Now many citizens' awareness of rights protection is increasing, and we use contracts more and more. Signing a contract can clarify the rights and obligations of both parties. So what should we pay attention to when concluding a contract? The following is a sample contract for formal contract settlement for your reference, hoping to help friends in need.
Formal Contract 1 General Contractor: (hereinafter referred to as Party A)
Liquidator: (hereinafter referred to as Party B) In the spirit of friendly cooperation, Party A and Party B signed the following contract in accordance with the Contract Law and other relevant laws.
I. Overview of the Project
1, project name:
2. Project location:
3. Project content:
4. Project:
Second, quantity and price.
1, quantity: m2;
2. Unit price: RMB/m2;
3. Labor cost: RMB.
Three. terms of payment
1. After the personnel enter the site, Party A shall pay Party B ten thousand yuan;
2. After the installation is completed, Party A shall pay Party B ten thousand yuan;
4. After the acceptance, Party A shall pay 95% of the total contract price to Party B;
5. Leave 5% quality deposit. If there is no quality problem after one year, Party A will pay the balance to Party B in one lump sum.
Fourth, design.
1. Party A shall provide Party B with a set of drawings and construction scheme, and be responsible for disclosure;
2. If Party A has no drawings, it shall clearly explain the requirements to Party B, and Party B shall draw a sketch for Party A's approval before construction.
Verb (abbreviation of verb) material
1. Party B is responsible for providing Party A with the list of materials to be purchased, and Party A shall timely purchase materials for the use of the construction team. ;
2. Without the consent of Party A, Party B shall not purchase materials by itself;
3. Party B shall inspect and accept the quality of the building materials purchased by Party A, and raise quality problems with Party A in time, and have the right to refuse to use them;
4. Party B shall assist Party A to receive the goods and check the accuracy of the quantity and accessories;
5. Party B shall properly keep the materials and prohibit other personnel from entering the site;
6. Without Party A's permission, Party B shall not lose or damage the information. If any loss or damage is found, it shall be deducted from the labor cost according to the material price.
Sixth, the construction period
1, commencement date MM DD YY, completion date mm DD YY; The construction period is tentatively set as sunny.
2. If the construction period is delayed due to Party A's factors, Party A may deduct Party B's related labor costs.
Seven. Party B's responsibilities
1. Party B shall carry out the construction in strict accordance with the drawings and contracts provided or reviewed by Party A to complete the steel structure construction task;
2. Party B shall bring its own tools needed for construction, and ensure the safety and good usability of the tools, and Party B shall undertake the maintenance of the tools by itself;
3. Party B shall complete the project within the time limit stipulated in the contract, and deduct 500 yuan for each day of delay;
4. In case of force majeure factors such as gale, rainstorm and power failure, the construction period will be postponed;
5. During the construction period, Party B's personnel shall pay attention to the safe construction, and Party B shall bear all responsibilities for all personal injuries and deaths during the construction period;
6. Without the consent of Party A, Party B shall not stop work or stop work under any circumstances;
7. The construction unit is responsible for clearing the construction waste to the designated place in time. After the construction, the construction personnel are responsible for clearing the construction waste on the site before leaving the site.
8, the construction unit must ensure the construction quality, construction quality problems, the construction unit should promptly correct.
Eight. maintain
1. Party B shall repair the quality problems caused by Party B's construction for free within two years;
2. For general maintenance, Party B shall carry out timely maintenance within three days after Party A notifies Party B, and in special cases (water leakage), Party B must arrive and carry out maintenance within 24 hours;
3. If Party B fails to complete the maintenance in time as stipulated in the contract, Party A may arrange other construction teams to carry out the maintenance work, and deduct the labor cost from the warranty fund.
Nine. dispute over a contract
1. In case of any dispute, Party A and Party B shall settle it through negotiation first. If negotiation fails, they can bring a lawsuit to the court where the dispute is located.
2. This contract is made in duplicate, with each party holding one copy.
Party a: xxx co., ltd. party b:
Address: xxx address:
Representative: representative:
Mobile phone number: mobile phone number:
20xx year x month x day
Regular settlement of labor contract 2 Party A:
Party B:
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law and relevant administrative regulations, following the principles of fairness, voluntariness, equality and mutual benefit, and giving full play to their respective advantages, this agreement is hereby signed by both parties on the responsibility contracting of cleaning personnel for finished product warehouses, machine repair workshops, sporadic engineering pools and water pump houses in Ningxia Sun Magnesium Industry.
I. Name of the contract
Formwork production, installation, support and erection of finished product warehouse, machine repair workshop, sporadic project pool and water pump room in Ningxia Sun Magnesium Industry.
Second, the scope of contracting:
All formwork works within the scope of construction drawing. From foundation cushion to main body capping, cast-in-place and prefabricated formwork fabrication and installation, all kinds of mechanical foundation formwork fabrication and installation, pre-embedded parts reservation, formwork erection and dismantling, raw material handling, vertical transportation, collection and cleaning, nail dismantling and oiling, all kinds of work related to woodworking work are piled up at the designated place.
Third, the contract unit price:
Both parties agree that according to the construction drawings of this project, the contract price of woodworking shift cleaning contractor is 50 yuan per square meter; (This fee includes the safety guarantee fee of 2 yuan per square meter for the expanded surface of the construction drawing design, the progress measure fee of 2 yuan per square meter for the expanded surface of the construction drawing design, and the 2 yuan per square meter for the expanded surface of the construction drawing design in civilized construction measures. If Party B violates the above three provisions, Party A has the right to deduct the violation fee, and Party B will unconditionally obey).
Fourth, the settlement method:
Both parties agree to calculate the expansion area of the installation template required for designing concrete members according to the construction drawings multiplied by the unit price stipulated in the contract.
Verb (abbreviation of verb) construction cycle:
Party B shall strictly implement the project construction plan prepared by Party A's project department, actively cooperate with and obey the guidance and supervision of project department managers, owners and supervision leaders, and coordinate the safety, quality and progress of various types of work. According to the schedule and special circumstances, timely deployment of labor, strengthen management measures and efforts. The overall, monthly and weekly completion plan of the project formulated by the project department must be unconditionally implemented. In case of violation of the provisions listed in this article of this contract, Party A will deduct the cost of progress measures specified in Article 3 of this contract, and Party B shall unconditionally obey it.
Six, quality requirements:
During the construction period, Party B shall be familiar with the changes in the construction drawings and joint review, report them correctly according to the actual needs, plan the materials, carry out the construction in strict accordance with the requirements of the acceptance specification of formwork engineering, and do a good job in technical disclosure and technical review of joints in technical operation to prevent the occurrence of formwork explosion due to axis deviation, displacement, offset, insufficient section, deformation and weak support.
Seven. Machinery and tools provided by both parties:
1. All tools related to woodworking work shall be purchased and distributed by Party A. ..
2. Party B shall undertake the custody obligation. In case of loss, Party B shall compensate the price.
Eight, civilized construction:
During the construction period, Party B shall actively cooperate with the guidance and supervision of the project management department according to the specific requirements of the project management department. According to the requirements of the builder of the project department, the materials shall be classified according to varieties and specifications, packed neatly in order, and shall not be piled up, sawed or used indiscriminately. Materials should be used in a stereotyped way, and miscellaneous materials should be used in a timely and reasonable manner. Used materials must be pulled out and oiled, and then sorted, stacked or used. Arrange personnel to collect and sort out scattered materials and put them into use in time. If it is found that raw materials are used in a planned way, 200 yuan will be fined for sawing each board indiscriminately, with the title of 50 yuan/Root.
Nine, security management requirements:
During the construction period, Party B shall earnestly implement the policy of safety first and prevention first, strictly prohibit illegal operation and illegal command, operate in strict accordance with the requirements of relevant national safety laws and regulations, organize and train employees' safety production education and management in time, report to the project department for rectification in time when potential safety hazards are found, and actively cooperate with the project department to sign safety production responsibility letters with workers in various shifts. And must abide by the following construction site safety management system formulated by the project department: ① Gambling and fighting are strictly prohibited in the construction site area. Once found, all parties will be fined 500 yuan. (2) Without permission, it is forbidden to use electrical equipment with fast temperature rise and high power consumption. Once found, the goods will be confiscated and 500 yuan will be punished. (3) Employees are prohibited from bringing their families and children into the construction site. (4) Those who don't work after drinking, who don't go shirtless, who wear slippers and don't wear helmets enter the construction site to work. Once found, it will be fined 100 yuan/time. ⑤ It is forbidden to connect wires in the field and dormitory without permission. ⑥ All employees who arrive at the construction site must register with the project department, submit their ID cards and family planning certificates, and receive three-level safety education. Pay the fee for temporary residence permit and other documents (this fee shall be borne by Party B).
X. Liability and breach of contract of both parties:
Party A's responsibilities:
(1) Party A shall make overall arrangements, guide and supervise Party B's work, prepare the overall progress, monthly and weekly progress plans, make progress and technical disclosure to Party B, and provide the actual needed information in time according to the report.
(2) During the construction period, Party A shall conduct comprehensive management guidance, supervision and guidance on Party B's safety, quality, progress and civilized construction.
(3) Pay the living expenses and wages in time as agreed.
Party B's responsibilities should be based on the requirements of the project department, and pay comprehensive and serious attention to safety, quality, progress, civilized construction and other matters. The specific agreement is as follows:
(1) Safety: During the construction period, all major and minor safety accidents due to Party B's illegal operation and other reasons shall be borne by Party B (Party A has included the safety deposit in the contract price).
(2) Progress: If Party B fails to implement the progress plan of the project department within the construction period, it will be fined 1 1,000 yuan/day for each day of delay (Party A has included the progress measure fee in the contract price).
(3) Civilized construction: During the construction period, Party B must cooperate with civilized construction as required. If it is not implemented as required, 2 yuan /m2 will be deducted for civilized construction measures, and Party A will send someone to handle it (Party A has included civilized construction measures in the contract price).
(4) All machines, tools and tools used by Party B must be returned to the warehouse according to the actual data of the outbound order. In case of loss or damage, Party B shall compensate at the original price and deduct the liquidated damages for the above items at the time of settlement.
(5) During the performance of the contract, both parties shall not bargain or unreasonably adjust the price.
(6) During the construction period, Party B shall not return the package for any reason or stop work halfway to make trouble. In case of similar situation, Party A has the right to terminate the contract and instruct Party B's personnel to leave the site unconditionally, which is regarded as Party B's failure to perform the settlement obligations.
XI。 Payment method:
(1) Both parties agreed to pay 70% of the completed quantities after the completion of the main structure.
(2) When all the works are completed, 80% of the total works will be paid within one month after the renovation of the main structure is completed.
(4) All quantities shall be completed and paid within one and a half months after reaching the preliminary inspection conditions.
(5) Before each payment of the above-mentioned project funds, it must be audited by the construction personnel of the project department and signed and issued.
The contents of the above-mentioned agreement between the two sides hope that both sides will respect the facts, be sincere and trustworthy, cooperate friendly and develop together.
Twelve. Special agreement:
1. Party B shall not default on the wages of migrant workers for any reason within the validity period of the contract, which will cause migrant workers to petition.
2. During the validity of the contract, Party B shall not interfere with the normal work of Party A's project department for any reason.
3. The project funds within the scope of the contract shall be dominated by Party B, which shall be responsible for its own profits and losses, and Party A shall not bear any economic responsibilities.
4. If Party B violates the three provisions of the appeal, Party A has the right to terminate the contract and punish Party B with RMB 20xx0 yuan, which will be directly deducted from the project payment without Party B's consent.
Thirteen. Matters not covered shall be settled by both parties through consultation.
Fourteen This agreement is made in quadruplicate.
Party A and Party B (official seal): _ _ _ _ _ Party B (official seal): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party A: (hereinafter referred to as Party A)
Party B: (hereinafter referred to as Party B)
Now the interior decoration project is contracted to Party B in the form of contractor. In order to clarify the responsibilities of both parties, the following terms are reached through consultation, which are expected to be observed and performed by both parties and will be used as the basis for settlement after the project is completed. The agreement is as follows:
I. Obligations of both parties
1. Party A arranges the project progress and provides building materials and safety facilities.
2. Party A guarantees the timely supply of materials. Except for materials specially processed according to the required processing cycle, other conventional materials must be delivered within the time agreed by both parties.
3. After rechecking according to the drawings, Party B shall carry out production and assembly according to the drawings (in case of any discrepancy, the company documents shall prevail or be decided by the Engineering Department). According to Party A's instructions, according to the actual construction progress and the actual situation of Party B's site, Party B is responsible for increasing or decreasing the labor force. In case of violation of safety regulations and casualties in production safety, Party B shall bear all expenses.
4. Party B shall handle personal safety insurance procedures at its own expense.
5. Party B shall be equipped with on-site designated safety officers and constructors, and sign the contract.
6. Party B's various types of work should cooperate with each other, and problems can be solved on site or through the project management department.
7. Party B shall complete the construction task within the specified time to ensure the labor balance during holidays, and Party B shall not delay the construction period without reason.
8. Party B shall pass the packaging quality, packaging period and packaging acceptance.
2. Scope and price of the contract:
If the project is completed on time and with good quality, and passed the one-time acceptance by the relevant units, it will be evaluated as an excellent project, and then reward/set will be given.
The above expenses include labor costs of construction personnel, on-site materials storage fees, labor costs of workers, on-site construction coordination fees, on-site construction tools fees, product cleaning and protection fees before products are delivered to customers, etc.
Note: it is necessary to report the list of construction personnel and salary standards provided by the construction team to the company to ensure that the wages of workers are paid in proportion; In case of violation, Party A has the right to pay the workers' wages on behalf of the contractor in the presence of the contractor.
3. Construction period:
According to Party A's construction flow chart, the construction period is tentatively scheduled to be within days, specifically according to Party A's project schedule requirements. If there is any delay, it will be fined every day 150-500 yuan. If the construction period is delayed due to subjective reasons of Party A, the construction period will be postponed and the corresponding living expenses will be made up to the construction team.
Four. Payment and settlement methods:
Pay the living expenses of 5% of the total project amount in advance for 7 days when entering the site (the construction personnel must meet the construction requirements).
● Mud carpentry division (sub-division) is completed, and 40% of the total project price will be paid after acceptance.
● Pay 60% of the total project payment after signing the completion acceptance, and settle the project payment within 10- 15 days after the house is delivered.
5. Construction quality requirements:
1. This project must be constructed in accordance with national standards, market quality inspection standards and drawings. According to national standards and enterprise standards
In other words, it is necessary to check and accept the acceptance standards of residential decoration and Shanghai local standards to ensure the quality acceptance. The construction quality shall be subject to the construction acceptance certificate signed and confirmed by the construction team issued by Su Zhen.
2. In case of any nonconformity or disqualification during construction (except for special arrangement by the Engineering Department), Party B shall bear the cost of rework and impose a fine of 30-50 yuan each time according to the quality penalty regulations.
3. The actual project schedule should be discharged every month and submitted to the project management department.
4. If the project manager finds out the unqualified person, the manager will issue a rectification notice, and the construction team will unconditionally repair it within the specified time until it is approved by the project management department. If rework is caused by subjective reasons of Party A, the expenses shall be borne by Party A. ..
5. Materials or parts used on site shall be protected and shall not be piled up at will.
The engineering department will check these materials and spare parts. Except for proper wear and tear, the quantity of other materials will be compared with the list of materials issued by the budget department. If the loss exceeds a large part, Party B will be responsible for compensation, which will be deducted from its construction project payment.
6. If the company's materials are damaged and the materials used in the rectification project exceed the standard, the money will also be deducted from the project payment.
7. Every employee on the construction site should set up the concept of protecting finished products and protect the finished products of each type of work. If there is any damage, it will be compensated according to the price.
8. All tools used by Party B must be properly protected. For example, machinery, tools, wires, iodine tungsten lamp, helmets and other materials. All the materials received by Party B shall be returned to Party A after the completion of the project (consumables and old products shall be returned to the account), and the missing parts shall be made up as fake.
9. Party B's building materials shall be quantitatively constructed according to the consumption of each suite type. If the quantity exceeds, the excess shall be borne by the construction team (the quantity of materials shall be measured by the company's engineering department on site), especially the cement mortar mixed on the same day, which must be used up on the same day to clean up after work. In case of irregular inspection, Party A will be fined 50-200 yuan.
6. Construction responsibility:
1. Party B shall be responsible for the construction progress and quality of the whole project, including the services during the warranty period and the implementation of the project.
Crew safety production and construction discipline. Strictly implement the project plan to ensure the quality. Assist the project manager to coordinate the field work and write a construction diary every day. Subject to the company's acceptance certificate and obey the unified arrangement of the engineering management department.
2. For the construction team or related personnel who make things difficult for the project management personnel or refuse to carry out the instructions of the engineering department, the engineering department has the right to ask them to leave the company and terminate the contract immediately. If you are not satisfied with this decision, you can report it to the superior leader of the company, but the decision to leave the company must be obeyed.
3. Party B must adhere to the policy of "safe production and civilized construction", conscientiously implement labor, safety and regulations, attach importance to safety production, strengthen safety education, implement safety precautions, and put an end to industrial accidents. In case of personal injury or mechanical equipment accident, all responsibilities and economic losses shall be borne by Party B. ..
4. In the process of organizing production, Party B must strictly abide by the regulations of the state and administrative departments at all levels on labor protection, labor safety and social security. Shall not use the contract to terminate or reduce the treatment of employees.
Medical care for female workers, and the use of child labor is strictly prohibited. Party B's operators must be registered employees of Party B, hold relevant certificates, ensure good technical quality, abide by Party A's various management systems and obey the production mobilization of Party A's management personnel.
5. When signing the contract, Party B shall submit the names, copies of ID cards and photos of all construction personnel to the Engineering Management Department for unified management, and accept the inspection, supervision and rewards and punishments of Party A, and handle temporary residence permits and public security management fees according to the regulations of the local police station, and the expenses shall be borne by Party B. ..
6. At the construction site, employees are not allowed to cook and cook at the construction site, but should cook, cook and dine at the designated place, and ensure that the site is clean, tidy and safe.
Seven. Matters not covered in this contract shall be settled by both parties through consultation. This contract is made in duplicate, one for each party, and shall come into effect after being signed and sealed by both parties. After payment, this contract will automatically become invalid.
Eight. Others. (Site construction related documents issued by Engineering Management Department)
Party A: Shanghai Su Zhen Decoration and Design Co., Ltd.
Party B:
Tel: Tel:
date month year
;