Model agreement on intermediary service contract (6 selected articles) 1? Party A (client): ID number: Party B (trustee): ID number:
? In order to give full play to the advantages of both parties, Party A and Party B, in accordance with the Contract Law of People's Republic of China (PRC), reached the following agreement through full consultation on the principle of equality, voluntariness and equal compensation:
? I. Entrusting matters
? 1. Entrusted by Party A, Party B is responsible for introducing Party A to directly negotiate with the unit of earthwork project (hereinafter referred to as the project), providing Party A with important information of the project, and finally urging Party A to sign a construction contract with the unit.
? 2. "Intermediary success" means that Party A has signed a written project contracting contract with this unit.
? Two. Obligations of Party B
? 1. Party B must provide information about the project to Party A, and Party B has the obligation to assist Party A in the field investigation of the project.
? 2. Party B promises that the above information about this project provided to Party A is true and reliable.
? Three. Obligations of Party A
? 1. Party A is responsible for providing qualification certificates, business licenses and other relevant materials; Be responsible for the contract negotiation with this unit.
? 2. If the mediation is successful, Party A will fully perform the professional construction contract signed with this unit. Party A's rights and obligations arising from the performance of the construction contract have nothing to do with Party B. ..
? 3. If the intermediary is successful, Party A shall pay the intermediary remuneration to Party B as agreed in this contract. If the payment is not made in time, Party B shall bear the penalty of 1% of the daily unpaid intermediary remuneration.
? Four, the calculation method, payment time and payment method of intermediary remuneration.
? 1. The intermediary remuneration for this project is RMB two million only (￥ 2,000,000.00).
? 2. The agency fee shall be paid within days after Party A signs the project (professional contracting construction contract) with the unit recommended by Party B..
? 3. Party A can pay Party B by transfer or cash.
? V. Undertaking of intermediary fees
? Agency fee refers to the necessary expenses actually paid by Party B to complete the entrusted matters. When this contract is signed, Party A shall pay Party B RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
? Confidential matters of intransitive verbs
? 1. Both parties shall fully keep the business secrets involved in this agreement.
? 2. Both parties shall not use the business secrets obtained in the intermediary process to do anything that is unfavorable to the other party, otherwise, the other party has the right to demand the other party to bear the liability for breach of contract.
? Seven. Termination of contract
? 1. If Party B still fails to complete the mediation task within _ _ _ _ _ _ _ _ years after the signing of this contract.
? 2. If the mediation is successful, this contract will be terminated after full performance.
? Eight. Dispute resolution method
? In case of contract disputes, both parties shall settle them through consultation; If negotiation fails, both parties may apply to the arbitration commission in the place where the contract is signed for arbitration or request a court decision.
? Nine. any other business
? 1. Party B shall not delegate the matters entrusted in this contract.
? 2. This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed by both parties.
? Date of signing this contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ \
? Party B (seal):
Model Agreement on Intermediary Service Contract (6 selected articles) Part II? Party A:
? Party B:
? In order to give full play to the advantages of both parties, Party A and Party B have reached the following agreement through full consultation in accordance with the Contract Law of People's Republic of China (PRC) and the principles of equality, voluntariness and equal compensation.
? I. Entrusting matters
? Entrusted by Party A, Party B is responsible for introducing the earthwork to Party A, directly negotiating with the construction project party on the north side of Kema Expressway on the east side of Jin Quan Lake Reservoir, providing Party A with important information of the project, and finally urging Party A to sign the project contract with the project party.
? II. Obligations of Party B
? Party B must provide information about the project to Party A, and has the obligation to assist Party A in the field investigation of the project.
? Party B promises to provide Party A with true and reliable information about this project.
? Three. Obligations of Party A
? Party A is responsible for providing qualification certificates, business licenses and other relevant materials and negotiating contracts with the project party.
? If the mediation is successful, Party A will fully perform the professional construction unit contract signed with the project party, and the rights and obligations arising from Party A's performance of the construction contract have nothing to do with Party B. ..
? If the mediation is successful, Party A shall abide by this contract. Pay the agency fee to Party B. If it is not paid in time, Party B shall bear the penalty of 1% of the daily unpaid agency fee.
? 4. Intermediary fee and payment method
? The intermediate cost of this project is 2.75 million yuan (two million seven hundred and fifty thousand yuan).
? The agency fee shall be paid within _ _ _ days after Party A signs a formal contract with the project party.
? Party A can pay by transfer or cash.
? V. Termination of the contract
? If the intermediary is successful, the accommodation fee shall be paid, and the contract shall be terminated after the full performance.
? VI: Other matters
? This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed by both parties.
? Party A: Party B:
Model Agreement on Intermediary Service Contract (6 selected articles) Part III? Party A:
? Party B:
? Party A recommends Party B to build dormitories and teachers' apartments in Xingguo Middle School. After research, Party A's company decided to sign this irrevocable intermediary service fee agreement. According to the relevant provisions on intermediary services in Articles 23, 422 and 427 of People's Republic of China (PRC) Contract Law and People's Republic of China (PRC) State Responsibility Authorization Law, and referring to the international provisions of ICC500/600, Party A hereby issues an intermediary agreement to Mr. Wang. ..
? 1. Party A agrees that Mr. Wang will introduce the apartment building project of Xingguo Middle School students' dormitory for teachers, and agrees to pay the accommodation fee (RMB) as the intermediary service fee for the project.
? 2. After Party B successfully introduced the project, Party A has invested about 790,000 yuan in the total actual project number and total cost of the general contractor, and paid 6.5% of the intermediary service fee of 3.95 million yuan. In case of evasion or deliberate delay in payment, Party A is willing to pay 0.5% of the overdue fine for each day of delay until it is paid off, and bear the relevant expenses (including but not limited to attorney fees, legal fees and property fees) arising from breach of contract.
? 3. Party A guarantees that the payment agreement, relevant licensing materials and signature documents issued by it are true, legal and effective, and there is no fraud. If Party A fails to perform this agreement, Party A is willing to bear all legal and economic responsibilities, Party B may bring a lawsuit to the court according to this agreement, and Party A voluntarily waives all rights of defense and appeal.
? 4. The engineering service fee of 3.95 million yuan charged by Party B is pre-tax income, and Party A is responsible for the specific customs clearance procedures. In case of misappropriation, Party A will remit money or pay cash respectively according to the list and account provided by Party B..
? 5. The way for Party A to pay the room fee to Party B; When Party A and Party B signed the Intermediary Agreement, they paid RMB 3.35 million to the bank account designated by Party B, and the intermediation was successful. When Party A starts construction, Party A shall pay Party B an accommodation fee of RMB 600,000 only.
? 6. This Agreement is irrevocable and unchangeable. Party A shall not fail to fulfill its promise to Party B for any reason. No matter what the responsibilities of the signatory or Party A are, Party B (the intermediary) has nothing to do with it, and does not have to bear any economic and legal responsibilities.
? 7. As long as Party A undertakes the project, regardless of whether the project is completed or not, Party A shall pay the accommodation fee to Party B according to Articles 4 and 5.
? VIII. The above promises that Party A will pay all intermediary service fees to Party B, and this intermediary agreement will automatically terminate. If the intermediary is unsuccessful, this intermediary agreement will automatically terminate.
? Hereby promise;
? The legal representative of Party A; Legal Representative of Party B:
? Legal signature: legal person signature.
? Bank of deposit: Bank of deposit:
? Account number: Account number:
? Year, month, year, month, year
Model agreement on intermediary service contract (6 selected articles) 4? Client (Party A) and intermediary (Party B):
? Based on the principle of equality and mutual benefit, the entrusting party and the intermediary signed this contract for the greening project of the factory area of Xinjiang Bagang Nanjiang Iron and Steel Baicheng Co., Ltd. through friendly negotiation:
? I. Mode and scope of cooperation
? 1. Party A authorizes Party B Bai Lin to provide information services for Urumqi Ruiyi New Ecological Park Technology Development Co., Ltd.
? 2. When signing the project in the name of Party A, Party A shall pay the information service fee to Party B. ..
? Two. Rights and obligations of Party A:
? 1. Party A shall guarantee the quality, construction period, safety and other precautions of the project signed by Party B. 2. Party A shall provide support, guidance and supervision for the project signed by Party B, and keep Party B's business secrets.
? 3. Party A shall be responsible for compensating the direct economic losses caused to users by its own engineering quality and customer service.
? Three. Rights and obligations of Party B:
? 1. Party B is responsible for contacting and negotiating with customers before signing the project contract, and cooperating with Party A to provide after-sales service for customers after signing the contract.
? 2. Party B must sign a construction contract with the user in the name of Party A, and the construction contract will be established after being signed and sealed by Party A and is legally binding on Party A. ..
? 3. Party B shall actively publicize and popularize that Party A can undertake this project, safeguard Party A's interests, actively collect market information and feed it back to Party A in time.
? 5. Party B has the obligation to ask customers to pay Party A and urge them to pay the arrears according to the payment terms agreed in the project contract.
? 6. Party A's business secrets known to Party B during the conclusion of this contract shall not be disclosed or used improperly, regardless of whether this contract is established or not.
