Model factory contract agreement (I) Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
With the consent of all the partners of Party A, through fair, just and friendly negotiation, Party A and Party B contract out all the right to use and operate the fixed assets of _ _ _ _ to Party B, and the two parties reach the following agreement:
I. Contents of the Contract
Party A shall contract out the right to use _ _ _ _ _ _ _ _ _ _ fixed assets to Party B from the date of signing the contract, and Party B shall be responsible for its own profits and losses, and Party A has no right to interfere.
Second, the contract period
The term of the contract is _ _ _ _ _ _ _ _ _ years.
III. Contract Amount and Payment Method
1. Contract amount: Party B shall pay the contract amount of RMB to Party A every year. Party B shall pay a contract deposit of RMB to Party A..
2. Payment method: Party B shall pay the contract money _ _ days before each quarter. Party B fails to pay the contract money on time. If Party B fails to pay on time for one day, Party A has the right to increase the overdue fine of _ _% of the amount owed to Party B. If it exceeds _ _ months, Party A has the right to stop the normal production of Party B. ..
Four. Responsibility of both parties
1. During the contract period, Party B shall be responsible for managing Party A's property, maintaining and repairing it in time, and shall not transfer or sell it, nor mortgage _ _ _ _ _ _ _. If there is such behavior, Party A has the right to stop it, and the consequences arising therefrom shall be borne by Party A. ..
2. After the expiration of the contract, Party B shall ensure that Party A's original equipment can operate normally.
3. If Party A's old machine is aging, Party B can replace it at its own expense.
4. Party A allows Party B the right to purchase new production equipment and expand productivity during the contract period. At the end of the contract period, Party B shall dispose of the equipment purchased by Party B by itself, and shall not offset the contract price at a discount.
5. Party B shall be responsible for all kinds of production-related taxes and fees collected by relevant departments during the contract period.
6. The _ _ _ _ _ _ _ _ formalities are not completed or other taxes and fees that are not within the scope of production imposed by the relevant departments shall be settled by both parties through consultation.
7. In case of major events during the contract period, Party A shall come forward to mediate.
8. During the contract period, all creditor's rights and debts shall be enjoyed and borne by Party B, which has nothing to do with Party A. During the contract period, Party B shall strengthen the management of production safety and eliminate potential safety hazards in time. Party B shall take full responsibility for safety accidents, and Party A shall not bear any economic and legal responsibilities, but Party A shall cooperate.
9. During the contract period, if the relevant departments require _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ ).) Its investment is contributed by Party A, and the increased property belongs to Party A. The investment amount is increased by Party B's contracted fund for _ _ _ _ years, and the increased asset management right belongs to Party B. If Party B cannot produce during the rectification period, the contracted fund will decrease in proportion to time.
Verb (short for verb) others
1. In case of national policy adjustment, forced relocation of the government to the industrial park, or natural disasters caused by force majeure, the contract can be terminated through negotiation by the partners.
2. Liability for breach of contract: Party A and Party B shall strictly abide by the contract, and Party B shall contract the operation, and Party A shall not interfere. If the normal production and operation of Party B is affected due to Party A's reasons, Party A shall pay liquidated damages to Party B at _ _ _% of the annual contract payment, and if Party B breaches the contract, it shall pay liquidated damages to Party A at _ _ _ _% of the annual contract payment.
3. Matters not covered in this contract shall be negotiated separately by both parties.
4. This contract shall come into effect immediately after being signed and sealed by the representatives of Party A and Party B and all the partners of Party A, with each party holding _ _ _ _.
Party A: (Seal) _ _ _ _ _ _ _ _ _ _ _ _
Party B: (Seal) _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Date of Signing: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Model factory contract agreement (II) Employer: _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Contractor: _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)
This Contract is concluded in accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness, honesty and credibility.
Article 1: Project Name: _ _ _ _ _ _ _ _ _ _ _ _
Article 2: Project Location: _ _ _ _ _ _ _ _ _ _ _ _
Article 3: Contract scope: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 4: Project Cost: _ _ _ _ _ _ _ _ _ _ _ _
1, the unit price of this project is _ _ _ _ _. Project construction area: _ _ _ square meters.
Total RMB: _ _ _ _ _.
Article 5: Contract method: _ _ _ _ _ _ _ _ _ _ _.
Article 6: The construction period is _ _ _ _ days. In case of force majeure natural disasters during the construction period, the construction period will be postponed through negotiation.
Article 7: Method of payment:
Pay RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Pay _ _ _ _ _ _ _ yuan after acceptance, and the balance shall be paid within _ _ _ _ _ _ years.
Article 8: Main responsibilities of both parties
1, Party A:
1) to provide construction drawings and guarantee payment on schedule.
2) Before Party B enters the site, the construction site must be "three links and one leveling", that is, water, electricity and roads are connected and the site is leveled. Party A is responsible for leading the power supply to the installation site.
