excellent, implement the latest national acceptance standards, and Party B shall bear all responsibilities and losses caused by the quality defects of the project.
Article 4 Materials and Equipment:
The variety, quality and model of main materials and equipment used in this project must be approved by Party A before Party B can purchase and use them; Without the consent of Party A, the main materials and equipment used by Party B, expenses and losses shall be borne by Party B..
Article 5 Settlement and adjustment of project price
1, this project adopts adjustable price contract, and the adjustment method is factual settlement.
2. The settlement of this project will implement the consumption quota and expense quota in 2003, and the specific agreement is as follows:
(1) Project category: The regulations of Shandong Province shall be implemented.
(2) Measures fee: settled according to the facts.
(3) Tax: Both parties agree that the business tax and surcharges collected by Party B shall be withheld and remitted by the constructor.
(4) Environmental protection expenses related to this project shall be implemented in accordance with relevant state regulations.
3. Both parties agree that Party B will pay 2% of the total project price to Party A for this project, and this amount will be adjusted when the project is completed and settled.
Article 6 Payment of project funds:
1. The project settlement agreement signed separately by both parties is an integral part of this clause.
2. Party A shall pay 30% of the total project cost after the acceptance of the main project and 70% of the total project price after the completion of the project; Party B shall submit the settlement report materials to Party A within one month after the completion and acceptance of the project, and the project cost consulting unit must conduct an audit and issue an audit report within one month; Party A shall not be responsible for the delay in the construction period caused by reasons other than Party A's. Party A shall pay 95% of the total project price within one year after the settlement is completed, and the remaining 5% shall be used as the quality warranty fund, which shall be paid in one lump sum within ten days after the expiration of the warranty period. If Party A fails to pay the project payment on schedule, it shall pay the arrears to Party B according to the loan interest of the bank for the same period.
3. If Party A fails to pay the project funds as agreed in the contract, both parties agree that the construction unit will pay Party B directly from the project funds payable by Party A.. ..
Article 7 guarantee
(1) Warranty content: See the scope of installation and construction;
(2) Warranty period: two years from the date of acceptance;
(three) after the expiration of the warranty period, according to the relevant provisions of the state signed a maintenance contract.
Article 8 Liability for breach of contract
(1) Party A's responsibilities:
1. No site, drawings, water and electricity are provided. According to the provisions of the contract, in addition to the extension of the construction period, Party B shall also be compensated for the actual losses caused by work stoppage and slowdown;
2. If the project is stopped or postponed midway, measures shall be taken to make up or reduce the losses, and at the same time compensate Party B for the losses and actual expenses caused by the stoppage, slowdown and transshipment;
3, the project without the acceptance of the competent department, use in advance, found that the quality problem, bear the responsibility;
4, more than the date stipulated in the contract acceptance or pay the contract price, according to the project cost of 0 every day. 3% shall pay Party B the overdue penalty.
(II) Party B's responsibilities:
1. If Party B fails to deliver the project or the quality does not conform to the contract, Party A has the right to request free repair or rework within a time limit. In case of late delivery, Party A shall pay 0.5% of the total project cost every day. 3% shall pay Party A the overdue penalty. ..
2. In case of quality problems during the warranty period, Party B shall repair them free of charge; If it is due to Party A, Party B shall be responsible for the maintenance and Party A shall bear the corresponding expenses.
Article 9 Matters not covered in this contract shall be determined by both parties through consultation.
Article 10 Dispute settlement methods:
Disputes arising from the performance of this contract shall be settled by both parties through consultation. If negotiation fails, both parties agree to apply to Rizhao Arbitration Commission for arbitration.
Article 11 This contract is made in quadruplicate, with each party holding two copies.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Classic design contract format template 5 related articles:
★ Five classic templates of renovation contract in 2022
★ 5 classic renovation contract excellent essays.
★ Five model articles on the format of 2022 classic cooperation agreement
★ Five general templates for classic service contracts
★ Five classic templates of cooperation agreement
★ Five excellent templates of classic service contracts
★ Five classic templates of company cooperation agreement
★ 3 classic construction contract templates
★ Classic planning and promotion service contract template
★ Five classic templates for excellent procurement contracts