? Fourth, the settlement method
? 1. Once the project contract is signed, Party A is responsible for the project, and the project payment must be returned to Party A's account, and Party B is responsible for on-site contact.
? 2. All expenses incurred by Party B in signing this project shall be borne by Party B. ..
? 3. The information service fee shall be settled one by one. The final settlement price is 10% of the net profit of the total settlement price agreed by Party A and Party B under the plant greening project of Nanjiang Baicheng Iron and Steel Co., Ltd. of Xinjiang Bagang (the net profit of the total settlement price is10%; Less than 30 million yuan, according to 13% settlement).
? 4. After signing the contract with Xinjiang Bagang Nanjiang Iron and Steel Co., Ltd., Party A will pay Party B 150,000 yuan first, Party A will pay Party B 600,000 yuan after the project reaches 70 days, and the rest will be paid to Party B through negotiation according to Article 3.
? V. Settlement of disputes
? In the whole process of cooperation, Party A and Party B should solve the problem through friendly negotiation based on the principle of mutual respect and understanding. If negotiation fails, the case shall be submitted to Urumqi Arbitration Commission for arbitration.
? 6. This agreement shall come into effect after being authorized by both parties and stamped with the official seal of the unit, and the agreement shall be valid for one year. This agreement is made in duplicate, one for each party.
? Party A: Party B:
? Address: Address:
? Date of signature: year month day.
Chapter V of Model Agreement on Intermediary Service Contract (6 selected articles)? Party A:
? Party B:
? On the basis of initial contact between Party A and Party B, at the request of Party A's financing, Party B agrees to use its professional ability and market resources to help Party A's financing plan, with the amount of RMB _ _ _ _ _ _. Based on the principle of sincere cooperation and mutual benefit, both parties have reached the following agreement through full consultation:
? 1. Party A formally entrusts Party B as its financing intermediary. Make use of Party B's professional skills and market resources to write agency and implement financing plan for Party A;
? Two. Party B accepts Party A's entrustment and faithfully and dutifully implements Party A's financial plan. If Party A fails to connect with investors due to cooperation conditions, Party B will not be responsible for the unsuccessful financing.
? Third, the cost:
? Financing accommodation fee: _ _ _ _% of the financing amount determined by both parties through consultation.
? Four. mode of payment
? Party A shall pay the commission of the investor in cash on the day when the investor's funds arrive in Party A's account.
? V. Rights and obligations of both parties
? 1. Rights and obligations of Party A
? Rights: After the contract comes into effect, Party A has the right to supervise the content and progress of the scheme provided by Party B, have the right to ask Party B to strictly keep Party A's business secrets, and have the right to put forward opinions during the scheme design.
? Obligations: Party A shall cooperate with Party B's work, and shall be obliged to provide Party B with the information needed for the investor list in a true and comprehensive way according to Party B's requirements, and provide convenient conditions for Party B and investors to work, and pay the fees agreed by Party B in full and on time.
? 2. Rights and obligations of Party B
? Rights: After this contract comes into effect, Party B has the right to independently design the scheme, to obtain necessary information from Party A, and to collect fees according to the charging standards and payment methods agreed in this contract.
? Obligation: Party B has the obligation to design the scheme according to the quality and quantity required by the contract, and keep Party A's business secrets.
? For the settlement of matters not covered in this contract, both parties shall settle the matters not covered in this contract through friendly negotiation and sign a supplementary agreement in this regard.
? 7. This contract shall come into effect as of the date of signature by both parties, and it is made in duplicate, with the same effect. The supplementary agreement reached by both parties on matters not covered in this contract has the same effect as the main contract. The agreement held by Party A shall not be used as an attachment for commission payment, and shall be destroyed after being handed over to the investment inviting personnel at the termination of the rights and obligations of this agreement.
? Signature and seal of Party A:
? Signature and seal of Party B:
? Date of signing:
? Date of signing:
Model agreement on intermediary service contract (6 selected articles) 6? Party A:
? Party B:
? Whereas:
? 1. Due to insufficient funds and knowing that Party B can provide relevant financing information and assist Party A to complete the financing, Party A hereby entrusts Party B to find and introduce investors, and Party B also knows the above wishes of Party A. ..
? 2. Party A and Party B confirm that Party A agrees to entrust Party B to find and introduce investors, and Party B agrees to accept the entrustment, and the two parties sign a formal contract and strictly perform it to achieve the purpose of both parties.
? Based on the principles of voluntariness, equality, mutual benefit, honesty and credibility, both parties have reached the following contract terms through full friendly negotiation for their compliance and performance.
? Article 1: Entrusting matters
? 1. Party A entrusts Party B to find and introduce investors, and Party B accepts the entrustment of Party A. ..
? 2. Party B seeks or introduces the investor for Party A, and the investor signs a financing contract with Party A by legal means such as borrowing or investing, and the investor actually pays the financing amount agreed in Party A's contract. The amount of financing entrusted by Party A to Party B is RMB (in words).
? Article 2: Rights and obligations of intermediaries
? 1. Entrusted by Party A in the name of the company. When Party B accepts the entrustment, Party A shall present the business license and other legal qualification certificates. Party A entrusts in the name of an individual, and when Party B accepts the entrustment, Party A shall show his identity certificate and qualification certificate.
? 2. During the performance of this contract, Party B may indicate to the third party that it is the intermediary of Party A, and may introduce the financing situation of Party A to the third party.
? 3. Party B shall earnestly complete the matters entrusted by Party A, that is, seek opportunities for Party A according to the contents stipulated in Article 1 of this contract, and provide services such as liaison and matchmaking for Party A to sign contracts or agreements with relevant parties.
? 4. Party B shall not undertake any guarantee liability or other joint liability for the funds raised by Party A. ..
? 5. Completion standard of intermediary work: the investors sought and introduced by Party B sign a financing contract with Party A and actually pay the financing amount agreed in the contract to Party A. ..
? 6. Party A shall pay corresponding intermediary remuneration to Party B according to this agreement.
? Article 3: Intermediary remuneration, fees and payment methods
? 1. If Party B completes the obligations specified in Paragraph 5 of Article 2 of this Contract, Party A shall pay 50% of the financing amount to Party B as intermediary remuneration, and the relevant taxes and fees of the intermediary remuneration shall be borne by Party A, and the expenses incurred by Party B in the intermediary process shall be borne by Party B.. Party A shall pay the intermediary remuneration on the day when the funds are available. If Party A fails to pay the intermediary remuneration on time, it shall pay Party B a penalty of 0.2 ‰ of the unpaid amount for each day overdue from the date of payment.
? 2. If Party B's intermediary work fails to meet the intermediary work completion standard agreed in Paragraph 5 of Article 2 of this contract, Party B has no right to ask Party A to pay the intermediary remuneration, nor has it the right to ask Party A to pay any expenses incurred by Party B during the intermediary process.
? Article 4: Liability for breach of contract:
? Party A (legal representative) voluntarily provides Party B with joint and several liability guarantee with all assets under its name, so as to ensure Party A to fulfill its payment obligations under this contract.
? Article 5: Confidentiality
? Party A and Party B promise to keep confidential the documents and materials that belong to the other party and cannot be obtained from public channels during the discussion, signing and implementation of this Agreement. Without the written consent of the original provider of materials and documents, the other party shall not disclose all or part of the trade secrets to any third party, unless otherwise stipulated by laws and regulations or agreed by both parties.
? Article 6: Validity, Dissolution and Jurisdiction of Contracts
? 1. This contract shall come into effect after being signed or sealed by both parties;
? 2. Party A and Party B terminate this contract through a written agreement;
? This contract is valid for one year.
? 4. In case of any dispute arising from the performance of this contract, both parties shall negotiate amicably. If negotiation fails, a lawsuit shall be brought to the people's court with jurisdiction where Party A is located.
? Article 7: Both parties promise that
? 1. Party B shall provide Party A with honest, professional and efficient quality services;
? 2. Party A shall be responsible for all the information provided and guarantee its authenticity, integrity and legality;
? 3. Party A shall not ask Party B to do anything that violates national and industrial laws and regulations.
? Article 8: Special Agreement
? After the signing of this contract, once Party B facilitates the direct communication and exchange between Party A and the capital lender or investor, or the capital lender (or investor) has accepted Party A's financing application materials, it is deemed that Party B's assistance work has actually started, and Party B has no right to receive intermediary remuneration from now on until Party A obtains the actual financing. However, within one year after the signing of this contract, if Party A obtains financing from institutions in the same city, such as fund lenders (or investors), in the system where Party B has assisted Party A to actually carry out the work, and reaches the standard of Paragraph 5 of Article 2 of this contract, it shall be deemed that Party B has completed the entrusted and intermediary tasks of Party A, and Party A shall pay the intermediary remuneration to Party B according to this contract.
? This contract is made in duplicate, one for each party, with the same legal effect.
? Party A:
? Legal representative:
? Or entrusted agent:
? date month year
? Party B:
? Legal representative:
? Or entrusted agent:
? date month year
? Signing place: