sale
Enterprise contract management (management responsibility system) contract
loan agreement
propertyinsurancecontract
These contract formats are described below.
Contract for the sale of goods
ContractNo.: _ _ _
Buyer: _ _ _ Seller: _ _ _
Tel: _ _ _ Tel: _ _ _
According to the terms of this contract, the buyer agrees to buy and the seller agrees to sell the following products, and hereby sign the contract.
1. Name, specification: _ _ _ Unit: _ _ _ _ _ Quantity: _ _ _ _
Unit price: _ _ _ _ _ Total price: _ _ _ Total price: _ _ _ _ _ _ _
2. Country of origin and manufacturer: _ _ _ _ _ _ _
3. Packaging:
It must be packed in strong wooden cases or cartons. Suitable for long-distance sea/mail/air transportation and adapting to climate change, with good moisture-proof and earthquake-resistant ability.
If the goods are damaged due to poor packaging or rusted due to improper protective measures, the seller shall compensate for all losses caused thereby.
Complete maintenance and operation instructions should be attached to the packing box.
4. marks and numbers:
The seller shall mark the container number, gross weight, net weight, length, width and height with indelible paint on each container, and write the words "moistureproof", "handle with care" and "face up" for shipment:
5. Date of shipment: _ _ _ _ _ _ _
6. Port of shipment: _ _ _ _ _ _
7. Port of discharge: _ _ _ _ _ _
8. Insurance: The insurance shall be covered by the buyer after shipment.
9. Payment terms:
Divided into the following three situations:
(1) Adoption of the letter of credit: the buyer receives the payment and the seller delivers the goods [see Article 1 1 of this contract for details].
20 days before the delivery date, an irrevocable letter of credit for the same shipment amount will be opened by the _ _ _ _ bank in favor of the seller. The seller shall draw on the issuing bank a draft at sight with the amount of 100% of the invoice value, and attach the shipping documents (see Article 10 of this contract). Upon receipt of the above draft and shipping documents, the issuing bank will pay (by telegraphic transfer or air). The validity of the letter of credit is 15 days after the date of shipment.
(2) collection. After the goods are shipped, the seller shall issue a sight draft together with the shipping documents (seeNo. of this contract 10) and submit it to the buyer for collection through the bank where the seller is located and the buyer's bank. ① A business contract is a general contract. In international trade, if both parties have no special requirements for the contracted goods, the contents and forms of commercial contracts are generally adopted.
(3) Direct payment: The buyer shall pay the goods to the seller by telegraphic transfer or airmail within 7 days after receiving the seller's shipping documents (see Article 10 of this contract).
10. Documents: (1) Small ocean transportation: a full set of clean ocean bills of lading marked "freight prepaid" and "freight prepaid", endorsed in blank, and indicating the destination company. (2) Air transportation: Send a copy of the air waybill marked "Freight Paid"/"Freight Item" to the buyer. (3) Airmail: Send an airmail receipt to the buyer. (4) Invoice in quintuplicate, indicating the contract number and shipping marks (if there are multiple shipping marks, the invoice shall be listed separately), and the invoice shall be filled out in detail according to relevant contracts. (5) Packing list in duplicate issued by the manufacturer. (6) Quality and quantity guarantee issued by the manufacturer. (7) Notify the buyer by telegram/letter immediately after the goods are shipped. In addition, within 10 days after shipment, the buyer will send two copies of the above documents (except Article 5) by airmail, one directly to the buyer and the other directly to the company at the port of destination.
1 1. shipment: (1) f.o.b. terms: a. the seller shall notify the buyer of the contract number, product name, quantity, value, container number, gross weight, packing size and the date of arrival of the goods at the port of shipment by telegram/letter 30 days before the shipment date stipulated in the contract, so that the buyer can charter the ship. B the seller's shipping agent _ _ company _ _ (telegram: _ _ _) is responsible for chartering and booking shipping space. C _ _ _ _ chartering company or its port agent (or liner agent) shall notify the seller of the name of the ship, the expected loading date and the contract number 10 days before the expected arrival of the ship at the loading port, so that the seller can arrange shipment. The seller must keep close contact with the freight forwarder. When it is necessary to change the carrying vessel and the arrival of the vessel in advance or later, the buyer or its freight forwarder shall notify the seller in time. If the ship fails to arrive within 30 days after the buyer's notice, the storage fee and insurance premium shall be borne by the buyer after the 30th day. D. If the loading vessel arrives at the loading port as scheduled and the seller fails to make preparations, the deadweight and demurrage shall be borne by the seller. E. If the goods exceed the ship's rail and are not unloaded from the hook, all expenses and risks shall be borne by the seller; If the goods exceed the ship's rail and are unloaded from the hook, all expenses and risks shall belong to the buyer. (2) According to clause C&F: A. During the shipment, the seller is responsible for transporting the goods from the port of shipment to the port of destination. Transshipment is not allowed. B when the goods are sent by airmail/air, the seller shall inform the buyer of the scheduled delivery date, contract number, product name, invoice amount, etc. By telegram/letter 30 days before the delivery date stipulated in Article 5 of this contract. After the goods are delivered, the seller will immediately notify the buyer of the contract number, product name, invoice amount and delivery date by telegram/letter, so that the buyer can insure in time.
12. shipping notice: after all the goods are shipped, the seller shall immediately notify the buyer of the contract number, product name, quantity, invoice amount, gross weight, ship name and sailing date by telegram/letter. If the buyer cannot insure in time due to the seller's untimely notice, the buyer shall bear all the losses.
13. quality assurance: the seller guarantees that the goods supplied are made of the best materials and superb technology, the trademarks are new and unused, and their quality and specifications conform to the description in this contract. The quality guarantee period is 12 months after the goods arrive at the port of destination.
14. Claim: If the quality, specifications and quantity of the goods are found to be inconsistent with the contract within 90 days after the arrival of the goods at the port of destination, the buyer has the right to request a replacement or claim compensation based on the commodity inspection certificate issued by _ _ _ _ _, except for the part that should be borne by the insurance company or the ship. The seller guarantees that within 0/2 months after the goods arrive at the port of destination, the buyer will immediately notify the seller in writing and issue the inspection certificate listed by the Commodity Inspection Bureau, and lodge a claim for the damage caused by poor material quality and poor workmanship during use. Commodity inspection certificate is the basis of claim. According to the buyer's claim, the seller has the responsibility to immediately eliminate the defects of the goods, replace the goods in whole or in part, or reduce the price of the goods according to the defects.
15. Force Majeure: During the manufacture and shipment of the goods, the seller is not responsible for the delay or non-delivery caused by force majeure. The seller shall immediately notify the buyer of the force majeure event and airmail the accident certificate issued by the local authority to the buyer as evidence within 14 days after the event. Even in this case, the seller is still responsible for taking necessary measures to promote delivery as soon as possible. If the contract has not been performed for more than 10 weeks after the force majeure accident, the buyer has the right to cancel the contract.
16. Contract extension and liquidated damages: In addition to the force majeure reasons mentioned in Article 15 of this contract, if the seller fails to deliver the goods on time as stipulated in the contract and pay the liquidated damages confirmed by the seller, the buyer may agree to delay the delivery, and the paying bank will reduce the agreed payment amount accordingly, but the liquidated damages shall not exceed 5% of the total delayed delivery amount. If the seller still fails to deliver the goods after 10 weeks, the buyer has the right to cancel the contract. Although the contract has been terminated, the seller should still pay the above fine as scheduled.
17. Arbitration: All disputes arising from the execution of this contract shall be settled through friendly negotiation. If negotiation fails, it may be submitted to the Arbitration Commission for arbitration in accordance with its arbitration rules and procedures. The arbitration will be held in _ _ _, and the arbitration award is final and binding on both parties. The arbitration fee shall be borne by the losing party. Arbitration can also be conducted in a third country acceptable to both parties.
18. Additional terms: This contract is made in duplicate. This is the only statement signed by both parties, with each party holding one copy.
Seller: _ _ _ Buyer: _ _ _
Representative: _ _ _ Representative: _ _ _
Date: _ _ _ Date: _ _ _
Enterprise contract management (management responsibility system) contract
(A) enterprise bidding contract management contract
Both parties to the contract: Employer: _ _ _ _ _ Contractor: _ _ _ _ _ _ _
In order to deepen enterprise reform and improve labor productivity, the _ _ _ _ Industrial Contracting Committee composed of _ _ _ Administration Bureau of Industrial and Commercial Bank of China, _ _ _ _ Finance Bureau, _ _ _ _ Taxation Bureau, _ _ _ _ Labor Bureau and _ _ _ Branch is the contractor (hereinafter referred to as the contractor). The Employer finally decided that _ _ _ _ _ _ (individual, partner, enterprise and institution as legal person) will be the contractor of _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Chapter I General Provisions
Article 1 On the basis of adhering to the socialist enterprises owned by the whole people, bidding and contracting operations shall select operators through public bidding in accordance with the principle of separation of ownership and management rights, and determine the relationship of responsibility, right and benefit among employers, contractors and enterprise employees in the form of contracts, so that enterprises can truly become independent and self-financing socialist commodity producers.
Article 2 Our factory must adhere to the socialist orientation and implement the principles, policies, regulations and decrees of the party and the state in the contracted operation.
Article 3 During the contracted operation period, our factory shall carry out independent accounting, pay taxes according to regulations, operate independently and be responsible for its own profits and losses. Ownership, original administrative subordination and fiscal and taxation channels remain unchanged.
Article 4 During the contracted operation period, our factory must adhere to the direction of production and operation, and on this basis, we can conduct diversified operations.
Chapter II Term, Form and Main Indicators of Contract
Article 5. The operating period of this tender contract in our factory is _ _ _ years, that is, from _ _ _ _ to _ _ _ _ _ _ _ _.
Article 6 The contract management forms of this tender in our factory are: contract management responsibility system, guaranteed profits turned over, investment in technological transformation, and the total wages of employees linked to the profits turned over.
Article 7 The main economic and technical indicators of this tender contract operation of our factory are paid-in profit, technical transformation investment, loan repayment and enterprise level target. Details are as follows:
The first paragraph is based on the principle of "guaranteed bottom, increasing year by year, making up for the deficiency and exceeding the share", and the total profit paid during the contracted operation period is RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 2 During the contracted operation period, the technical transformation project is guaranteed to be completed, with a total investment of RMB. Among them, the year is ten thousand yuan, the year is ten thousand yuan, the year is ten thousand yuan, and the year is ten thousand yuan. ......
Article 3 During the contracted operation period, the total amount of bank loans returned is RMB. In which _ _ year is _ _ ten thousand yuan. The _ _ year is _ _ ten thousand yuan, the _ _ year is _ _ year, and the _ _ year is _ _ ten thousand yuan.
Article 4 The enterprise goal of our factory is to reach the national (municipal) enterprise standard before the end of the year.
Chapter III Rights and Obligations of the Contractor
Section 1 Contractor's Rights
Article 8 During the contract period, the first contractor contracted by an individual or a partnership (hereinafter referred to as "the first contractor") is the legal representative of the factory, of course, the factory director, and enjoys the responsibility system of the factory director and all the rights and obligations entrusted to the factory director by this contract. Where an enterprise or institution contracts in the form of a legal person, its designated contracting agent (limited to one person) is the legal representative of the factory, exercising the authority of the factory director and performing this contract on behalf of the contractor.
Article 9 During the contract period, the contractor shall have the following rights to the operation and management of the factory:
Rule number one. Have the right to independently appoint deputy factory directors and deputy factory-level administrative cadres to form the factory leadership team according to state regulations, and report to the competent department for the record. After the expiration or termination of the contract, the leading institution shall be dissolved.
Article 2. Have the right to decide the establishment of factories, the appointment and dismissal of factories and the appointment of professional and technical personnel.
Article 3. Have the right to reward and punish, recruit employees and dismiss employees who violate discipline in accordance with relevant regulations.
Article 4. Have the right to reform the internal distribution system of the factory, have the right to choose the salary form independently within the scope of the total salary approved by the superior, and independently set the salary standard.
Article 5 Have the right to purchase new equipment according to actual needs.
Article 6 Under the premise of not violating Article 4 of this contract, Party A has the right to develop new products.
Article 10 The contractor shall have the right to obtain his due legal income according to the provisions of this contract.
Section 2 Contractor's obligations
Article 11 During the contract period, the contractor shall perform the following obligations:
The first paragraph is fully responsible for the material and spiritual civilization construction of our factory.
Article 2 All taxes, fees and funds that should be paid must be paid in full and on time in accordance with relevant state regulations.
Article 3 All economic and technical indicators and additional indicators specified in this contract must be completed on schedule.
Article 4 During the contract period, the plant and equipment shall be guaranteed to be in good condition, and the fixed assets depreciation fund and major repair fund shall be set aside according to the proportion stipulated by the state for special purposes.
Article 5 Complete the mandatory plan issued by the state to our factory.
Article 6 Be responsible for continuing to perform all valid economic contracts signed between the factory and other units, and undertake all original legal creditor's rights and debts between the factory and other units.
Article 7 Consciously accept the supervision of the Party organizations and workers in our factory, respect and protect the democratic rights of the workers in our factory, report to the workers' congress on a regular basis, and listen to the opinions and suggestions of the workers.
Article 8. Safeguard the legitimate rights and interests of employees in our factory, improve their working conditions, and gradually increase their income and welfare on the premise of continuously improving their economic benefits.
Article 12 A contractor shall use certain self-owned funds as collateral (or guarantee). The amount of the contractor's mortgage (or deposit) is RMB.
Article 13 The contractor must fully perform all the clauses in this contract that should be performed by the contractor.
Chapter IV Rights and Obligations of the Employer
Article 14 The rights of an employer are as follows:
Rule number one. Have the right to safeguard the national interests and the interests of our factory from being damaged.
Article 2 Have the right to supervise the product management direction of our factory.
Article 3 We have the right to conduct financial supervision, auditing and product quality inspection.
Article 4 Have the right to safeguard the legitimate rights and interests of the workers and staff of our factory in accordance with national laws and regulations and the provisions of this contract.
Article 15 The obligations of the employer are as follows:
The first paragraph shall not violate the provisions of this contract or interfere with the contractor's business autonomy.
Article 2 The assets of our factory shall not be transferred horizontally.
The third paragraph must guarantee the legitimate rights and interests of the contractor in accordance with the provisions of this contract.
Article 4 All the clauses in this contract that should be performed by the Employer must be fully performed.
Chapter V Contractor's Income
Article 16 A contractor (referring to the contractor, the first contractor contracted by a partnership, and the contracting agent appointed by an enterprise or institution as a legal person, the same below) enjoys the income of the operator during the contract period, and its original salary level is filed. After the performance of this contract, if the contractor does not continue to contract, his salary level will be re-approved according to the relevant national salary policy. During the contract period, the contractor enjoys the welfare treatment of factory workers, and the state regulations and various subsidies are paid as usual.
Article 17 The contractor's income during the contract period shall be determined according to the principle of assessment linked to various economic and technical indicators and additional indicators stipulated in this contract. (Additional indicators refer to: sales revenue, product quality, production safety, labor productivity, capital profit and tax rate. This index is implemented according to the plan issued by the _ _ competent bureau every year)
The specific provisions are as follows:
Paragraph 1: The contractor shall complete the annual economic and technical indicators and additional indicators specified in this contract, and its income shall be based on the per capita income of employees in this factory in that year, and the income shall be twice as high as the base. Every time the profit turned over exceeds the current year's target 1%, it will accumulate a considerable income of _ _% until it reaches four times the base.
In the second paragraph, if the employer thinks that the contractor has made special contributions, he can give special rewards.
Article 3. Only the living expenses shall be paid in advance to the contractor who has actually worked for less than nine months due to illness or personal leave.
Article 4 The calculation range of per capita annual income of employees shall be implemented in accordance with the provisions of DocumentNo..
Article 18 If an enterprise or institution contracts more than the annual economic and technical indicators and additional indicators stipulated in this contract, its contracting income will be returned to the local area at 50% of the profits turned over by the contracting indicators, and the other 50% will be returned to the factory as a production development fund.
Article 19 The contractor's income shall be settled at the end of each year. Before the end of the year, the contractor can only advance the living expenses according to the standard of _ _ yuan per month (excluding subsidies stipulated by the state). After the year-end settlement, the personal income of the contractor and the income of enterprises and legal persons shall be paid by the employer in one lump sum.
Chapter VI Modification, Dissolution or Termination of a Contract
Article 20 This contract shall be legally binding after it comes into effect, and neither party shall change or terminate it at will. When this contract needs to be modified or dissolved, both parties must reach a new written agreement through consultation. This contract is still valid until a new written agreement is reached.
Article 21 During the performance of this contract, if the interests of either party to this contract are significantly affected by the relevant policies of the state compared with the signing of this contract, the affected party may propose to change or terminate this contract.
Article 22 If the contractor's poor management or serious mistakes in business decisions cause heavy losses to the factory or fail to meet the annual profit target stipulated in the cost contract for two consecutive years, the employer has the right to terminate the contract and reserve the right to claim compensation from the contractor.
Article 23 If the employer violates the provisions of this contract and interferes with the contractor's business management activities, so that the contractor can't continue to operate, or the contractor's legitimate income can't be guaranteed, the contractor has the right to terminate this contract and ask the employer to bear the liability for breach of contract.
Article 24 If the Contract cannot be fully performed or cannot be performed due to force majeure, the Contract may be modified or dissolved through negotiation between the contracting parties.
Article 25 This contract will automatically terminate after the expiration of the contract and the fulfillment of the rights and obligations of both parties.
Article 26 30 days before the expiration of this contract, the contractor shall accept the audit institution sent by the employer to audit its contracting situation, and the contractor shall not leave his post until the audit opinions are signed by the representatives of both parties.
Chapter VII Liability for Breach of Contract
Article 27 The Employer and the Contractor shall fully and earnestly perform this contract, and shall be liable for breach of contract if they fail to perform it or fail to perform it completely.
Article 28 If the contractor fails to complete the economic and technical indicators and annual additional indicators specified in this contract on schedule, it shall bear the liability for breach of contract and the corresponding economic penalties, as follows:
Paragraph 1 If the contractor fails to reach the annual profit target stipulated in the cost contract, 7% of the contractor's personal living expenses in advance shall be deducted for each reduction of 1% until 50% of his file salary is deducted.
Article 2 If the contractor fails to complete other annual economic and technical indicators and various additional indicators stipulated in the cost contract, the employer shall deduct the contractor's total income in that year as appropriate, but the maximum amount shall not exceed _% of its total income in that year.
Article 3 The contractor's unfinished profit target when the contract is dissolved or terminated shall be made up by his own mortgage (including the guarantor's) in addition to deducting the income according to the first to third paragraphs of this article until it is paid off or fully paid off.
Article 4 If an enterprise or institution as a legal person fails to achieve its annual profit target, it must make up for it with its own funds.
Article 5 Where an enterprise or institution contracts as a legal person, but fails to complete the annual economic, economic and technical indicators and additional indicators, the employer shall deduct the dividend income of the contractor as appropriate, but the maximum amount shall not exceed _% of the income.
Article 6 The deductions and offsets referred to in paragraphs 1 to 5 of this article are the default amount paid by the contractor in violation of this article. The contractor shall be responsible for paying liquidated damages to the owner before the end of March of the second year after the breach of contract. If the Contractor fails to pay the liquidated damages, it shall pay the Employer a late fee of three ten thousandths of the overdue amount on a daily basis, and the late fee shall be borne by the Contractor.
Article 29 If the Employer violates the provisions of Article 21 of this contract, it shall be liable for breach of contract, compensate the contractor for the direct economic losses caused by the breach of contract, and pay the contractor a penalty of 3% of the direct economic losses caused thereby. The employer's compensation and liquidated damages shall be delivered to the contractor before the end of January of the second year after the default. If the payment is delayed, from the date of delay to the date of completion, the employer shall pay the contractor a late payment fee of 3% of the delayed amount, and the late payment fee shall be borne by the employer.
Thirtieth when there is a dispute between the employer and the contractor, it shall be implemented in accordance with the Provisional Regulations on the Contract Management Responsibility System for Industrial Enterprises Owned by the Whole People.
Chapter VIII Supplementary Provisions
Article 31 If the original first contractor contracted by partnership (or the original designated contractor operator contracted by an enterprise or institution as a legal person) cannot continue to perform this contract due to an accident, the contractor (or enterprise or institution as a legal person) shall select (or assign) another first contractor (or contractor operator) to continue to perform the contract after confirmation by the employer.
Article 32 After the expiration of this contract, if the factory still carries out bidding operation and the contractor's performance is good, the contractor has the priority to re-contract under the same conditions.
Article 33 The bidding documents of the Employer, the bidding documents of the Contractor and the defense materials (cooperation agreement of the cooperative contractor) are all annexes to this contract. In case of any conflict between the above documents and materials and this contract, this contract shall prevail.
Article 34 This contract shall be signed by the representatives of the Employer and the Contractor, and shall come into effect after being notarized by a notary office.
Article 35 The original of this contract shall be held by the Employer, the Contractor and the Notary Office respectively.
This contract is made in several copies and submitted to the enterprise contracting steering committee and the member units of the employer for the record. The copy of this contract has the same legal effect as the original.
The employer _ _ the contractor _ _
Representative _ _ (signature and seal) Representative _ _ (signature and seal)
_ _ _ _ _ _ _ _ _ _ _
loan agreement
ContractNo.: _ _ _ _ _
Lender: _ _ _ _ _ _ _ _ _
Borrower: _ _ _ _ _ _ _ _ _
Guarantor: _ _ _ _ _ _ _ _
(Whether there should be a guarantor in the loan contract should be determined according to whether the borrower has a certain proportion of its own funds and marketable and applicable materials and property stipulated by the bank, or whether one or both borrowers request a guarantee. )
The borrower applies for a loan from the lender for _ _ _ _ _ _ _ production (or business activities) and employs _ _ _ _ as the guarantor. The Lender has reviewed and approved the Contract, and the three parties (or both parties) have reached an agreement to make it binding.
Article 1: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2: The purpose of the loan is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 3: The loan amount is RMB (in words) _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 4: Loan Interest Rate The loan interest is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 5: Loan Term and Repayment Method
1. The loan term is * * _ _ _ _ years, starting from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. The loan installment is as follows:
Loan term:
Loan amount:
Before the end of the first year of Yuan Dynasty.
Yuan before the end of the second year
At the end of the third year before Yuan Dynasty.
2. The repayment stages are as follows:
The repayment period, repayment time, repayment amount and interest rate at the time of repayment.
Before the end of the first year of Yuan Dynasty.
Yuan before the end of the second year
At the end of the third year before Yuan Dynasty.
Article 6: Sources of repayment funds and repayment methods
1. Source of repayment funds: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. repayment method: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 7: Warranty clause
1. If the borrower takes _ _ _ _ _ as collateral and cannot repay the loan to the lender at maturity, the lender has the right to dispose of the collateral. If the borrower repays the loan in full when due, the lender shall return the collateral to the borrower.
2. The borrower must use the loan according to the purpose stipulated in the loan contract, and shall not use it for other purposes or engage in illegal activities.
The borrower must repay the principal and interest within the time limit stipulated in the contract.
4. The borrower has the obligation to accept the lender's inspection, supervise the use of the loan, and understand the borrower's plan implementation, business management, financial activities, material inventory, etc. The borrower shall provide relevant plans, statistics, financial and accounting statements and materials.
5. When a guarantor is needed, the guarantor has the right to recover from the borrower after performing joint and several liabilities, and the borrower has the obligation to repay the guarantor.
Article 8: Liability for breach of contract
First, the borrower's liability for breach of contract
1. If the borrower fails to use the loan according to the purpose stipulated in the contract, the lender has the right to recover part or all of the loan, and the bank will charge default interest at the stipulated interest rate for the part used in violation of the contract.
2. If the borrower fails to repay the loan within the time limit, the lender has the right to recover the loan and collect the penalty interest according to the regulations of the bank. If the borrower repays the loan in advance, the interest will be reduced according to the regulations.
Two. Lender's liability for breach of contract If the lender fails to provide the loan on schedule, it shall pay the borrower liquidated damages according to the amount of breach of contract and the number of days of extension. The calculation of the amount of liquidated damages shall be the same as that of the borrower's penalty interest.
Article 9: Other (dispute settlement methods, etc. )
________________________________________________________________________
________________________________________________________________________。
All necessary measures