3) Send representatives to the site to supervise the progress and quality of the project, go through the intermediate completion acceptance procedures, be responsible for the visa for the change of project quantity, and solve other problems that should be solved by Party A. ..
2. Party B:
1) Prepare the construction organization design;
2) Purchasing materials and equipment and arranging production in time;
3) Party B's on-site project manager is responsible for the on-site construction;
Article 9: The design unit or Party A shall issue a notice of engineering change and notify Party B in time. The project cost adjusted due to design changes shall be settled by both parties through consultation.
Article 10: Project Quality
1, engineering quality and acceptance standards shall be implemented in accordance with the Code for Construction and Acceptance of Steel Structure Engineering.
2. Party A shall supplement to Party B that after the project is submitted for acceptance, it shall organize acceptance within _ _ _ days, sign the acceptance certificate and hand over the project to Party A for management. If Party A exceeds the acceptance period or the project has been put into use, it will be deemed as qualified.
Article 11: Safe production: Party B strictly abides by the safety operation rules and strengthens the on-site safety management. If an accident occurs during the construction, Party B shall be responsible for it, which has nothing to do with Party A;
Article 12: Liability for breach of contract: In case of any dispute, both parties shall settle it through consultation; If negotiation fails, it shall be decided by the court where the plaintiff is located.
Article 13: For other matters not covered, both parties shall negotiate separately, and the supplementary agreement shall have the same legal effect as this contract.
Article 14: The original of this contract is _ _ _ _ _ _, and each party holds _ _ _ _. After the contract is fulfilled, it will automatically become invalid.
Article 15: The comprehensive date of this contract is _ _ _ _ _ _ _ _ _ _.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Model factory contract agreement (III) Party A: _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _
After careful negotiation by both parties, Party A agrees to contract the paint workshop to Party B, and the specific terms are as follows.
1. The term of this contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Second, the way of contracting, contracting, that is, the composition of carpentry workshop personnel, the management of labor remuneration distribution, the use and maintenance of various equipment.
Third, the settlement method of the contract fee, the labor fee is _ _ _ months, and it is settled at the end of each month.
Four, the piece price of products:
1, flat door _ _ _ yuan per set,
2. The price of each set of European doors is RMB _ _ _ _ _,
5. The products produced by Party B must meet the standards specified by Party A, and the specific quality standards are as follows:
1, the style is made according to the drawings and processing technology.
2. The dimensions shall be processed according to the production bill, and the wooden door shall be smooth, square, free from warping and plastic deformation. Meet the tolerance requirements (national standards).
3, set of silk interface must be smooth, set of silk bending tolerance allowed _ _ _ _ mm. ..
4, wooden door surface without glue, smooth, modelling door interface must be smooth and seamless.
5. The surface of the whole door is free of scratches, bumps and other injuries.
6. Before handing over to the next level, the whole door should be polished and leveled, and the door leaf must be nailed with corner protectors and punched.
Responsibilities and obligations of both sides of intransitive verbs
1. Party A shall provide relatively complete production workshops and production equipment according to production needs.
2. According to the contract, Party A guarantees to pay the labor service fee to Party B on time.
3. If the task is insufficient, Party A promises to bear the guaranteed salary of _ _ _ _ yuan per person per month.
4. Party A must seriously consider the requirements put forward by Party B according to the needs of production and employees' life, and try its best to solve them reasonably under the principle of mutual understanding, mutual accommodation and humanization when Party A's conditions permit, but there must be no strikes or slowdowns to realize the requirements.
5. According to the production task of Party A, Party B is equipped with corresponding technical force, and guarantees to complete the task on time with good quality and quantity.
6. Party B should be concerned about the physical health and mental health of employees, and should not just focus on catching up with tasks, regardless of the physical limits of employees, and it is not allowed to beat and scold. Once found, Party A has the right to deal with it seriously.
7. Party B shall be equipped with documents and quality inspectors in the production process to ensure the tracking and supervision of the quantity and quality of the whole production process and production cycle.
8. Strictly control the handover of workpieces, carefully check the quantity, quality and style, establish and improve the handover procedures, and the supervisors of both parties shall perform the signing and approval procedures to prevent unqualified workpieces from being mixed in.
9. In addition to earnestly completing the tasks and time specified in the task list issued by Party A, Party B shall do its best to arrange and complete some particularly urgent matters at the first time (such as the sample of the project list, the color swatch, the repair of a workpiece in the customer list, etc.) to ensure the reputation of the factory.
10. In the production process, Party B should pay special attention to safety issues. For the equipment that employees don't understand, we should seriously ensure that it can be used after teaching, otherwise it will lead to production accidents and personal accidents. Party B shall bear all responsibilities. Before work, the mechanical equipment used shall be strictly checked in good condition. If maintenance is needed, Party A shall be informed in advance, so as not to affect production. It is absolutely not allowed to use mechanical equipment with diseases, so as not to cause greater losses.
1 1. Party B shall lead employees in civilized production, and shall not smoke, spit, litter or peel in the workshop. After work every day, Party B shall clean the workshop, cut off the power supply, close the doors and windows and check the equipment.
12. Party B shall lead the employees in this workshop, abide by the factory rules and regulations, attend the meetings in the factory and the meetings of various departments, and do a good job of unity and coordination among employees.
13, take good care of the public property in the factory, prohibit the brutal use of equipment, rationally use all kinds of important equipment in the contracted workshop, and do a good job in daily inspection and maintenance.
14. If the products produced by Party B are packaged or the quality inspectors of customers find them unqualified, Party A will punish Party B, and Party B will bear all expenses arising from quality problems.
15. If there are no special circumstances (such as power failure and mechanical equipment failure), Party B will be fined 5% of the total order amount for each delay.
16. If Party B stops production before the expiration of the contract, Party A will not pay all the expenses incurred in Party B's early production.
17. Party A can fully assist in solving the accidental personal accidents caused by workers leaving the factory and provide assistance within its capacity, but Party A will not bear all the expenses arising therefrom.
18. If the products produced by Party B have quality problems, Party B shall bear the responsibilities and losses.
Seven. This contract is made in duplicate, with each party holding one copy.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Model factory contract agreement (IV) Party A (employer): _ _ _ _ _ _ _
Party B (contractor): _ _ _ _ _ _
In order to better manage the cutting group in the production mold workshop, improve production efficiency and improve the utilization rate of plates. Through consultation between Party A and Party B, it is decided that Party B will contract the operation of the cutting team. In order to clarify the rights and obligations of both parties, this contract is hereby concluded:
First, the contracting method.
Party A contracts the cutting group of the production mold workshop it owns to Party B to process it for Party A. During the contract period, Party A will provide the site, equipment and production line; All expenses, including raw materials, equipment, consumables, auxiliary materials, water, electricity, equipment maintenance fees, etc., shall be paid by Party A, and Party B shall only bear the labor wages. Production workshop contract.
Second, the contract period
The term of this contract is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Third, the price of the contracted products.
Cut the board in _ _ _ _ _ every month, and the reserve price is _ _ _ _ _ yuan. If it exceeds the square number, it shall be paid at _ _ _ _ yuan per square meter.
Four. Party A's power
1. Party A has the right to carry out various administrative management on Party B's hygiene and safety. Smoking is prohibited in the mold workshop to avoid fire. In case of an accident, Party B will compensate all losses.
2. Party A has the right to supervise Party B's production environment and labor protection. If Party B is found to be in violation of regulations, Party A has the right to terminate the contract or give economic sanctions.
3. Party A gives Party B the production task every day, and Party B shall complete the production task with good quality and quantity on time according to Party A's requirements. Party A has the right to impose economic penalties on Party B for delayed delivery, and deduct _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Verb (abbreviation of verb) Party B's responsibility
1. In production and operation, Party B must obey the management of Party A, complete the production tasks assigned by Party A on time, and carry out production according to Party A's various rules and regulations. ..
2. Party B is responsible for regularly maintaining the equipment and facilities provided by Party A, and should report the abnormal situation of the equipment as soon as possible. Party B shall be responsible for the equipment damage caused by Party B's operational mistakes.
3. Party B must provide Party A with daily production report data, and Party A's accounting department will calculate the processing fee according to Party B's output. Without permission, Party B shall not undertake the supply from other units. Once found, Party B will be fined _ _ _ _ yuan each time.
4. The personal safety of all personnel of Party B's cutting team shall be the responsibility of Party B, and Party A shall not bear any responsibility.
5. During the contract period, Party B shall not subcontract the mold workshop to others.
Settlement and payment methods of intransitive verbs
1. Settlement method: Party B shall submit the production report of the current month to Party A's accounting department, which shall submit it to Party A's finance department after review. ..
2. Payment time: the handling fee of the current month will be paid to Party B's card on _ _ _ _ _ _ _ _ (for example, the handling fee will be paid on _ _ _ _ _ _ _ _), and it will be postponed in case of _ _ _ _.
3. Cooperation security deposit: when the processing fee is paid, _ _ _% of the processing fee of the current month shall be deducted as the cooperation security deposit, which shall be paid once every _ _ _ _ years.
Other matters of intransitive verbs
1. After this contract is signed by both parties, it will not be affected by any factors such as market conditions. During the contract period, if either party terminates the contract without authorization (including Party B's withdrawal), it shall be treated as breach of contract.
2. Upon the expiration of the contract, both parties shall notify each other _ _ _ months in advance, whether to renew or terminate the contract.
3. In case of contract dispute, both parties shall bring a lawsuit at the location of Party A's factory, namely _ _ _ _.
4. Matters not covered shall be settled by both parties through negotiation.
5. This contract shall take effect on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A (seal): _ _ _ _ _ _ _ Co., Ltd.
Representative of Party A (signature): _ _ _ _ _ _ _ _ _ _ _
Party B (signature): _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _